ITB 13-022 Key West Bight Ferry Terminal Boat ... - KeyWestCity.com
ITB 13-022 Key West Bight Ferry Terminal Boat ... - KeyWestCity.com
ITB 13-022 Key West Bight Ferry Terminal Boat ... - KeyWestCity.com
You also want an ePaper? Increase the reach of your titles
YUMPU automatically turns print PDFs into web optimized ePapers that Google loves.
BID DOCUMENTS<br />
FOR<br />
KEY WEST BIGHT FERRY TERMINAL<br />
BOAT LIFTS<br />
CONSISTING OF:<br />
BIDDING REQUIREMENTS<br />
CONTRACT FORMS<br />
CONDITIONS<br />
TECHNICAL SPECIFICATIONS<br />
<strong>ITB</strong> PROJECT #:<strong>13</strong>-<strong>022</strong><br />
PREPARED BY:<br />
THE CITY OF KEY WEST<br />
ENGINEERING SERVICES<br />
KEY WEST, FLORIDA<br />
SEPTEMBER 20<strong>13</strong><br />
1
TABLE OF CONTENTS<br />
PART 1:<br />
BIDDING REQUIREMENTS<br />
Invitation to Bid……………………………………………………….4-5<br />
Instructions to Bidders………………………………………………...6-12<br />
Bid Form………………………………………………………………<strong>13</strong>-18<br />
Florida Bid Bond……………………………………………………...19-20<br />
Public Entities Crime Form…………………………………………...21-22<br />
Anti – Kickback Affidavit……………………………………………23<br />
City of <strong>Key</strong> <strong>West</strong> Indemnification……………………………………24<br />
Local Vendor Certification…………………………………………...25<br />
City Ordinance & Affidavit Sec. 2-799………………………………26-30<br />
City Ordinance & Affidavit Sec. 2-773………………………………31-35<br />
PART 2<br />
CONTRACT FORMS<br />
Contract……………………………………………………………....37-38<br />
PART 3<br />
CONDITIONS<br />
Conditions of Bid……………………………………………………40-42<br />
General Conditions…………………………………………………. 43-74<br />
Supplementary Conditions…………………………………………..75-77<br />
Insurance Exhibits A-J……………………………………………….78-87<br />
Grant Requirements ………………………………………………….88-93<br />
PART 4<br />
PART 5<br />
SCOPE OF WORK<br />
Scope of Work………………………….…………………………….95-96<br />
SITE MAPS<br />
<strong>Boat</strong> Lift Locations & Boarding Platforms…………………………..97-98<br />
2
PART 1<br />
BIDDING REQUIREMENTS<br />
3
INVITATION TO BID<br />
Sealed Bids addressed to the City of <strong>Key</strong> <strong>West</strong> (CITY), for the Invitation to Bid (<strong>ITB</strong>) # <strong>13</strong>-<strong>022</strong>:<br />
KEY WEST BIGHT FERRY TERMINAL BOAT LIFTS will be received at the office The<br />
Clerk of the City of <strong>Key</strong> <strong>West</strong> at 3126 Flagler Ave, <strong>Key</strong> <strong>West</strong>, Florida 33040, until 3:00 p.m.,<br />
local time, on October , 20<strong>13</strong> and then will be publicly opened and read. Any Bids received<br />
after the time and date specified will not be considered.<br />
The project contemplated consists of the supply and installation on the existing seawall of two<br />
(2) elevator boat lifts with boarding platforms including design & permitting, labor and materials<br />
required to perform the work.<br />
Drawings and Specifications may be obtained from Demand Star by Onvia or from the City of<br />
<strong>Key</strong> <strong>West</strong> website (www.keywestcity.<strong>com</strong>). Please contact Demand Star at<br />
www.demandstar.<strong>com</strong> or call 1-800-711-1712.<br />
Each Bid must be submitted on the prescribed forms and ac<strong>com</strong>panied by Bid security. Bid or<br />
Bid security shall be by cash, by certified or cashier's check, by a Bid bond or an irrevocable<br />
letter of credit made payable to the city and provided by a surety <strong>com</strong>pany authorized to do<br />
business as a surety in the state in an amount not less than five percent of the amount of the Bid.<br />
Performance and Payment Bonds will not be required as part of this contract.<br />
One (1) original, one (1) copy, and 2 CD copies or flash drives in PDF format of the Bid are to<br />
be submitted in two sealed envelopes, one within the other, clearly marked on the outside<br />
“<strong>ITB</strong> #<strong>13</strong>-<strong>022</strong>:”KEY WEST BIGHT FERRY TERMINAL BOAT LIFTS”, and addressed to the<br />
City Clerk.<br />
Bidders must hold and furnish documentation of all State of Florida licenses, certifications,<br />
registrations or <strong>com</strong>petency cards required in order to Bid and perform the work specified herein.<br />
The successful Bidder will be required to show that he/she is in <strong>com</strong>pliance with the provisions<br />
of Chapter 66 of the Code of Ordinances of the City of <strong>Key</strong> <strong>West</strong> within 10-days of Notice of<br />
Award. The successful Bidder must demonstrate that he/she holds, as a minimum, the following<br />
licenses and certificates:<br />
A. City of <strong>Key</strong> <strong>West</strong> License as defined in the Code of Ordinances, Chapter 66, enabling the<br />
Contractor to perform the work stated herein.<br />
B. A valid Certificate of Competency issued by the Chief Building Official of the City of<br />
<strong>Key</strong> <strong>West</strong>, which shall be valid throughout the contract time.<br />
C. A valid Business Tax Receipt issued by the City of <strong>Key</strong> <strong>West</strong>.<br />
All Bid bonds, insurance contracts, and certificates of insurance shall be either executed by or<br />
countersigned by a licensed resident agent of the Surety or insurance <strong>com</strong>pany having his/her<br />
place of business in the State of Florida, and in all ways <strong>com</strong>plying with the insurance laws of<br />
4
the State of Florida. Further, the said Surety or insurance <strong>com</strong>pany shall be duly licensed and<br />
qualified to do business in the State of Florida.<br />
Before a Contract will be awarded for the work contemplated herein, the Owner will conduct<br />
such investigation as is necessary to determine the performance record and ability of the apparent<br />
lowest, qualified Bidder to perform the size and type of work specified under this Contract.<br />
Upon request, the Bidder shall submit such information as deemed necessary by the Owner to<br />
evaluate the Bidder's qualifications.<br />
For information concerning the proposed work, or for appointment to visit the site of the<br />
proposed work, contact Janet Muccino, Project Manager (305) 809-3867.<br />
Prior to award by the CITY the successful Bidder must be able to prove that Bidder held State<br />
Licenses prior to submittal of Bid as would be required to perform work herein. Within 10-days<br />
after issuance of the Notice of Award, the successful Bidder must be able to prove that Bidder<br />
holds City Licenses as would be required to perform work herein. Any permit and/or license<br />
requirement and subsequent costs are located within the Bid document. The successful Bidder<br />
must also be able to satisfy the City Attorney as to such insurance coverage, and legal<br />
requirements as may be demanded in Bid. The CITY may reject Bids: (1) for budgetary reasons,<br />
(2) if the Bidder misstates or conceals a material fact in its Bid, (3) if the Bidder does not strictly<br />
conform to the law or is non-responsive to Bid requirements, (4) if the Bid is conditional, (5) if a<br />
change of circumstances occurs making the purpose of the Bid unnecessary or (6) if such<br />
rejection is in the best interest of the CITY. The CITY may also waive any minor informalities or<br />
irregularities in any Bid.<br />
This project is funded by the federal government through a grant from the Department of<br />
Homeland Security.<br />
5
1. CONTRACT DOCUMENTS<br />
FORMAT<br />
INSTRUCTIONS TO BIDDERS<br />
The Contract Documents are divided into parts, divisions, and sections for convenient<br />
organization and reference. Generally, there has been no attempt to divide the<br />
Specification sections into work performed by the various building trades, work by<br />
separate subcontractors, or work required for separate facilities in the project.<br />
The intent of the Documents is to describe a functionally <strong>com</strong>plete project (or part thereof)<br />
to be constructed in accordance with the Contract Documents. Any work, materials, or<br />
equipment that may reasonably be inferred from the Contract Documents, as being required<br />
to produce the intended result shall be supplied whether or not specifically called for.<br />
DOCUMENT INTERPRETATION<br />
The separate sections contained within these Contract Documents are intended to be<br />
mutually cooperative and to provide all details reasonably required for the execution of<br />
the proposed work.<br />
Should there be any doubt as to the meaning or intent of said Contract Documents, the<br />
Bidder should request of the Project Manager, in writing, at least ten (10) calendar days<br />
prior to the Bid opening, an interpretation thereof. Any interpretation or change in said<br />
Contact Documents will be made only in writing, in the form of addenda to the<br />
Documents which will be furnished through Demand Star to all registered holders of the<br />
Contract Documents. Bidders shall submit with their Bids, or indicate receipt of, all<br />
Addenda. The Owner will not be responsible for any other explanation or interpretations<br />
of said Documents.<br />
2. DESCRIPTION OF THE PROJECT<br />
The work to be <strong>com</strong>pleted for this project can be found in Part 4. The Bidder will be<br />
required to <strong>com</strong>plete all work as specified.<br />
3. QUALIFICATION OF CONTRACTORS<br />
Bidders must hold all licenses, certifications, registrations or <strong>com</strong>petency cards required<br />
by Florida Statute and local ordinances in order to perform the work specified herein.<br />
4. BIDDER'S UNDERSTANDING<br />
Each Bidder must inform him/herself of the conditions relating to the execution of the<br />
work, and it is required that he/she will inspect the site(s) and make himself/herself<br />
thoroughly familiar with the Bid Documents. Failure to do so will not relieve the<br />
6
successful Bidder of his/her obligation to enter into a Contract and <strong>com</strong>plete the<br />
contemplated work in strict accordance with the Bid Documents. It shall be the Bidder’s<br />
obligation to verify for himself and to his <strong>com</strong>plete satisfaction all information<br />
concerning site and construction or worksite conditions.<br />
