Improvement of FPA Laboratory - Fertilizer and Pesticide Authority

(b)(c)(d)(e)(f)(g)(h)The Procuring Entity’s Representative instructs the Contractor to delaythe progress of the Works, and the instruction is not withdrawn withintwenty eight (28) days;The Procuring Entity shall terminate this Contract if the Contractor isdeclared bankrupt or insolvent as determined with finality by a court ofcompetent jurisdiction. In this event, termination will be withoutcompensation to the Contractor, provided that such termination willnot prejudice or affect any right of action or remedy which has accruedor will accrue thereafter to the Procuring Entity and/or the Contractor.In the case of the Contractor's insolvency, any Contractor's Equipmentwhich the Procuring Entity instructs in the notice is to be used until thecompletion of the Works;A payment certified by the Procuring Entity’s Representative is notpaid by the Procuring Entity to the Contractor within eighty four (84)days from the date of the Procuring Entity’s Representative’scertificate;The Procuring Entity’s Representative gives Notice that failure tocorrect a particular Defect is a fundamental breach of Contract and theContractor fails to correct it within a reasonable period of timedetermined by the Procuring Entity’s Representative;The Contractor does not maintain a Security, which is required;The Contractor has delayed the completion of the Works by thenumber of days for which the maximum amount of liquidated damagescan be paid, as defined in the GCC Clause 9; andIn case it is determined prima facie by the Procuring Entity that theContractor has engaged, before or during the implementation of thecontract, in unlawful deeds and behaviors relative to contractacquisition and implementation, such as, but not limited to, thefollowing:(i)(ii)(iii)(iv)corrupt, fraudulent, collusive, coercive, and obstructivepractices as defined in ITB Clause 3.1(a), unless otherwisespecified in the SCC;drawing up or using forged documents;using adulterated materials, means or methods, or engaging inproduction contrary to rules of science or the trade; andany other act analogous to the foregoing.18.4. The Funding Source or the Procuring Entity, as appropriate, will seek toimpose the maximum civil, administrative and/or criminal penaltiesavailable under the applicable law on individuals and organizations deemedto be involved with corrupt, fraudulent, or coercive practices.57