CIVIL WORK - Government of Himachal Pradesh

More documents

Recommendations

Info

SECTION 2:FORMS OF BID, QUALIFICATION INFORMATION ANDLETTER OF ACCEPTANCETable of Forms:- CONTRACTOR’S BID- QUALIFICATION INFORMATION- LETTER OF ACCEPTANCE- NOTICE TO PROCEED WITH THE WORK- AGREEMENT FORMContractor EE 22
Description of the Works:Contractor's BidPeriodic Maintenance of Sainj Chopal Nerwa Shallu RoadPackage No. HP-SH-08 (Sub Head: Providing and Laying20mm thick open-graded premix surfacing, Profile CorrectionCourse, Repair to C.D. Works, Retaining walls and Breastwalls, Side Drain and Parapets in PCC and road side furnitureand fixing sign boards and & Bioengineering measures)ii. Section from KM 38/0 to KM 90/0BID:ToAddressPackage No. HP-SH-08: The Chief Engineer (South Zone): HP PWD, Nirman Bhawan, Shimla-2GENTLEMEN,Having examined the bidding documents including addendum, we offer to execute the Works describedabove in accordance with the Conditions of Contract, Specifications, Drawings and Bill of Quantitiesaccompanying this Bid for the Contract Price of _________ [in figures](__________________________________________________) [in letters]. 3The advance Payment required is: Rupees ________________.We accept the appointment of Sh. S.P Negi (Retd. E-in-C) as the Adjudicator.(OR)We do not accept the appointment of ___________________ as the Adjudicator and propose instead that_______________________ be appointed as Adjudicator whose daily fees and biographical data areattached.This Bid and your written acceptance of it shall constitute a binding contract between us. We understandthat you are not bound to accept the lowest or any Bid you receive.We hereby certify that we have taken steps to ensure that no person acting for us or on behalf will engagein bribery.We undertake that, in competing for (and, if the award is made to us, in executing) the above contract, wewill strictly observe the laws against fraud and corruption in force in India namely “Prevention ofCorruption Act 1988”.Commissions or gratuities, if any, paid or to be paid by us to agents relating to this Bid, and to contractexecution if we are awarded the contract, are listed below:Name and address of agent Amount Purpose of Commission or gratuity______________________ ________ __________________________________________________ ________ __________________________________________________ ________ ____________________________(if none, state “none”)______________________________1 To be filled in by the Employer before issue of the Bidding Documents.2 To be filled in by the Employer before issue of the Bidding Documents.3 To be filled in by the Bidder, together with his particulars and date of submission at the bottom of theForm of Bid.Contractor EE 23
Page 1 and 2: GOVERNMENT OF HIMACHAL PRADESHSTATE
Page 3: GOVERNMENT OF HIMACHAL PRADESHSTATE
Page 7 and 8: 1. Scope of BidA. General1.1 The Ch
Page 9 and 10: (c)executed in any one year, the fo
Page 11 and 12: 4.7 Bidders who meet the minimum qu
Page 13 and 14: 10.2 Any addendum thus issued shall
Page 15 and 16: 16.2 Bank guarantees issued as sure
Page 17 and 18: E. Bid Opening and Evaluation23. Bi
Page 19 and 20: equirements of the Bidding document
Page 21: (ii) “fraudulent practice” 3 is
Page 25 and 26: Qualification InformationThe inform
Page 27 and 28: 1.5 The following items of Contract
Page 29 and 30: B. For field-testing laboratory:Pos
Page 31 and 32: SAMPLE FORMAT FOR EVIDENCE OF ACCES
Page 33 and 34: 6. We confirm that the above goods
Page 35 and 36: Issue of Notice to proceed with the
Page 37 and 38: In witness whereof the parties ther
Page 39 and 40: Conditions of ContractTable of Cont
Page 41 and 42: The Intended Completion Date is the
Page 43 and 44: 9.3 The Contractor shall not employ
Page 45 and 46: 23. Instructions23.1 The Contractor
Page 47 and 48: C. Quality Control33. Identifying D
Page 49 and 50: 42.4 The value of work executed sha
Page 51 and 52: 47.2 To the extent that full compen
Page 53 and 54: 59. Termination59.1 The Employer or
Page 55 and 56: (iv)(v)(aa)(bb)“coercive practice
Page 57 and 58: SALIENT FEATURES OF SOME MAJOR LABO
Page 59 and 60: c) the purchase of materials which
Page 61 and 62: 5. PROTECTION OF ENVIRONMENT:Add th
Page 63 and 64: Contract DataItems marked "N/A" do
Page 65 and 66: Insurance requirements are as under
Page 67 and 68: The amounts of the advance payment
Page 69 and 70: SECTION 5: SPECIFICATIONSContractor
Page 71 and 72: SECTION 6: DRAWINGSContractor EE 71
Page 73 and 74:
SECTION 7: Bill of QuantitiesPreamb
Page 75 and 76:
deleterious materials and disposal
Page 77 and 78:
2100 of MORT&H specification(latest
Page 79 and 80:
olling with 3-wheeled steel/vibrato
Page 81 and 82:
the black and white alternative ban
Page 83 and 84:
contract duration (including extens
Page 85 and 86:
Detail of Bio- Engineering Measures
Page 87 and 88:
Periodicity of Routine Maintenance
Page 89 and 90:
Forms of SecuritiesAcceptable forms
Page 91 and 92:
PERFORMANCE BANK GUARANTEEAnnex BTo
Page 93:
BANK GUARANTEE FOR ADVANCE PAYMENTA
show all

CIVIL WORK - Government of Himachal Pradesh

Create successful ePaper yourself

Delete template?

Save as template?