The Owner will make available to prospective Bidders upon request and at the office of<br />
the Project Manager, prior to Bid opening, any information that he/she may have as to<br />
conditions at the worksites.<br />
Investigations conducted by the Project Manager of any locations were made for the<br />
purpose of study and design, and the Project Manager assumes no responsibility whatever<br />
in respect to the sufficiency or accuracy of data or other investigations that have been<br />
made, or of the interpretations made thereof, and there is no warranty or guaranty, either<br />
express or implied, that the conditions indicated by such investigations are representative<br />
of those existing throughout such area, or any part thereof, or that unforeseen<br />
developments may not occur.<br />
Copies of any existing documents regarding the work sites can be viewed at Engineering<br />
Services, City Hall 3140 Flagler Avenue and any that are made available shall not be<br />
considered a part of the Contract Documents, said documents are made available only for<br />
the convenience of the Bidders.<br />
Information derived from Drawings showing location of utilities and structures will not in<br />
any way relieve the contractor from any risk, or from properly examining the site and<br />
making such additional investigations as he/she may elect, or from properly fulfilling all<br />
the terms of the Contract Documents.<br />
Each Bidder shall inform him/herself of, and the Bidder awarded a Contract shall <strong>com</strong>ply<br />
with, federal, state, and local laws, statutes, and ordinances relative to the execution of<br />
the work. This requirement includes, but is not limited to, applicable regulations<br />
concerning minimum wage rates, nondiscrimination in the employment of labor,<br />
protection of public and employee safety and health, environmental protection, the<br />
protection of natural resources, fire protection, burning and non-burning requirements,<br />
permits, fees, and similar subjects. Performance and Payment Bonds are not required as<br />
part of this contract.<br />
5. TYPE OF BID<br />
A. LUMP SUM<br />
The Bid for the work is to be submitted on a LUMP SUM basis. LUMP SUM prices<br />
shall be broken down on a unit price basis for each part of the project in the Bid and a<br />
Schedule of Values shall be included with the Bid. The total amount to be paid the<br />
Contractor shall be the amount of the Lump Sum Bid as adjusted for additions or<br />
deletions in number of units and/or resulting from Owner authorized changes in the<br />
project or by actual number of units used in construction. The owner reserves the right to<br />
7
enter into a contract for all or portions of the project and to adjust the final Lump Sum<br />
accordingly.<br />
B. PREPARATION OF BIDS<br />
GENERAL<br />
All blank spaces in the Bid form must be filled in, as required, in BLACK INK or<br />
TYPED. All price information will be shown in both words and figures where required.<br />
No changes shall be made in the phraseology of the forms. Written amounts shall govern<br />
in case of discrepancy between amounts stated in writing and the amounts stated in<br />
figures.<br />
Any Bid shall be deemed informal, which contains omissions, erasures, alterations, or<br />
additions of any kind, or prices uncalled for, or in which any of the prices are obviously<br />
unbalanced, or which in any manner shall fail to conform to the conditions of the<br />
published <strong>ITB</strong>.<br />
Bidders shall not submit unbalanced Bids as requested in the breakdown of Bids.<br />
Only one (1) Bid from any individual, firm, partnership, or corporation under the same or<br />
different names, will be considered. Should it appear to the Owner that any Bidder is<br />
interested in more than one (1) Bid for work contemplated, all Bids in which such Bidder<br />
is interested will be rejected.<br />
SIGNATURE<br />
The Bidder shall sign his/her Bid in the blank space provided therefore. If Bidder is a<br />
corporation, the legal name of the corporation shall be set forth above, together with the<br />
signature of the officer or officers authorized to sign Contracts on behalf of the<br />
corporation. If the Bidder is a partnership, the true name of the firm shall be set forth<br />
above, together with the signature of the partner or partners authorized to sign Contracts<br />
on behalf of the partnership. If signature is by an agent, other than an officer of a<br />
corporation or a member of a partnership, a notarized power of attorney must be on file<br />
with the Owner prior to opening of Bids or submitted with the Bid, otherwise the Bid will<br />
be regarded as not properly authorized.<br />
SPECIAL BIDDING REQUIREMENTS<br />
The Bidder's attention is brought to the hiring practices and licenses and permits of the<br />
City of <strong>Key</strong> <strong>West</strong>. These are defined in the addition to Article 39, CODES,<br />
ORDINANCES, PERMITS, and LICENSES.<br />
8
ATTACHMENTS<br />
Bidder shall <strong>com</strong>plete and submit the following forms with Bid or as otherwise identified<br />
in the Bid document:<br />
• Bid Form including detail schedule of values,<br />
• Sworn statement under section 287.<strong>13</strong>3(3)(a) Florida Statutes, on public entity<br />
crimes,<br />
• Anti-Kickback Affidavit<br />
• City of <strong>Key</strong> <strong>West</strong> Indemnification Form<br />
• Local Vendor Certification<br />
• Equal Benefits for Domestic Partner Affidavit<br />
• At least three (3) years of current or recent projects of similar work shall be<br />
provided (dates of works and contacts shall be included),<br />
• A description of any previous or existing legal action against the Bidder within<br />
the past three (3) years. If none, Bidder shall state this fact in writing.<br />
• All Bidders shall include with their Bid package their <strong>com</strong>plete Bid on a CD or<br />
flash drive in one (1) PDF format file (two CDs or flash drives are required with<br />
the Bid)<br />
Note: if any of the items above or as required in other parts of the document are not<br />
included in the Bid, the Bid will be considered nonresponsive and therefore will be rejected<br />
unless City Commission directs otherwise.<br />
7. STATE AND LOCAL SALES AND USE TAX<br />
The Owner is exempt from state sales tax on materials incorporated into the work due to<br />
the qualification of the work under this Contract, the Contractor, as required by the laws<br />
and statutes of the state and its political subdivisions shall pay all state and local sales and<br />
use taxes unless stated differently in these documents. Prices quoted in the Bid shall<br />
include all nonexempt sales and use taxes, unless provision is made in the Bid form to<br />
separately itemize the tax.<br />
8. SUBMISSION OF BIDS<br />
All Bids must be submitted not later than the time prescribed, at the place, and in the<br />
manner set forth in the <strong>ITB</strong>. Bids must be made on the Bid forms provided herewith.<br />
Each Bid must be submitted in two sealed envelopes, one within the other, so marked as<br />
to indicate the Bidder's name and its contents without being opened, and addressed in<br />
conformance with the instructions in the <strong>ITB</strong>. One original, one copy, and 2 CD copies or<br />
flash drives are required.<br />
9
9. MODIFICATIONS OR WITHDRAWAL OF BIDS<br />
Prior to the time and date designated for receipt of Bids, any Bid submitted may be<br />
modified or withdrawn by notice to the party receiving Bids at the place designated for<br />
the receipt of Bids. Such notice shall be in writing over the signature of the Bidder or by<br />
telephone, fax, or email. If by telephone, fax, or email, written confirmation over the<br />
signature of the Bidder shall be mailed and postmarked on or before the date and time set<br />
for receipt of Bids, and it shall be so worded as not to reveal the amount of the original<br />
Bid. No Bid may be withdrawn after the time scheduled for the opening of Bids, unless<br />
the time specified in paragraph 12, AWARD OF CONTRACT, in these Instructions to<br />
Bidders shall have elapsed.<br />
10. BID SECURITY<br />
The Attorney-in-Fact who executes this bond in behalf of the Surety must attach a<br />
notarized copy of his/her power-of-attorney as evidence of his/her authority to bind the<br />
certification by a resident agent shall also be provided.<br />
Bid or BID security shall be by cash, by certified or cashier's check, by a Bid bond or an<br />
irrevocable letter of credit made payable to the city and provided by a surety <strong>com</strong>pany<br />
authorized to do business as a surety in the state.<br />
11. RETURN OF BID SECURITY<br />
Within fifteen (15) days after the award of the Contract or at the discretion of the Project<br />
Manager, the Owner will return the Bid securities to all Bidders whose Bids are not to be<br />
further considered in awarding the Contract. Retained Bid securities will be held until<br />
the Contract has been finally executed, after which all Bid securities, other than Bidder's<br />
Bonds and any guarantees which have been forfeited, will be returned to the respective<br />
Bidders whose Bids they ac<strong>com</strong>panied.<br />
12. AWARD OF CONTRACT<br />
Within ninety (90) calendar days after the opening of the Bids, the Owner will accept one<br />
of the Bids or will act in accordance with the following Section <strong>13</strong> of the Part 3:<br />
Conditions of Bid. The acceptance of the Bid will be by written notice of award, mailed<br />
to the office designated in the Bid, or delivered to the Bidder's representative. In the<br />
event of failure of the lowest, responsive, qualified Bidder to sign the Contract and<br />
provide acceptable insurance certificate(s), the Owner may award the Contract to the next<br />
lowest, responsive, qualified Bidder. Such award, if made, will be made within ninety<br />
(90) days after the opening of the Bids.<br />
Bid Award will be the date of the Notice of Award letter. Any permit and/or license<br />
requirement and subsequent costs are located within the documents. The successful<br />
Bidder must also be able to satisfy the City Attorney as to such insurance coverage and<br />
