Asphalt Overlay of CDC Roads - Clark Freeport Zone
Asphalt Overlay of CDC Roads - Clark Freeport Zone Asphalt Overlay of CDC Roads - Clark Freeport Zone
1. DefinitionsFor purposes of this Clause, boldface type is used to identify defined terms.1.1. The Arbiter is the person appointed jointly by the Procuring Entity andthe Contractor to resolve disputes in the first instance, as provided forin GCC Clause 21.1.2. Bill of Quantities refers to a list of the specific items of the Work andtheir corresponding unit prices, lump sums, and/or provisional sums.1.3. The Completion Date is the date of completion of the Works ascertified by the Procuring Entity’s Representative, in accordance withGCC Clause 49.1.4. The Contract is the contract between the Procuring Entity and theContractor to execute, complete, and maintain the Works.1.5. The Contract Price is the price stated in the Letter of Acceptance andthereafter to be paid by the Procuring Entity to the Contractor for theexecution of the Works in accordance with this Contract.1.6. Contract Time Extension is the allowable period for the Contractorto complete the Works in addition to the original Completion Datestated in this Contract.1.7. The Contractor is the juridical entity whose proposal has beenaccepted by the Procuring Entity and to whom the Contract to executethe Work was awarded.1.8. The Contractor’s Bid is the signed offer or proposal submitted by theContractor to the Procuring Entity in response to the BiddingDocuments.1.9. Days are calendar days; months are calendar months.1.10. Day works are varied work inputs subject to payment on a time basisfor the Contractor’s employees and Equipment, in addition to paymentsfor associated Materials and Plant.1.11. A Defect is any part of the Works not completed in accordance withthe Contract.1.12. The Defects Liability Certificate is the certificate issued byProcuring Entity’s Representative upon correction of defects by theContractor.1.13. The Defects Liability Period is the one year period between projectcompletion and final acceptance within which the Contractor assumes42Clark Development CorporationSection IV General Conditions of the ContractAsphalt Overlay of CDC Roads
the responsibility to undertake the repair of any damage to the Worksat his own expense.1.14. Drawings are graphical presentations of the Works. They include allsupplementary details, shop drawings, calculations, and otherinformation provided or approved for the execution of this Contract.1.15. Equipment refers to all facilities, supplies, appliances, materials orthings required for the execution and completion of the Work providedby the Contractor and which shall not form or are not intended to formpart of the Permanent Works.1.16. The Intended Completion Date refers to the date specified in theSCC when the Contractor is expected to have completed the Works.The Intended Completion Date may be revised only by the ProcuringEntity’s Representative by issuing an extension of time or anacceleration order.1.17. Materials are all supplies, including consumables, used by theContractor for incorporation in the Works.1.18. The Notice to Proceed is a written notice issued by the ProcuringEntity or the Procuring Entity’s Representative to the Contractorrequiring the latter to begin the commencement of the work not laterthan a specified or determinable date.1.19. Permanent Works all permanent structures and all other projectfeatures and facilities required to be constructed and completed inaccordance with this Contract which shall be delivered to the ProcuringEntity and which shall remain at the Site after the removal of allTemporary Works.1.20. Plant refers to the machinery, apparatus, and the like intended toform an integral part of the Permanent Works.1.21. The Procuring Entity is the party who employs the Contractor tocarry out the Works stated in the SCC.1.22. The Procuring Entity’s Representative refers to the Head of theProcuring Entity or his duly authorized representative, identified in theSCC, who shall be responsible for supervising the execution of theWorks and administering this Contract.1.23. The Site is the place provided by the Procuring Entity where the Worksshall be executed and any other place or places which may bedesignated in the SCC, or notified to the Contractor by the ProcuringEntity’s Representative as forming part of the Site.43Clark Development CorporationSection IV General Conditions of the ContractAsphalt Overlay of CDC Roads
- Page 1 and 2: Clark Development CorporationClark
- Page 3 and 4: Section I. Invitation to BidClark D
- Page 5 and 6: 5. A complete set of Bidding Docume
- Page 7 and 8: Section II. Instructions to Bidders
- Page 9 and 10: A. General1. Scope of Bid1.1. The P
- Page 11 and 12: (c)(d)(e)(f)(g)A Bidder has the sam
- Page 13 and 14: 5.4. Unless otherwise provided in t
- Page 15 and 16: terrain, geological conditions at t
- Page 17 and 18: 11. Language of BidsC. Preparation
- Page 20 and 21: 14. Alternative Bids14.1. Alternati
- Page 22 and 23: (b) Irrevocable letter of credit is
- Page 24 and 25: 20. Sealing and Marking of Bids20.1
- Page 26 and 27: this regard, bids that fail to incl
- Page 28 and 29: (b)The ranking of the total bid pri
- Page 30 and 31: Entity shall approve or disapprove
- Page 32 and 33: (c)(d)Signing of the contract as pr
- Page 34 and 35: 33. Notice to Proceed33.1. Within t
- Page 36 and 37: ITB ClauseBid Data Sheet1.1. The PR
- Page 38 and 39: 2. Php 90,140.00 (2% of ABC), Irrev
- Page 40 and 41: Return (Monthly: BIR Form No. 2550-
- Page 42 and 43: TABLE OF CONTENTS1. DEFINITIONS ...
