Proposed Renovation of Former Jacinto Building - Clark Freeport Zone

More documents

Recommendations

Info

27.RIGHT TO VARY................................................................................6428.CONTRACTORS RIGHT TO CLAIM ................................................6429.DAYWORKS........................................................................................6430.EARLY WARNING .............................................................................6431.PROGRAM OF WORK .......................................................................6532.MANAGEMENT CONFERENCES......................................................6633.BILL OF QUANTITIES ......................................................................6634.INSTRUCTIONS, INSPECTIONS AND AUDITS ..........................6635.IDENTIFYING DEFECTS ..................................................................6736.COST OF REPAIRS............................................................................6737.CORRECTION OF DEFECTS ............................................................6738.UNCORRECTED DEFECTS ...............................................................6839.ADVANCE PAYMENT ........................................................................6840.PROGRESS PAYMENTS....................................................................6841.PAYMENT CERTIFICATES...............................................................6942.RETENTION........................................................................................7043.VARIATION ORDERS .......................................................................7044.CONTRACT COMPLETION...............................................................7245.SUSPENSION OF WORK..................................................................7346.PAYMENT ON TERMINATION........................................................7447.EXTENSION OF CONTRACT TIME.................................................7448.PRICE ADJUSTMENT........................................................................7649.COMPLETION.....................................................................................7650.TAKING OVER....................................................................................7651.OPERATING AND MAINTENANCE MANUALS ............................7642Clark Development CorporationSection IV General Conditions of the ContractProposed Renovation of Former Jacinto Building (Motorpool, Property & ECMDWarehouse/Maintenance Area )
1. DefinitionsFor purposes of this Clause, boldface type is used to identify defined terms.1.1. The Arbiter is the person appointed jointly by the Procuring Entity andthe Contractor to resolve disputes in the first instance, as provided forin GCC Clause 21.1.2. Bill of Quantities refers to a list of the specific items of the Work andtheir corresponding unit prices, lump sums, and/or provisional sums.1.3. The Completion Date is the date of completion of the Works ascertified by the Procuring Entity’s Representative, in accordance withGCC Clause 49.1.4. The Contract is the contract between the Procuring Entity and theContractor to execute, complete, and maintain the Works.1.5. The Contract Price is the price stated in the Letter of Acceptance andthereafter to be paid by the Procuring Entity to the Contractor for theexecution of the Works in accordance with this Contract.1.6. Contract Time Extension is the allowable period for the Contractorto complete the Works in addition to the original Completion Datestated in this Contract.1.7. The Contractor is the juridical entity whose proposal has beenaccepted by the Procuring Entity and to whom the Contract to executethe Work was awarded.1.8. The Contractor’s Bid is the signed offer or proposal submitted by theContractor to the Procuring Entity in response to the BiddingDocuments.1.9. Days are calendar days; months are calendar months.1.10. Day works are varied work inputs subject to payment on a time basisfor the Contractor’s employees and Equipment, in addition to paymentsfor associated Materials and Plant.1.11. A Defect is any part of the Works not completed in accordance withthe Contract.1.12. The Defects Liability Certificate is the certificate issued byProcuring Entity’s Representative upon correction of defects by theContractor.43Clark Development CorporationSection IV General Conditions of ContractProposed Renovation of Former Jacinto Building(Motorpool, Records, Warehouses and Maintenance Area)
Page 1 and 2: Clark Development CorporationClark
Page 3 and 4: Section I. Invitation to BidClark D
Page 5 and 6: 5. A complete set of Bidding Docume
Page 7 and 8: Section II. Instructions to Bidders
Page 9: A. General1. Scope of Bid1.1. The P
Page 12 and 13: implementation of the project, if t
Page 14 and 15: under ongoing contracts, including
Page 16 and 17: 6.8. Bidders should note that the P
Page 18 and 19: Philippines, in which case the Engl
Page 20 and 21: (i.2)a surety bond accompanied by a
Page 22 and 23: 15. Bid Prices15.1. The contract sh
Page 24 and 25: draft/guarantee, or irrevocable let
Page 26 and 27: 19.3. The Bidder shall prepare an o
Page 28 and 29: administrative, civil, and criminal
Page 30 and 31: 27. Detailed Evaluation and Compari
Page 32 and 33: Calculated Bid to make a similar de
Page 34 and 35: (a)Submission of the following docu
Page 36 and 37: 33. Notice to Proceed33.1. Within t
Page 38 and 39: Bid Data SheetITBClause1.1. The PRO
Page 40 and 41: 14.2. No further instructions.15.4.
Page 42 and 43: Section IV. General Conditions ofCo
Page 46 and 47: 1.13. The Defects Liability Period
Page 48 and 49: 2.2. If sectional completion is spe
Page 50 and 51: particularly when they shall requir
Page 52 and 53: Procuring Entity shall rescind this
Page 54 and 55: and/or intended purpose of the same
Page 56 and 57: 15.2. The Contractor shall provide
Page 58 and 59: 16.5. All materials on the Site, Pl
Page 60 and 61: 18.5. When persons from either part
Page 62 and 63: (i) Employment of competent technic
Page 64 and 65: decision was wrongly taken, the dec
Page 66 and 67: 27. Right to Vary27.1. The Procurin
Page 68 and 69: 32. Management Conferences32.1. Eit
Page 70 and 71: 38. Uncorrected Defects38.1. The Pr
Page 72 and 73: (c)Include the valuations of approv
Page 74 and 75: (a)(b)(c)(d)(e)If the Procuring Ent
Page 76 and 77: unless there are justifiable reason
Page 78 and 79: consideration and the validity of t
Page 80 and 81: GCC ClauseSpecial Conditions of Con
Page 82 and 83: Section VI. Technical Specification
Page 84 and 85: Item 800 (b) Cleaning and Scrubbing
Page 86 and 87: in the approved Plan shall undertak
Page 88 and 89: The concrete materials shall be pro
Page 90 and 91: The quantity of metal structures to
Page 92 and 93: Valves for water supply system shal
Page 94 and 95:
High Pressure Plastic Laminate comp
Page 96 and 97:
ALUMINUM GLASS WINDOWS (Supply and
Page 98 and 99:
Doors shall be operated and with pr
Page 100 and 101:
Mortar mixture shall be freshly pre
Page 102 and 103:
portion(s) shall not start until cl
Page 104 and 105:
All panel board and metallic boxes
Page 106 and 107:
Panel boards shall conform to the s
Page 108 and 109:
Section VII. DrawingsSee attached10
Page 110 and 111:
Section VIII. Bill of Quantities108
Page 112 and 113:
Bid FormDate: ___________________IA
Page 114 and 115:
Form of Contract AgreementTHIS Cont
Page 116 and 117:
A C K N O W L E D G E M E N TREPUBL
Page 118 and 119:
6. [Name of Bidder] is authorizing
Page 120 and 121:
Any one of the Following:o Computat
Page 122 and 123:
Sample Forms of Eligibility, Techni
Page 124 and 125:
Standard Form Number: SF-INFR-16Sta
Page 126 and 127:
Standard Form Number: SF-INFR-20Rev
Page 128 and 129:
we undertake to pay to the Entity u
Page 130 and 131:
2) if the Principal does not accept
Page 132 and 133:
Page 134 and 135:
Page 136 and 137:
Page 138 and 139:
Standard Form Number: SF-INFR-48Qua
Page 140 and 141:
DAYWORK SCHEDULEPROJECT : Proposed
show all

Proposed Renovation of Former Jacinto Building - Clark Freeport Zone

Create successful ePaper yourself

Delete template?

Save as template?