legal requirements as may be demanded by the Bid in question. The Owner reserves the<br />
10
ight to reject any and/or all Bids because of irregularities or due to budgetary<br />
considerations, to waive irregularities or informalities in any or all Bids, and to accept<br />
any Bid that the CITY OF KEY WEST deems to be in the best interest of the Owner.<br />
<strong>13</strong>. BASIS OF AWARD<br />
The Owner on the basis of that Bid will make the award on base bid or a <strong>com</strong>bination of<br />
base bid and alternate bids from the lowest, responsive, qualified Bidder that in the<br />
Owner's sole and absolute judgment will serve the best interests of the Owner.<br />
If at the time this Contract is to be awarded, the total of the lowest acceptable Bid<br />
exceeds the funds then estimated by the Owner as available, the Owner may reject all<br />
Bids or take such other action as best serves the Owner's interest.<br />
14. EXECUTION OF CONTRACT<br />
The successful Bidder shall, within ten (10) working days after receiving notice of award,<br />
sign and deliver to the Owner the Contract together with the acceptable insurance<br />
certificates as required in these Documents. Within ten (10) working days after receiving<br />
the signed Contract, with acceptable insurance from the successful Bidder, the Owner's<br />
authorized agent will sign the Contract. Signature by both parties constitutes execution<br />
of the Contract.<br />
15. FAILURE TO EXECUTE CONTRACT AND FURNISH BONDS<br />
The Bidder who has a contract awarded to him/her and who fails to promptly and<br />
properly execute the contact shall forfeit the Bid security that ac<strong>com</strong>panied his Bid, and<br />
the Bid security shall be retained as liquidated damages by the Owner, and it is agreed<br />
that said sum is a fair estimate of the amount of the damages the Owner will sustain in<br />
case the Bidder fails to enter into a Contract or furnish the required bonds. Bid security<br />
deposited in the form of cash, a certified check, or cashier's check shall be subject to the<br />
same requirements as a Bid Bond. Performance and Payment Bonds will not be required<br />
as part of this contract.<br />
16. PERFORMANCE OF WORK BY CONTRACTOR<br />
The Contractor shall perform on site and with his/her own organization, labor equivalent<br />
to at least forty (40) percent of the total amount of the work to be performed under this<br />
Contract. If, during the progress of the work hereunder, the Contractor requests a<br />
reduction of such percentage, and the Project Manager determines that it would be to the<br />
client's advantage, the percentage of labor to be performed by the Contractor's own<br />
organization may be reduced; provided prior written approval of such reduction is<br />
obtained by the Contractor from the Project Manager.<br />
11
17. TIME OF COMPLETION<br />
The Bidder further agrees to begin work within twenty (20) calendar days after the date<br />
of the Notice to Proceed and to <strong>com</strong>plete the construction of all items in the lump sum<br />
base Bid, in all respects, for this particular project, within ninety (60) calendar days after<br />
receipt of all permits. Contractor is responsible to apply for all permits in a timely manner<br />
and keep project manager informed of progress.<br />
18. PAYMENT TERMS<br />
The Contractor will bill the City on a monthly basis. Terms of payment will be a<br />
maximum of 45 days from receipt of invoice. The Contractor may bill the City on a more<br />
frequent basis if agreed upon by the Project Manager. The Contractor may also bill the<br />
City for materials on site once proof of delivery and storage is provided.<br />
19. LICENSES, PERMITS, AND FEES<br />
The Contractor is responsible for identifying, obtaining and paying for all licenses and<br />
permits from Federal, State, and Local agencies required to perform the work as stated in<br />
Bid document. The Contractor shall verify the list with the appropriate City of <strong>Key</strong> <strong>West</strong><br />
Departments. The timely submittal of all permits applications is the responsibility of the<br />
contractor.<br />
Pursuant to the Public Bid Disclosure Act, each license, permit, or fee a Contractor will<br />
have to pay the City of <strong>Key</strong> <strong>West</strong> before or during construction or the percentage method<br />
or unit method of all licenses, permits, and fees REQUIRED BY THE CITY OF KEY<br />
WEST and payable to the City by virtue of this construction as part of the Contract is as<br />
follows:<br />
• <strong>Key</strong> <strong>West</strong>, Business Tax Receipt<br />
• General Contractors License<br />
LICENSES, PERMITS, AND FEES THAT MAY BE REQUIRED BY THE STATE<br />
OF FLORIDA, STATE AGENCIES, OR BY OTHER LOCAL GOVERNMENTAL<br />
ENTITIES ARE NOT INCLUDED IN THE ABOVE LIST.<br />
12
Notice to Bidder: Use Black Ink or Type For Completing the Form.<br />
BID<br />
To:<br />
The City of <strong>Key</strong> <strong>West</strong><br />
Address: 3126 Flagler Ave, <strong>Key</strong> <strong>West</strong>, Florida 33040<br />
Project Title:<br />
KEY WEST BIGHT FERRY TERMINAL BOAT LIFTS<br />
Project: <strong>ITB</strong> #<strong>13</strong>-<strong>022</strong><br />
BIDDER’S INFORMATION<br />
Name:<br />
Address:<br />
___________________________________________<br />
___________________________________________<br />
___________________________________________<br />
___________________________________________<br />
Contact Name: ___________________________________________<br />
Email:<br />
Telephone:<br />
Fax:<br />
___________________________________________<br />
___________________________________________<br />
___________________________________________<br />
Signature: ________________________________________________ Date: ______________<br />
BIDDER'S DECLARATION AND UNDERSTANDING<br />
The undersigned, hereinafter called the Bidder, declares that the only persons or parties<br />
interested in this Bid are those named herein, that this Bid is, in all respects, fair and without<br />
fraud, that it is made without collusion with any official of the Owner, and that the Bid is made<br />
without any connection or collusion with any person submitting another Bid on this Contract.<br />
The Bidder further declares that he/she has carefully examined the Contract Documents for the<br />
construction of the project, that he/she has personally inspected the site, that he/she has satisfied<br />
himself/herself as to the quantities involved, including materials and equipment, and conditions<br />
of work involved, including the fact that the description of the quantities of work and materials,<br />
as included herein, is brief and is intended only to indicate the general nature of the work and to<br />
identify the said quantities with the detailed requirements of the Contract Documents, and that<br />
<strong>13</strong>
this Bid is made according to the provisions and under the terms of the Contract Documents,<br />
which Documents are hereby made a part of this Bid.<br />
The Bidder further agrees that he/she has exercised his/her own judgment regarding the<br />
interpretation of job conditions and has utilized all data, which he/she believes pertinent from the<br />
Project Manager, Owner, and other sources in arriving at his/her conclusions.<br />
The intent of the Bid Documents is to describe a functionally <strong>com</strong>plete project (or part thereof) to<br />
be constructed in accordance with the Contract Documents. Any work, materials, or equipment<br />
that may reasonably be inferred from the Contract Documents, as being required to produce the<br />
intended result shall be supplied whether or not specifically called for.<br />
CONTRACT EXECUTION AND BONDS<br />
The Bidder agrees that if this BID is accepted, he/she will, within ten (10) calendar days after<br />
Notice of Award, sign the Contract in the form annexed hereto, will attach all required licenses<br />
and certificates, and will, to the extent of his BID, furnish all equipment, materials, and labor<br />
necessary to <strong>com</strong>plete all work as specified or indicated in the Contract Documents. Performance<br />
and Payment Bonds will not be required as part of this contract.<br />
CERTIFICATES OF INSURANCE<br />
Bidder agrees to furnish the Owner, before <strong>com</strong>mencing the work under this Contract, the<br />
certificates of insurance as specified in these Documents.<br />
START OF CONSTRUCTION AND CONTRACT COMPLETION TIME<br />
The Bidder further agrees to begin work within twenty (20) calendar days after the date of the<br />
Notice to Proceed and to <strong>com</strong>plete the construction of all items in the lump sum base Bid, in all<br />
respects, for this particular project, within sixty (60) calendar days after all permits are received .<br />
LIQUIDATED DAMAGES<br />
In the event the Bidder is awarded the Contract and shall fail to <strong>com</strong>plete the work within the<br />
time limit or extended time limit agreed upon as more particularly set forth in the Contract<br />
Documents, liquidated damages shall be paid to the Owner at the rate of five hundred dollars<br />
($500.00) per day for all work awarded under this contract until the work has been satisfactorily<br />
<strong>com</strong>pleted as provided by the Contract Documents. Sundays and legal holidays shall be included<br />
in determining days in default.<br />
ADDENDA<br />
The Bidder hereby acknowledges that he has received Addenda No's. , , , ,<br />
, (Bidder shall insert No. of each Addendum received) and agrees that all addenda issued<br />
are hereby made part of the Contract Documents, and the Bidder further agrees that his Bid(s)<br />
includes all impacts resulting from said addenda.<br />
14
SALES AND USE TAXES<br />
The Bidder agrees that all federal, state, and local sales and use taxes are included in the stated<br />
Bid prices for the work.<br />
PUBLIC ENTITY CRIMES<br />
“A person or affiliate who has been placed on the convicted vendor list following a conviction<br />
for a public entity crime may not submit a Bid on a contract to provide any goods or services to a<br />
public entity, may not submit a Bid on a contract with a public entity for the construction or<br />
