Asphalt Overlay of CDC Roads - Clark Freeport Zone

More documents

Recommendations

Info

Special Conditions of ContractGCC Clause1.16 The Intended Completion Date is [Insert date].1.21 The Procuring Entity is Clark Development Corporation Bldg. 2122 E.Quirino St. CDC Corporate Center, Clark Freeport Zone, Philippines.1.22 The Procuring Entity’s Representative isEngr. Rene S. ArcillaOfficer-In-ChargeEngineering, Construction and Maintenance DepartmentBldg. 2125, E. Quirino Avenue corner Carlos P. Garcia St.CDC Corporate Center, Clark Freeport Zone, Philippines 2023The Duly Authorized Representative is Engr. Alan C. Turla1.23 The Site is located at Clark Freeport Zone and is defined in drawings No.[Insert Number].1.27 The Start Date is within seven (7) calendar days upon receipt of theNotice to Proceed.1.30The Works involves the asphalt overlay of E. Aguinaldo Street, MalomaStreet, Magsaysay Avenue, Abacan Street and Chico Street in accordancewith the Scope of Works and Technical Specifications including compliancewith the latest DPWH Standards and Specifications.2.2 If different dates are specified for completion of the Works by section(“sectional completion”), these dates should be listed here5.1. The Procuring Entity shall give possession of all parts of the Site to theContractor upon receipt of Notice to Proceed.6.5. The Contractor shall employ the following Key Personnel:[List key personnel by name and designation]7.1. No further instructions.7.4(c)The Contractor had submitted the required warranty security.8.1. No further instructions.9.1. The applicable liquidated damages is one tenth (1/10) of one percent ofthe cost of the unperformed portion for every day of delay.78Clark Development CorporationSection V Special Conditions of the ContractAsphalt Overlay of CDC Roads
The maximum deduction shall be ten percent (10%) of the amount of thecontract, the Procuring Entity shall rescind the contract, without prejudiceto other courses of action and remedies open to it.10. The site investigation reports are: none12.5. In case of semi-permanent structures, such as buildings of types 1, 2, and3 as classified under the National Building Code of the Philippines,concrete/asphalt roads, concrete river control, drainage, irrigation linedcanals, river landing, deep wells, rock causeway, pedestrian overpass, andother similar semi-permanent structures: Five (5) years.13. If the Contractor is a joint venture, “All partners to the joint venture shallbe jointly and severally liable to the Procuring Entity.”21.2. The Arbiter is:Construction Industry Arbitration Commission4F, Jupiter Building56 Jupiter Street, Bel Air Makati City21.3. No further instructions.26.1. No further instructions.29.1. Day works are applicable at the rate shown in the Contractor’s original Bid.31.1. The Contractor shall submit the Detailed Program of Work to theProcuring Entity’s Representative within fourteen (14) calendar daysupon receipt of the Notice to Proceed.31.3. The period between Program of Work updates is seven (7) days.The amount to be withheld for late submission of an updated Program ofWork is 1% of every Progress Billing of the Contractor.34.3. The Funding Source is the Government of the Philippines.37.1. No further instructions.39.1. The amount of the advance payment is 15% of the Contract Amount.40.1. No further instructions.40.3. No further instructions.42.2. No further instructions.48. No further instructions.51.1. The date by which operating and maintenance manuals are required iswithin seven (7) working days upon satisfactory completion.The date by which “as built” drawings are required is within seven (7)working days upon satisfactory completion.79Clark Development CorporationSection V Special Conditions of the ContractAsphalt Overlay of CDC Roads
Page 1 and 2:
Clark Development CorporationClark
Page 3 and 4:
Section I. Invitation to BidClark D
Page 5 and 6:
5. A complete set of Bidding Docume
Page 7 and 8:
Section II. Instructions to Bidders
Page 9 and 10:
A. General1. Scope of Bid1.1. The P
Page 11 and 12:
(c)(d)(e)(f)(g)A Bidder has the sam
Page 13 and 14:
5.4. Unless otherwise provided in t
Page 15 and 16:
terrain, geological conditions at t
Page 17 and 18:
11. Language of BidsC. Preparation
Page 20 and 21:
14. Alternative Bids14.1. Alternati
Page 22 and 23:
(b) Irrevocable letter of credit is
Page 24 and 25:
20. Sealing and Marking of Bids20.1
Page 26 and 27:
this regard, bids that fail to incl
Page 28 and 29:
(b)The ranking of the total bid pri
Page 30 and 31: Entity shall approve or disapprove
Page 32 and 33: (c)(d)Signing of the contract as pr
Page 34 and 35: 33. Notice to Proceed33.1. Within t
Page 36 and 37: ITB ClauseBid Data Sheet1.1. The PR
Page 38 and 39: 2. Php 90,140.00 (2% of ABC), Irrev
Page 40 and 41: Return (Monthly: BIR Form No. 2550-
Page 42 and 43: TABLE OF CONTENTS1. DEFINITIONS ...
Page 44 and 45: 1. DefinitionsFor purposes of this
Page 46 and 47: 1.24. Site Investigation Reports ar
Page 48 and 49: All Materials and Plant on Site sha
Page 50 and 51: 7. Performance Security7.1. Unless
Page 52 and 53: 10. Site Investigation ReportsThe C
Page 54 and 55: Form of Warranty(a) Cash or letter
Page 56 and 57: evidence and such policies shall be
Page 58 and 59: 17. Termination for Default of Proc
Page 60 and 61: 18.6. If this Contract is terminate
Page 62 and 63: accordance with approved plans and
Page 64 and 65: agreement, the parties may agree in
Page 66 and 67: (d)At appropriate new rates, equal
Page 68 and 69: 33. Bill of Quantitiesthe PROCURING
Page 70 and 71: 38.2. The use of a third party to c
Page 72 and 73: 42.2. Progress payments are subject
Page 74 and 75: justifications for the need of such
Page 76 and 77: 46. Payment on Termination46.1. If
Page 78 and 79: 49. CompletionThe Contractor shall
Page 82 and 83: 51.2.The amount to be withheld for
Page 84 and 85: PROJECT TITLE : Asphalt Overlay of
Page 86 and 87: Section VII. DrawingsSee attached84
Page 88 and 89: Section IX. Bidding FormsTABLE OF C
Page 90 and 91: (e) Our firm, including any subcont
Page 92 and 93: 3. In consideration of the payments
Page 94 and 95: 5. [Name of Bidder] is authorizing
Page 96 and 97: Contracting Capability Any one of t
Page 98 and 99: Sample Forms of Eligibility, Techni
Page 100 and 101: Standard Form Number: SF-INFR-16Sta
Page 102 and 103: Standard Form Number: SF-INFR-20Rev
Page 104 and 105: his demand the Entity will note tha
Page 106 and 107: 3) if the Principal having been not
Page 112 and 113: Series of _________;Standard Form N
Page 114 and 115: Standard Form Number: SF-INFR-48Qua
Page 116 and 117: DAYWORK SCHEDULEPROJECT : Asphalt O
show all

Asphalt Overlay of CDC Roads - Clark Freeport Zone

You also want an ePaper? Increase the reach of your titles

Delete template?

Save as template?