- Page 46 and 47: 1.24. Site Investigation Reports ar
- Page 48 and 49: All Materials and Plant on Site sha
- Page 50 and 51: 7. Performance Security7.1. Unless
- Page 52 and 53: 10. Site Investigation ReportsThe C
- Page 54 and 55: Form of Warranty(a) Cash or letter
- Page 56 and 57: evidence and such policies shall be
- Page 58 and 59: 17. Termination for Default of Proc
- Page 60 and 61: 18.6. If this Contract is terminate
- Page 62 and 63: accordance with approved plans and
- Page 64 and 65: agreement, the parties may agree in
- Page 66 and 67: (d)At appropriate new rates, equal
- Page 68 and 69: 33. Bill of Quantitiesthe PROCURING
- Page 70 and 71: 38.2. The use of a third party to c
- Page 72 and 73: 42.2. Progress payments are subject
- Page 74 and 75: justifications for the need of such
- Page 76 and 77: 46. Payment on Termination46.1. If
- Page 78 and 79: 49. CompletionThe Contractor shall
- Page 80 and 81: Special Conditions of ContractGCC C
- Page 82 and 83: 51.2.The amount to be withheld for
- Page 84 and 85: PROJECT TITLE : Asphalt Overlay of
- Page 86 and 87: Section VII. DrawingsSee attached84
- Page 88 and 89: Section IX. Bidding FormsTABLE OF C
- Page 90 and 91: (e) Our firm, including any subcont
- Page 92 and 93: 3. In consideration of the payments
the responsibility to undertake the repair <strong>of</strong> any damage to the Worksat his own expense.1.14. Drawings are graphical presentations <strong>of</strong> the Works. They include allsupplementary details, shop drawings, calculations, and otherinformation provided or approved for the execution <strong>of</strong> this Contract.1.15. Equipment refers to all facilities, supplies, appliances, materials orthings required for the execution and completion <strong>of</strong> the Work providedby the Contractor and which shall not form or are not intended to formpart <strong>of</strong> the Permanent Works.1.16. The Intended Completion Date refers to the date specified in theSCC when the Contractor is expected to have completed the Works.The Intended Completion Date may be revised only by the ProcuringEntity’s Representative by issuing an extension <strong>of</strong> time or anacceleration order.1.17. Materials are all supplies, including consumables, used by theContractor for incorporation in the Works.1.18. The Notice to Proceed is a written notice issued by the ProcuringEntity or the Procuring Entity’s Representative to the Contractorrequiring the latter to begin the commencement <strong>of</strong> the work not laterthan a specified or determinable date.1.19. Permanent Works all permanent structures and all other projectfeatures and facilities required to be constructed and completed inaccordance with this Contract which shall be delivered to the ProcuringEntity and which shall remain at the Site after the removal <strong>of</strong> allTemporary Works.1.20. Plant refers to the machinery, apparatus, and the like intended t<strong>of</strong>orm an integral part <strong>of</strong> the Permanent Works.1.21. The Procuring Entity is the party who employs the Contractor tocarry out the Works stated in the SCC.1.22. The Procuring Entity’s Representative refers to the Head <strong>of</strong> theProcuring Entity or his duly authorized representative, identified in theSCC, who shall be responsible for supervising the execution <strong>of</strong> theWorks and administering this Contract.1.23. The Site is the place provided by the Procuring Entity where the Worksshall be executed and any other place or places which may bedesignated in the SCC, or notified to the Contractor by the ProcuringEntity’s Representative as forming part <strong>of</strong> the Site.43<strong>Clark</strong> Development CorporationSection IV General Conditions <strong>of</strong> the Contract<strong>Asphalt</strong> <strong>Overlay</strong> <strong>of</strong> <strong>CDC</strong> <strong>Roads</strong>