repair of a public building or public work, may not submit Bids on leases of real property to a<br />
public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or<br />
Contractor under a contract with any public entity and may not transact business with any public<br />
entity in excess of the threshold amount provided in Section 287.017, for CATEGORY TWO for<br />
a period of 36 months from the date of being placed on the convicted vendor list.”<br />
LUMP SUM BASE BID<br />
The Bidder agrees to accept as full payment for performance of the work as herein specified and<br />
shown on the Drawings (if any), the following lump sum. The Bidder agrees that the lump sum<br />
price represents a true measure of the design, labor, materials, and equipment required to<br />
perform the work, including all allowances for overhead and profit for each type and unit of<br />
work called for in these Contract Documents. The amounts shall be shown in both words and<br />
figures. In case of a discrepancy, the amount shown in words shall govern. Final lump sum<br />
payments will be adjusted based on actual units and unit prices.<br />
15
BID FORM<br />
<strong>ITB</strong> #<strong>13</strong>-<strong>022</strong>: KEY WEST BIGHT FERRY TERMINAL BOAT LIFTS<br />
LUMP SUM BASE BID PRICE* for supply & installation of 2 boat lifts each with a<br />
<strong>com</strong>posite boarding platform<br />
$_____________________________________<br />
Bid Total in Words<br />
BID BREAKDOWN*<br />
The Bidder shall provide a schedule of values for all aspects of the project including<br />
mobilization/demobilization, labor and materials, permitting, etc. required or to be used for the<br />
project. The schedule of values shall be in sufficient detail to allow the owner to understand how<br />
the Bidder arrived at said Base Bid and Alternate Bid prices and shall be<strong>com</strong>e part of the<br />
contract for basis of payment. The City may ask for a more detailed schedule of values if one<br />
submitted is not sufficient.<br />
*FINAL PAYMENT WILL BE BASED ON ACTUAL QUANTITIES MEASURED IN<br />
THE FIELD AND APPROVED BY CITY STAFF<br />
16
SUBCONTRACTORS<br />
The Bidder further proposes that the following subcontracting firms or businesses will be<br />
awarded subcontracts for the following portions of the work in the event that the Bidder is<br />
awarded the Contract:<br />
Portion of Work:<br />
Name:<br />
Address:<br />
Portion of Work:<br />
Name:<br />
Address:<br />
Portion of Work:<br />
Name:<br />
Address:<br />
BIDDER<br />
The name of the Bidder submitting this Bid is: __________________________________<br />
Doing business at _____________________________________________________________<br />
City ___________________________________State ______________Zip________________<br />
Telephone No._____________________________________<br />
This address is where all <strong>com</strong>munications concerning this Bid shall be sent.<br />
The names of the principal officers of the Corporation submitting this Bid, or of the Partnership,<br />
or of all persons interested in this Bid as Principals are as follows:<br />
Name<br />
Title<br />
______________________________________________________________________________<br />
______________________________________________________________________________<br />
______________________________________________________________________________<br />
17
If Corporation<br />
IN WITNESS WHEREOF the undersigned corporation has caused this instrument to be executed<br />
and its seal affixed by its duly authorized officers this _______day of ________________, 20<strong>13</strong>.<br />
(SEAL)<br />
Name of Corporation<br />
By: ___________________________________________________<br />
Title: _________________________________________________<br />
Attest: _________________________________________________<br />
Secretary<br />
If Sole Proprietor or Partnership<br />
IN WITNESS hereto the undersigned has set his/her/its hand this ______day of _____________,<br />
20<strong>13</strong>.<br />
Signature of Bidder _____________________________________<br />
Title_____________________________________<br />
18
FLORIDA BID BOND<br />
BOND NO.________________________<br />
AMOUNT $_______________________<br />
KNOW ALL MEN BY THESE PRESENTS, that<br />
____________________________________________________________, hereinafter called the<br />
PRINCIPAL, and ____________________________________________, a corporation duly<br />
organized under the laws of the State of ______________having its principal place of business at<br />
_____________________________________________in the State of _________________ and<br />
authorized to do business in the State of Florida, as SURETY, are held firmly bound unto<br />
hereinafter called the Obligee, in the sum of __________________________________________<br />
DOLLARS ($_______________________) for the payment for which we bind ourselves, our<br />
heirs, executors, administrators, successors, and assigns, jointly and severally, firmly by these<br />
presents..<br />
THE CONDITION OF THIS BOND IS SUCH THAT:<br />
WHEREAS, the PRINCIPAL is herewith submitting his or its Bid or Bid for:<br />
KEY WEST BIGHT FERRY TERMINAL BOAT LIFTS, said Bid, by reference thereto, being<br />
hereby made a part hereof.<br />
WHEREAS, the PRINCIPAL contemplates submitting or has submitted a Bid to the OBLIGEE<br />
for the furnishing of labor, materials, (except those specifically furnished by the Owner),<br />
equipment, machinery, tools, apparatus, means of transportation for, and the performance of the<br />
work covered in the Bid and the detailed Specifications entitled:<br />
KEY WEST BIGHT FERRY TERMINAL BOAT LIFTS<br />
WHEREAS, it was a condition precedent to the submission of said Bid that a cashier's check,<br />
certified check, or Bid bond in the amount of five (5) percent of the base Bid be submitted with<br />
said Bid as a guarantee that the Bidder would, if awarded the Contract, enter into a written<br />
Contract with the Owner for the performance of said Contract, within five (5) working days after<br />
written notice having been given of the award of the Contract.<br />
NOW, THEREFORE, the conditions of this obligation are such that if the PRINCIPAL within<br />
five (5) working days after written notice of such acceptance, enters into a written Contract with<br />
the OBLIGEE then this obligation shall be void: otherwise the sum herein stated shall be due and<br />
payable to the OBLIGEE and the Surety herein agrees to pay said sum immediately upon<br />
19
demand of the OBLIGEE in good and lawful money of the United States of America, as<br />
liquidated damages for failure thereof of said principal.<br />
Signed and sealed this day of, _________________ 20<strong>13</strong>.<br />
_______________________________________<br />
PRINCIPAL<br />
____________________________________<br />
By<br />
______________________________________<br />
SURETY<br />
___________________________________<br />
Attorney-In-Fact<br />
20
SWORN STATEMENT UNDER SECTION 287.<strong>13</strong>3(3)(a)<br />
FLORIDA STATUTES, ON PUBLIC ENTITY CRIMES<br />
PROJECT <strong>ITB</strong> #<strong>13</strong>-021: MARINE SANITATION SEWER SYSTEM- WAHOO AND KINGFISH PIERS<br />
THIS FORM MUST BE SIGNED IN THE PRESENCE OF A NOTARY PUBLIC OR OTHER OFFICE<br />
AUTHORIZED TO ADMINISTER OATHS.<br />
1. This sworn statement is submitted with Bid, Bid or Contract No. ____________________________ for<br />
__________________________________________________________________________________<br />
2. This sworn statement is submitted by ______________________________________________________<br />
(Name of entity submitting sworn statement)<br />
whose business address is _______________________________________________________________<br />
_____________________________________________________________and (if applicable) its Federal<br />
Employer Identification Number (FEIN) is _____________________________(If the entity has no FEIN,<br />
include the Social Security Number of the individual signing this sworn statement.)<br />
3. My name is and my relationship to<br />
(Please print name of individual signing)<br />
the entity named above is .<br />
4. I understand that a "public entity crime" as defined in Paragraph 287.<strong>13</strong>3(1)(g), Florida Statutes, means a<br />
violation of any state or federal law by a person with respect to and directly related to the transaction of<br />
business with any public entity or with an agency or political subdivision of any other state or with the<br />
United States, including but not limited to, any Bid or contract for goods or services to be provided to any<br />
public entity or an agency or political subdivision of any other state or of the United States and involving<br />
antitrust, fraud, theft, bribery, collusion, racketeering, conspiracy, material misrepresentation.<br />
5. I understand that "convicted" or "conviction" as defined in Paragraph 287.<strong>13</strong>3(l)(b), Florida Statutes, means<br />
a finding of guilt or a conviction of a public entity crime, with or without an adjudication guilt, in any<br />
federal or state trial court of record relating to charges brought by indictment information after July 1,<br />
1989, as a result of a jury verdict, nonjury trial, or entry of a plea of guilty or nolo contendere.<br />
6. I understand that an "affiliate" as defined in Paragraph 287.<strong>13</strong>3(1)(a), Florida Statutes, means<br />
1. A predecessor or successor of a person convicted of a public entity crime: or<br />
2. An entity under the control of any natural person who is active in the management of t entity and<br />
who has been convicted of a public entity crime. The term "affiliate" includes those officers,<br />
directors, executives, partners, shareholders, employees, members, and agents who are active in<br />
the management of an affiliate. The ownership by one person of shares constituting controlling<br />
interest in another person, or a pooling of equipment or in<strong>com</strong>e among persons when not for fair<br />
market value under an arm's length agreement, shall be a prima facie case that one person controls<br />
another person. A person who knowingly enters into a joint venture with a person who has been<br />
