Technology & Communications (DoIT&C) Government of Rajasthan (GoR)

More documents

Recommendations

Info

Final RFP - Maintenance of IT Hardware under various projects of DoIT&C c) In case supply is desired to be sent by the purchase officer by passenger train, the entire railway freight will be borne by the bidder. d) Remittance charges on payment made shall be borne by the bidder. 23) Payments a) Advance Payment will not be made except in rare and special cases. In case of advance payment being made, it will be against proof of despatch and to the extent as prescribed in financial powers by rail/ reputed goods transport companies, etc., and prior inspection, if any. The balance, if any, will be paid on receipt of the consignment in good condition with the certificate to that effect endorsed on the inspection not given to the bidder. b) Unless otherwise agreed between the parties, payment for the delivery of the stores will be made on submission of bill in proper form by the bidder to the Purchase Officer in accordance with G.F.& A.R all remittance charges will be bourne by the bidder. c) In case of disputed items, 10% to 25% of the amount shall be withheld and will be paid on settlement of the dispute. d) Payment in case of those goods which need testing shall be made only when such tests have been carried out, test results received conforming to the prescribed specification. 24) Liquidated Damages (LD) a) In case of extension in the delivery period with liquidated damages the recovery shall be made on the basis of following percentages of value (calculated for a quarter) of which the bidder has failed to supply/commence services:- delay up to one fourth period of the prescribed delivery period: 2.5% delay exceeding one fourth but not exceeding half of the prescribed period: 5.0% delay exceeding half but not exceeding three fourth of the prescribed period: 7.5% delay exceeding three fourth of the prescribed period: 10% b) Fraction of a day in reckoning period of delay in supplies shall be eliminated if it is less than half a day. c) The maximum amount of liquidated damages shall be 10% of the contract value. d) If the supplier requires an extension of time in completion of contractual supply on account of occurrence of any hindrance, he shall apply in writing to the authority, which has placed the supply order, for the same immediately on occurrence of the hindrance but not after the stipulated date of completion of supply. e) Delivery period may be extended with or without liquidated damages if the delay in the supply of goods is on account of hindrances beyond the control of the bidder. 25) Bidders must make their own arrangements to obtain import licence, if necessary. If a bidder imposes conditions which are in addition to or in conflict with the conditions mentioned herein, his bid is liable to summary rejection. In any case none of such conditions will be Page 46 of 77
Final RFP - Maintenance of IT Hardware under various projects of DoIT&C deemed to have been accepted unless specifically mentioned in the letter of acceptance of bid issued by the Purchase Officer. 26) Settlement of Disputes: If any dispute arise out of the contract with regard to the interpretation, meaning and breach of the terms of the contract, the matter shall be referred to by the Parties to the Head of the Department who will appoint his senior most deputy as the Sole Arbitrator of the dispute who will not be related to this contract and whose decision shall be final. 27) All legal proceedings, if necessary arise to institute may by any of the parties (Government of Contractor) shall have to be lodged in courts situated in Rajasthan and not elsewhere. 28) Authenticity of Equipment a) The selected bidder shall certify (as per Annexure-6) that the replaced part / sub parts / assemblies are brand new, genuine/ authentic, not refurbished, conform to the description and quality as specified in this bidding document and are free from defects in material, workmanship and service. b) If during the contract period, the said goods be discovered counterfeit/ unauthentic or not to conform to the description and quality aforesaid or have determined (and the decision of the Purchase Officer in that behalf will be final and conclusive), notwithstanding the fact that the purchaser may have inspected and/ or approved the said goods, the purchaser will be entitled to reject the said goods or such portion thereof as may be discovered not to conform to the said description and quality, on such rejection the goods will be at the selected bidder‟s risk and all the provisions relating to rejection of goods etc., shall apply. The selected bidder shall, if so called upon to do, replace the goods etc., or such portion thereof as is rejected by Purchase Officer, otherwise the selected bidder shall pay such damage as may arise by the reason of the breach of the condition herein contained. Nothing herein contained shall prejudice any other right of the Purchase Officer in that behalf under this contract or otherwise. c) Goods accepted by the purchaser in terms of the contract shall in no way dilute purchaser‟s right to reject the same later, if found deficient in terms of the this clause of the contract. 29) Patent Indemnity a) The supplier/ selected bidder shall, subject to the Purchaser‟s compliance with subclause (b) below, indemnify and hold harmless the Purchaser and its employees and officers from and against any and all suits, actions or administrative proceedings, claims, demands, losses, damages, costs, and expenses of any nature, including attorney‟s fees and expenses, which the Purchaser may suffer as a result of any infringement or alleged Page 47 of 77
Page 1 and 2: 2013 cument History Overview Docume
Page 3 and 4: Final RFP - Maintenance of IT Hardw
Page 45: Final RFP - Maintenance of IT Hardw
Page 77: Final RFP - Maintenance of IT Hardw

Technology & Communications (DoIT&C) Government of Rajasthan (GoR)

Create successful ePaper yourself

Delete template?

Save as template?