convicted of a public entity crime in Florida during the preceding 36 months shall be considered<br />
an affiliate.<br />
7. I understand that a "person" as defined in Paragraph 287.<strong>13</strong>3(1)(8), Florida Statutes, means any natural<br />
21
person or entity organized under the laws of any state or of the United States with the legal power to enter<br />
into a binding contract and which Bids or applies to Bid on contracts for the provision of goods or services<br />
let by a public entity, or which otherwise transacts or applies to transact business with a public entity. The<br />
term "person" includes those officers, directors, executives, partners, shareholders, employees, members,<br />
and agents who are active in management of an entity.<br />
8. Based on information and belief, the statement, which I have marked below, is true in relation to the entity<br />
submitting this sworn statement. (Please indicate which statement applies.)<br />
Neither the entity submitting this sworn statement, nor any officers, directors, executives, partners,<br />
shareholders, employees, members, or agents who are active in management of the entity, nor any<br />
affiliate of the entity have been charged with and convicted of a public entity crime subsequent to July<br />
1, 1989.<br />
The entity submitting this sworn statement, or one or more of the officers, directors, executives,<br />
partners, shareholders, employees, members, or agents who are active in management of the entity, or<br />
an affiliate of the entity has been charged with and convicted of a public entity crime subsequent to<br />
July 1, 1989, AND (Please indicate which additional statement applies.)<br />
There has been a proceeding concerning the conviction before a hearing of the State of Florida,<br />
Division of Administrative Hearings. The final order entered by the hearing officer did not<br />
place the person or affiliate on the convicted vendor list. (Please attach a copy of the final<br />
order.)<br />
The person or affiliate was placed on the convicted vendor list. Them has been a subsequent<br />
proceeding before a hearing officer of the State of Florida, Division of Administrative<br />
Hearings. The final order entered by the hearing officer determined that it was in the public<br />
interest to remove the person or affiliate from the convicted vendor list. (Please attach a copy<br />
of the final order.)<br />
The person or affiliate has not been put on the convicted vendor list. (Please describe any<br />
action taken by or pending with the Department of General Services.)<br />
(Signature)<br />
(Date)<br />
STATE OF<br />
COUNTY OF<br />
PERSONALLY APPEARED BEFORE ME, the undersigned authority,<br />
___________________________________ who, after first being sworn by me, affixed his/her signature in the<br />
(Name of individual signing)<br />
space provided above on this day of ________________________, 20<strong>13</strong>.<br />
My <strong>com</strong>mission expires:<br />
____________________________________________<br />
NOTARY PUBLIC<br />
22
ANTI-KICKBACK AFFIDAVIT<br />
PROJECT <strong>ITB</strong> #<strong>13</strong>-<strong>022</strong>: KEY WEST FERRY TERMINAL BOAT LIFTS<br />
STATE OF ___________________ )<br />
: SS<br />
COUNTY OF _________________ )<br />
I, the undersigned hereby duly sworn, depose and say that no portion of the sum herein Bid will<br />
be paid to any employees of the City of <strong>Key</strong> <strong>West</strong> as a <strong>com</strong>mission, kickback, reward or gift,<br />
directly or indirectly by me or any member of my firm or by an officer of the corporation.<br />
By: __________________________<br />
Sworn and subscribed before me this<br />
day of ________________, 20<strong>13</strong>.<br />
___________________________________________<br />
NOTARY PUBLIC, State of _______________at Large<br />
My Commission Expires: ______________________<br />
23
CITY OF KEY WEST INDEMNIFICATION FORM<br />
To the fullest extent permitted by law, the Contractor expressly agrees to indemnify and hold<br />
harmless the City of <strong>Key</strong> <strong>West</strong>, their officers, directors, agents, and employees (herein called the<br />
“indemnities”) from liabilities, damages, losses and costs, including, but not limited to,<br />
reasonable attorney’s fees and court costs, such legal expenses to include costs incurred in<br />
establishing the indemnification and other rights agreed to in this Paragraph, to persons or<br />
property, to the extent caused by the negligence, recklessness, or intentional wrongful<br />
misconduct of the Contractor its Subcontractors or persons employed or utilized by them in the<br />
performance of the Contract. Claims by indemnities for indemnification shall be limited to the<br />
amount of Contractor’s insurance or $1 million per occurrence, whichever is greater. The parties<br />
acknowledge that the amount of the indemnity required hereunder bears a reasonable <strong>com</strong>mercial<br />
relationship to the Contract and it is part of the project specifications or the bid documents, if<br />
any.<br />
The indemnification obligations under the Contract shall not be restricted in any way by any<br />
limitation on the amount or type of damages, <strong>com</strong>pensation, or benefits payable by or for the<br />
Contractor under workers’ <strong>com</strong>pensation acts, disability benefits acts, or other employee benefits<br />
acts, and shall extend to and include any actions brought by or in the name of any employee of<br />
the Contractor or of any third party to whom Contractor may subcontract a part or all of the<br />
Work. This indemnification shall continue beyond the date of <strong>com</strong>pletion of the work.<br />
CONTRACTOR:________________________________________<br />
SEAL:<br />
________________________________________<br />
Address<br />
________________________________________<br />
Signature<br />
________________________________________<br />
Print Name<br />
________________________________________<br />
Title<br />
Date<br />
24
LOCAL VENDOR CERTIFICATION PURSUANT TO CKW ORDINANCE 09-22<br />
SECTION 2-798<br />
The undersigned, as a duly authorized representative of the vendor listed herein, certifies to the best of<br />
his/her knowledge and belief, that the vendor meets the definition of a “Local Business.” For purposes of<br />
this section, “local business” shall mean a business which:<br />
a. Principle address as registered with the FL Department of State located within 30 miles of the<br />
boundaries of the city, listed with the chief licensing official as having a business tax receipt with<br />
its principle address within 30 miles of the boundaries of the city for at least one year<br />
immediately prior to the issuance of the solicitation.<br />
b. Maintains a workforce of at least 50 percent of its employees from the city or within 30 miles of<br />
its boundaries.<br />
c. Having paid all current license taxes and any other fees due the city at least 24 hours prior to the<br />
publication of the call for bids or request for proposals.<br />
• Not a local vendor pursuant to Ordinance 09-22 Section 2-798<br />
• Qualifies as a local vendor pursuant to Ordinance 09-22 Section 2-798<br />
If you qualify, please <strong>com</strong>plete the following in support of the self-certification & submit copies of your<br />
County and City business licenses. Failure to provide the information requested will result in denial of<br />
certification as a local business.<br />
Business Name<br />
Current Local Address:<br />
(P.O Box numbers may not be used to establish status)<br />
Phone:<br />
Fax:<br />
Length of time at this address<br />
____________________________________________<br />
Signature of Authorized Representative<br />
_____________________<br />
Date<br />
STATE OF_________________<br />
COUNTY OF_______________<br />
The foregoing instrument was acknowledged before me this _________day of ________, 20<strong>13</strong>.<br />
By_____________________________________________, of____________________________<br />
(Name of officer or agent, title of officer or agent) Name of corporation acknowledging)<br />
or has produced____________________________________________as identification<br />
(type of identification)<br />
________________________________<br />
Signature of Notary<br />
________________________________<br />
Return Completed form with<br />
Print, Type or Stamp Name of Notary<br />
Supporting documents to:<br />
City of <strong>Key</strong> <strong>West</strong> Purchasing<br />
________________________________<br />
Title or Rank<br />
25
EQUAL BENEFITS FOR DOMESTIC PARTNERS AFFIDAVIT<br />
PROJECT <strong>ITB</strong> #<strong>13</strong>-<strong>022</strong>: KEY WEST FERRY TERMINAL BOAT LIFTS<br />
STATE OF ____________________ )<br />
: SS<br />
COUNTY OF ________________ )<br />
I, the undersigned hereby duly sworn, depose and say that the firm of ______________________<br />
provides benefits to domestic partners of its employees on the same basis as it provides benefits<br />
to employees’ spouses per City of <strong>Key</strong> <strong>West</strong> Ordinance Sec. 2-799.<br />
By: __________________________<br />
Sworn and subscribed before me this<br />
day of ________________, 20<strong>13</strong>.<br />
___________________________________________<br />
NOTARY PUBLIC, State of _______________ at Large<br />
My Commission Expires: ______________________<br />
26
City Ordinance Sec. 2-799<br />
Requirements for City Contractors to Provide Equal Benefits for Domestic Partners<br />
(a)<br />
Definitions. For purposes of this section only, the following definitions shall apply:<br />
(1) Benefits means the following plan, program or policy provided or offered by a<br />
contractor to its employees as part of the employer's total <strong>com</strong>pensation package:<br />
sick leave, bereavement leave, family medical leave, and health benefits.<br />
(2) Bid shall mean a <strong>com</strong>petitive bid procedure established by the city through the<br />
issuance of an invitation to bid, request for proposals, request for qualifications,<br />
or request for letters of interest.<br />
(3) Cash equivalent means the amount of money paid to an employee with a<br />
domestic partner in lieu of providing benefits to the employee's domestic partner.<br />
The cash equivalent is equal to the employer's direct expense of providing<br />
benefits to an employee for his or her spouse.<br />
The cash equivalents of the following benefits apply:<br />
a. For bereavement leave, cash payment for the number of days that would<br />
be allowed as paid time off for the death of a spouse. Cash payment would<br />
be in the form of the wages of the domestic partner employee for the<br />
number of days allowed.<br />
b. For health benefits, the cost to the contractor of the contractor's share of<br />
the single monthly premiums that are being paid for the domestic partner<br />
employee, to be paid on a regular basis while the domestic partner<br />
employee maintains such insurance in force for himself or herself.<br />
c. For family medical leave, cash payment for the number of days that would<br />
be allowed as time off for an employee to care for a spouse who has a<br />
serious health condition. Cash payment would be in the form of the wages<br />
of the domestic partner employee for the number of days allowed.<br />
(4) Contract means any written agreement, purchase order, standing order or similar<br />
instrument entered into pursuant to the award of a bid whereby the city is<br />
<strong>com</strong>mitted to expend or does expend funds in return for work, labor, professional<br />
services, consulting services, supplies, equipment, materials, construction,<br />
construction related services or any <strong>com</strong>bination of the foregoing.<br />
(5) Contractor means any person or persons, sole proprietorship, partnership, joint<br />
venture, corporation, or other form of doing business, that is awarded a bid and<br />
enters into a covered contract with the city, and which maintains five (5) or more<br />
full-time employees.<br />
(6) Covered contract means a contract between the city and a contractor awarded<br />
subsequent to the date when this section be<strong>com</strong>es effective valued at over twenty<br />
thousand dollars ($20,000).<br />
(7) Domestic partner shall mean any two adults of the same or different sex, who<br />
have registered as domestic partners with a governmental body pursuant to state<br />
or local law authorizing such registration, or with an internal registry maintained<br />
by the employer of at least one of the domestic partners. A contractor may<br />
institute an internal registry to allow for the provision of equal benefits to<br />
27
employees with domestic partner who do not register their partnerships pursuant<br />
to a governmental body authorizing such registration, or who are located in a<br />
jurisdiction where no such governmental domestic partnership registry exists. A<br />
contractor that institutes such registry shall not impose criteria for registration that<br />
are more stringent than those required for domestic partnership registration by the<br />
City of <strong>Key</strong> <strong>West</strong> pursuant to Chapter 38, Article V of the <strong>Key</strong> <strong>West</strong><br />
Code of Ordinances.<br />
(8) Equal benefits mean the equality of benefits between employees with spouses<br />
and employees with domestic partners, and/or between spouses of employees and<br />
domestic partners of employees.<br />
(b)<br />
Equal benefits requirements.<br />
(1) Except where otherwise exempt or prohibited by law, a Contractor awarded a<br />
covered contract pursuant to a bid process shall provide benefits to domestic<br />
partners of its employees on the same basis as it provides benefits to employees’<br />
spouses.<br />
(2) All bid requests for covered contracts which are issued on or after the effective<br />
date of this section shall include the requirement to provide equal benefits in the<br />
procurement specifications in accordance with this section.<br />
(3) The city shall not enter into any covered contract unless the contractor certifies<br />
that such contractor does not discriminate in the provision of benefits between<br />
employees with domestic partners and employees with spouses and/or between<br />
the domestic partners and spouses of such employees.<br />
(4) Such certification shall be in writing and shall be signed by an authorized officer<br />
of the contractor and delivered, along with a description of the contractor's<br />
employee benefits plan, to the city's procurement director prior to entering into<br />
such covered contract.<br />
(5) The city manager or his/her designee shall reject a contractor's certification of<br />
<strong>com</strong>pliance if he/she determines that such contractor discriminates in the<br />
provision of benefits or if the city manager or designee determines that the<br />
certification was created, or is being used for the purpose of evading the<br />
requirements of this section.<br />
(6) The contractor shall provide the city manager or his/her designee, access to its<br />
records for the purpose of audits and/or investigations to ascertain <strong>com</strong>pliance<br />
with the provisions of this section, and upon request shall provide evidence that<br />
the contractor is in <strong>com</strong>pliance with the provisions of this section upon each new<br />
bid, contract renewal, or when the city manager has received a <strong>com</strong>plaint or has<br />
reason to believe the contractor may not be in <strong>com</strong>pliance with the provisions of<br />
this section. This shall include but not be limited to providing the city manager or<br />
his/her designee with certified copies of all of the contractor's records pertaining<br />
to its benefits policies and its employment policies and practices.<br />
(7) The contractor may not set up or use its contracting entity for the purpose of<br />
evading the requirements imposed by this section.<br />
(c)<br />
Mandatory contract provisions pertaining to equal benefits. Unless otherwise exempt,<br />
every covered contract shall contain language that obligates the contractor to <strong>com</strong>ply with<br />
28
the applicable provisions of this section. The language shall include provisions for the<br />
following:<br />
(1) During the performance of the covered contract, the contractor certifies and<br />
represents that it will <strong>com</strong>ply with this section.<br />
(2) The failure of the contractor to <strong>com</strong>ply with this section will be deemed to be a<br />
material breach of the covered contract.<br />
(3) If the contractor fails to <strong>com</strong>ply with this section, the city may terminate the<br />
covered contract and all monies due or to be<strong>com</strong>e due under the covered contract<br />
may be retained by the city. The city may also pursue any and all other remedies<br />
at law or in equity for any breach.<br />
(4) If the city manager or his designee determines that a contractor has set up or used<br />
its contracting entity for the purpose of evading the requirements of this section,<br />
the city may terminate the covered contract.<br />
(d)<br />
Enforcement. If the contractor fails to <strong>com</strong>ply with the provisions of this section:<br />
(1) The failure to <strong>com</strong>ply may be deemed to be a material breach of the covered<br />
contract; or<br />
(2) The city may terminate the covered contract; or<br />
(3) Monies due or to be<strong>com</strong>e due under the covered contract may be retained by the<br />
city until <strong>com</strong>pliance is achieved; or<br />
(4) The city may also pursue any and all other remedies at law or in equity for any<br />
breach;<br />
(5) Failure to <strong>com</strong>ply with this section may also subject contractor to the procedures<br />
set forth in Division 5 of this article, entitled "Debarment of contractors from city<br />
work."<br />
(e)<br />
Exceptions and waivers.<br />
The provisions of this section shall not apply where:<br />
(1) The contractor does not provide benefits to employees' spouses.<br />
(2) The contractor is a religious organization, association, society or any non-profit<br />
charitable or educational institution or organization operated, supervised or<br />
controlled by or in conjunction with a religious organization, association or<br />
society.<br />
(3) The contractor is a governmental entity.<br />
(4) The sale or lease of city property.<br />
(5) The provision of this section would violate grant requirement, the laws, rules or<br />
regulations of federal or state law (for example, The acquisition services procured<br />
pursuant to Chapter 287.055, Florida Statutes known as the "Consultants'<br />
Competitive Negotiation Act").<br />
(6) Provided that the contractor does not discriminate in the provision of benefits, a<br />
contractor may also <strong>com</strong>ply with this section by providing an employee with the<br />
cash equivalent of such benefits, if the city manager or his/her designee<br />
determines that either:<br />
29
a. The contractor has made a reasonable yet unsuccessful effort to provide<br />
equal benefits. The contractor shall provide the city manager or his/her<br />
designee with sufficient proof of such inability to provide such benefit or<br />
benefits which shall include the measures taken to provide such benefits or<br />
benefits and the cash equivalent proposed, along with its certificate of<br />
<strong>com</strong>pliance, as is required under this section.<br />
(7) The city <strong>com</strong>mission waives <strong>com</strong>pliance of this section in the best interest of the<br />
city, including but not limited to the following circumstances:<br />
a. The covered contract is necessary to respond to an emergency.<br />
b. Where only one bid response is received.<br />
c. Where more than one bid response is received, but the bids<br />
demonstrate that none of the bidders can <strong>com</strong>ply with the<br />
requirements of this section.<br />
(f)<br />
(g)<br />
City's authority to cancel contract. Nothing in this section shall be construed to limit the<br />
city's authority to cancel or terminate a contract, deny or withdraw approval to perform<br />
a subcontract or provide supplies, issue a non-responsibility finding, issue a nonresponsiveness<br />
finding, deny a person or entity prequalification, or otherwise deny a<br />
person or entity city business.<br />
Timing of application. This section shall be applicable only to covered contracts<br />
awarded pursuant to bids which are after the date when this section be<strong>com</strong>es effective.<br />
30
CONE OF SILENCE AFFIDAVIT<br />
STATE OF ________________ )<br />
: SS<br />
COUNTY OF ________________ )<br />
I the undersigned hereby duly sworn depose and say that all owner(s), partners, officers,<br />
directors, employees and agents representing the firm of _______________________________<br />
have read and understand the limitations and procedures regarding <strong>com</strong>munications concerning<br />
City of <strong>Key</strong> <strong>West</strong> issued <strong>com</strong>petitive solicitations pursuant to City of <strong>Key</strong> <strong>West</strong> Ordinance<br />
Section 2-773 Cone of Silence (attached).<br />
Sworn and subscribed before me this<br />
day of ________________, 20<strong>13</strong>.<br />
___________________________________________<br />
NOTARY PUBLIC, State of ______________ at Large<br />
My Commission Expires: ______________________<br />
31
Sec. 2-773. Cone of Silence<br />
(a) Definitions. For purposes of this section, reference to one gender shall include the other, use<br />
of the plural shall include the singular, and use of the singular shall include the plural. The<br />
following definitions apply unless the context in which the word or phrase is used requires a<br />
different definition:<br />
1) Competitive Solicitation means a formal process by the City of <strong>Key</strong> <strong>West</strong> relating to<br />
the acquisition of goods or services, which process is intended to provide an equal<br />
and open opportunity to qualified persons and entities to be selected to provide the<br />
goods or services. Completive Solicitation shall include request for proposals<br />
("RFP"), request for qualifications ("RFQ"), request for letters of interest ("RFLI"),<br />
invitation to bid ("<strong>ITB</strong>") or any other advertised solicitation.<br />
2) Cone of Silence means a period of time during which there is a prohibition on<br />
<strong>com</strong>munication regarding a particular Competitive Solicitation.<br />
3) Evaluation or Selection Committee means a group of persons appointed or designated<br />
by the City to evaluate, rank, select, or make a re<strong>com</strong>mendation regarding a Vendor<br />
or the Vendor's response to the Competitive Solicitation. A member of such a<br />
<strong>com</strong>mittee shall be deemed a city official for the purposes of subsection (c) below.<br />
4) Vendor means a person or entity that has entered into or that desires to enter into a<br />
contract with the City of <strong>Key</strong> <strong>West</strong> or that seeks an award from the City to provide<br />
goods, perform a service, render an opinion or advice, or make a re<strong>com</strong>mendation<br />
related to a Competitive Solicitation for <strong>com</strong>pensation or other consideration.<br />
5) Vendor's Representative means an owner, individual, employee, partner, officer, or<br />
member of the board of directors of a Vendor, or a consultant, lobbyist, or actual or<br />
potential subcontractor or sub consultant who acts at the behest of a Vendor in<br />
<strong>com</strong>municating regarding a Competitive Solicitation.<br />
(b) Prohibited Communications: A Cone of Silence shall be in effect during the course of a<br />
Competitive Solicitation and prohibit:<br />
1) Any <strong>com</strong>munication regarding a particular Competitive Solicitation between a<br />
potential Vendor or Vendor's Representative and the City's administrative staff<br />
including, but not limited to, the city manager and his or her staff;<br />
2) Any <strong>com</strong>munication regarding a particular Competitive Solicitation between a<br />
potential Vendor or Vendor's Representative and the Mayor, City Commissioners, or<br />
their respective staff;<br />
32
3) Any <strong>com</strong>munication regarding a particular Competitive Solicitation between a<br />
potential Vendor or Vendor's Representative and any member of a City evaluation<br />
and/or selection <strong>com</strong>mittee therefore; and<br />
4) Any <strong>com</strong>munication regarding a particular Competitive Solicitation between the<br />
Mayor, City Commissioners, or their respective staff, and a member of a City<br />
evaluation and/or selection <strong>com</strong>mittee therefore.<br />
(c) Permitted Communications: Notwithstanding the foregoing, nothing contained herein shall<br />
prohibit:<br />
1) Communication between members of the public who are not Vendors or a Vendor’s<br />
representative and any city employee, official or member of the City Commission;<br />
2) Communications in writing at any time with any city employee, official or member of the<br />
City Commission, unless specifically prohibited by the applicable Competitive<br />
Solicitation.<br />
(A) However, any written <strong>com</strong>munication must be filed with the City Clerk. Any<br />
City employee, official or member of the City Commission receiving or<br />
making any written <strong>com</strong>munication must immediately file it with the City<br />
Clerk.<br />
(B) The City Clerk shall include all written <strong>com</strong>munication as part of the agenda<br />
item when publishing information related to a particular Competitive<br />
Solicitation.<br />
3) Oral <strong>com</strong>munications at duly noticed pre-bid conferences;<br />
4) Oral presentations before publically noticed evaluation and/or selection <strong>com</strong>mittees;<br />
5) Contract discussions during any duly noticed public meeting;<br />
6) Public presentations made to the City Commission or advisory body thereof during any<br />
duly noticed public meeting;<br />
7) Contract negotiations with city staff following the award of a Competitive Solicitation by<br />
the City Commission; or<br />
33
8) Purchases exempt from the <strong>com</strong>petitive process pursuant to section 2-797 of these Code<br />
of Ordinances.<br />
(d) Procedure<br />
1) The Cone of Silence shall be imposed upon each Competitive Solicitation at the time of<br />
Public Notice of such solicitation as provided by section 2-826 of this Code. Public<br />
notice of the Cone of Silence shall be included in the notice of the Competitive<br />
Solicitation. The city manager shall issue a written notice of the release of each<br />
Competitive Solicitation to the affected departments, with a copy thereof to each<br />
Commission member, and shall include in any public solicitation for goods and services a<br />
statement disclosing the requirements of this ordinance.<br />
2) The Cone of Silence shall terminate at the time the City Commission or other authorized<br />
body makes final award or gives final approval of a contract, rejects all bids or responses<br />
to the Competitive Solicitation, or takes other action which ends the Competitive<br />
Solicitation.<br />
3) Any City employee, official or member of the City Commission that is approached<br />
concerning a Competitive Solicitation while the Cone of Silence is in effect shall notify<br />
such individual of the prohibitions contained in this section. While the Cone of Silence is<br />
in effect, any City employee, official or member of the City Commission who is the<br />
recipient of any oral <strong>com</strong>munication by a potential Vendor or Vendor’s Representative in<br />
violation of this section shall create a written record of the event. The record shall<br />
indicate the date of such <strong>com</strong>munication, the persons with whom such <strong>com</strong>munication<br />
occurred, and a general summation of the <strong>com</strong>munication.<br />
(e) Violations/penalties and procedures.<br />
1) A sworn <strong>com</strong>plaint alleging a violation of this ordinance may be filed with the City<br />
Attorney’s office. In each such instance, an initial investigation shall be performed to<br />
determine the existence of a violation. If a violation is found to exist, the penalties and<br />
process shall be as provided in section 1-15 of this Code.<br />
2) In addition to the penalties described herein and otherwise provided by law, a violation of<br />
this ordinance shall render the Competitive Solicitation void at the discretion of the City<br />
Commission.<br />
3) Any person who violates a provision of this section shall be prohibited from serving on a<br />
City of <strong>Key</strong> <strong>West</strong> advisory board, evaluation and/or selection <strong>com</strong>mittee.<br />
34
4) In addition to any other penalty provided by law, violation of any provision of this<br />
ordinance by a City of <strong>Key</strong> <strong>West</strong> employee shall subject said employee to disciplinary<br />
action up to and including dismissal.<br />
5) If a Vendor is determined to have violated the provisions of this section on two more<br />
occasions it shall constitute evidence under City Code section 2-834 that the Vendor is<br />
not properly qualified to carry out the obligations or to <strong>com</strong>plete the work contemplated<br />
by any new Competitive Solicitation. The City’s Purchasing Agent shall also <strong>com</strong>mence<br />
any available debarment from city work proceeding that may be available upon a finding<br />
of two or more violations by a Vendor of this section.<br />
35
PART 2<br />
CONTRACT FORMS<br />
36
CONTRACT<br />
This Contract, made and entered into this _______ day of _________ 20<strong>13</strong>, by and between the<br />
CITY OF KEY WEST, hereinafter called the "Owner", and<br />
hereinafter called the "Contractor";<br />
WITNESSETH:<br />
The Contractor, in consideration of the sum to be paid him by the Owner and of the covenants<br />
and agreements herein contained, hereby agrees at his own proper cost and expense to do all the<br />
work and furnish all the materials, tools, labor, and all appliances, machinery, and appurtenances<br />
for the PROJECT <strong>ITB</strong> #<strong>13</strong>-<strong>022</strong>: KEY WEST BIGHT FERRY TERMINAL BOAT LIFTS, to the<br />
extent of the BID made by the Contractor, dated this _______ day of ______________ 20<strong>13</strong>, all<br />
in full <strong>com</strong>pliance with the Contract Documents referred to herein:<br />
BIDDING REQUIREMENTS, CONTRACT FORMS, CONDITIONS OF THE CONTRACT,<br />
SPECIFICATIONS, AND DRAWINGS (if any), which consists of KEY WEST BIGHT FERRY<br />
TERMINAL BOAT LIFTS are hereby referred to and by reference made a part of this Contract<br />
as fully and <strong>com</strong>pletely as if the same were fully set forth herein and are mutually cooperative<br />
therewith.<br />
In consideration of the performance of the work as set forth in these Contract Documents, the<br />
Owner agrees to pay to the Contractor the LUMP SUM BID amount in the Bid as adjusted in<br />
accordance with the Contract Documents, or as otherwise herein provided, and to make such<br />
payments in the manner and at the times provided in the Contract Documents.<br />
The Contractor agrees to <strong>com</strong>plete the work within the time specified in the Contract, and to<br />
accept as full payment hereunder the amounts as determined by the Contract Documents and<br />
based on the said Bid.<br />
The Contractor agrees to remedy all defects appearing in the work or developing in the materials<br />
furnished and the workmanship performed under this Contract during a two (2) year warranty<br />
37
period after the date of final acceptance of the work by the Owner, and further agrees to<br />
indemnify and hold harmless the Owner from any costs encountered in remedying such defects.<br />
The Bidder further agrees to begin work within twenty (20) calendar days after receipt the date<br />
of the Notice to Proceed and to <strong>com</strong>plete the construction of all items in the lump sum base Bid,<br />
in all respects, for this particular project, within sixty (60) calendar days after the date of receipt<br />
of all permits.<br />
In the event that the Contractor shall fail to <strong>com</strong>plete the work within the time limit or the<br />
extended time limit agreed upon, as more particularly set forth in the Contract Documents,<br />
liquidated damages shall be paid at the rate of five hundred dollars ($500.00) per calendar day.<br />
Sundays and legal holidays shall be included in determining days in default.<br />
IN WITNESS WHEREOF, we, the parties hereto, each herewith subscribe the same, this<br />
__________day of ____________ 20<strong>13</strong>.<br />
Attest:<br />
_______________________________<br />
Cheryl Smith, City Clerk<br />
By:<br />
______________________________<br />
Bogdan Vitas, Jr., City Manager<br />
Contractor:<br />
By:<br />
Print Name:<br />
Title:<br />
_____________________________ Witness: ___________________________<br />
_____________________________ Print Name: ________________________<br />
______________________________<br />
______________________________<br />
38
PART 3<br />
CONDITIONS OF THE CONTRACT<br />
39
CONDITIONS OF BID<br />
CITY OF KEY WEST<br />
1. PREPARATION OF BIDS:<br />
Bids will be prepared in accordance with the following:<br />
a. The enclosed Bid Response Form is to be used, other forms may be rejected.<br />
b. All information required by the Bid form shall be furnished. The BIDDER shall print<br />
or type his/her name and manually sign the Bid Response Form plus each<br />
continuation sheet on which an entry is made.<br />
c. Bid delivery time must be shown and shall include Sundays and holidays.<br />
d. BIDDER shall thoroughly examine the specifications, drawings (if any), schedule,<br />
instructions, and all other contract documents.<br />
e. All Bids shall be submitted in original plus one copy and 2 CDs or flash drives<br />
containing the <strong>com</strong>plete Bid in PDF format.<br />
f. BIDDERs are advised that all CITY OF KEY WEST contracts are subject to all legal<br />
requirements provided for in City ordinances and/or State and Federal Statutes.<br />
2. DESCRIPTION OF SUPPLIES:<br />
a. Any manufacturer's name, trade name, brand name, or catalog number used in the<br />
specifications is for the purpose of describing and establishing general quality levels.<br />
SUCH REFERENCES ARE NOT INTENDED TO BE RESTRICTIVE. Bids will be<br />
considered for any brand, which meets the quality of the specifications for any item.<br />
3. SUBMISSION OF BIDS:<br />
a. Bids and changes thereto shall be enclosed in sealed envelopes addressed to the City<br />
Clerk, City of <strong>Key</strong> <strong>West</strong>. The name and address of the BIDDER, the date and hour of<br />
the Bid opening and the Bid number shall be placed on the outside of the envelope.<br />
b. Bids must be submitted on the form furnished. Telecopy Bids will not be considered.<br />
c. Unless otherwise indicated, all City of <strong>Key</strong> <strong>West</strong> Bids may be awarded on a line-item<br />
basis.<br />
d. Bid prices must remain in effect for ordering up to three (3) months from Bid opening<br />
date.<br />
4. REJECTION OF BIDS:<br />
a. The CITY OF KEY WEST may reject Bids for any and/or all of the following<br />
reasons: (1) for budgetary reasons, (2) if the BIDDER misstates or conceals a material<br />
fact in his/her Bid, (3) if the Bid does not strictly conform to the law or is nonresponsive<br />
to the Bid requirements, (4) if the Bid is conditional, or (5) if a change of<br />
circumstances occurs making the purpose of the Bid unnecessary to the CITY OF<br />
KEY WEST. The CITY OF KEY WEST may also waive any minor informalities or<br />
irregularities in any Bid.<br />
5. WITHDRAWAL OF BIDS:<br />
a. Bids may not be withdrawn after the time set for the Bid opening for a period of time<br />
as specified in the Instruction to BIDDERs.<br />
40
. Bids may be withdrawn prior to the time set for Bids opening. Such request must be<br />
in writing addressed to the City Clerk.<br />
6. LATE BIDS OR MODIFICATION:<br />
a. Bids and modifications received after the time set for the Bid opening will not be<br />
considered.<br />
b. Modifications in writing received prior to the time set for the Bid opening will be<br />
accepted.<br />
7. LOCAL, STATE, AND FEDERAL COMPLIANCE REQUIREMENTS:<br />
a. BIDDERs shall <strong>com</strong>ply with all local, state and federal directives, orders and laws as<br />
applicable to this Bid and subsequent contract(s) including, but not limited to:<br />
1. Equal Employment Opportunity (EEO), in <strong>com</strong>pliance with Executive Order<br />
11246, as applicable to this contract.<br />
2. Minority Business Enterprises (MBE), as applicable to this contract.<br />
3. Occupational Safety and Health Act (OSHA), as applicable to this contract.<br />
8. COLLUSION:<br />
a. The BIDDER by affixing his/her signature to this Invitation to Bid, agrees to the<br />
following: "BIDDER certifies that his/her Bid is made without previous<br />
understanding, agreement, or connection with any person, firm, or corporation<br />
making a Bid for the same items and is in all respects fair, without outside control,<br />
collusion, fraud, or otherwise illegal action”.<br />
9. VARIANCE IN CONDITIONS:<br />
a. Any and all special conditions and specifications attached hereto, which vary from<br />
General Conditions, shall have precedence.<br />
10. APPROPRIATIONS CLAUSE:<br />
a. If the contract or delivery extends beyond the current fiscal year, which ends on<br />
September 30, the contract shall be contingent upon the availability of funds<br />
appropriated for such purposed in the City's annual budget for the next succeeding<br />
fiscal year.<br />
11. CLARIFICATION OR OBJECTION TO BID SPECIFICATIONS:<br />
a. If any person contemplating submitting a Bid for this contract is in doubt as to the<br />
true meaning of the specifications or other Bid documents or any part thereof, he/she<br />
may submit to the Project Manager, jmuccino@keywestcity.<strong>com</strong>, on or before ten<br />
calendar (10) days prior to scheduled opening a request for clarification. All such<br />
requests for information shall be made in writing (email) and the person submitting<br />
the request will be responsible for prompt delivery. Any interpretation of the Bid, if<br />
made, will be made only by Addendum duly issued. Such addendum will be made<br />
available through the DEMANDSTAR web site. The City will not be responsible for<br />
41
any other explanation or interpretation of the proposed Bid made or given prior to the<br />
award of the contract.<br />
12. DISCOUNTS:<br />
a. BIDDERs may offer a cash discount for prompt payment; however, such discount<br />
shall not be considered in determining the lowest net cost for Bid evaluation<br />
proposed. BIDDERs are encouraged to reflect cash discounts in the unit price quoted.<br />
b. In connection with any discount offered, time will be <strong>com</strong>puted from the date of<br />
receipt of supplies or services or form the date a correct invoice is received,<br />
whichever is the later date. Payment is deemed to be made on the date of mailing of<br />
the check.<br />
<strong>13</strong>. AWARD OF CONTRACT:<br />
a. The contract will be awarded to the lowest responsive and responsible BIDDER<br />
whose Bid, conforming to the Request for Bid, is most advantageous to the City,<br />
prices and other factors considered.<br />
b. The City reserves the right to accept and award item by item, and/or by group or in<br />
the aggregate, unless the BIDDER qualifies his/her Bid by specified limitations as<br />
provided in four (4).<br />
c. If two (2) or more Bids received are for the same total amount or unit price, quality<br />
and service being equal, the contract will be awarded according to City Ordinance<br />
Section 2-835(c).<br />
d. Prices quoted must be f.o.b. <strong>Key</strong> <strong>West</strong>, Florida, with all transportation charges<br />
prepaid unless otherwise specified in the Invitation to Bid.<br />
e. A written award of acceptance (Purchase Order) and a signed contract, mailed or<br />
otherwise furnished to the successful BIDDER shall result in a binding contract<br />
without further action by either party.<br />
14. LOCAL PREFERENCE:<br />
a. Pursuant to City Code Section 2-798 the City of <strong>Key</strong> <strong>West</strong> policy of local preference<br />
is applied to Bids submitted by qualified local businesses.<br />
15. DAMAGE:<br />
a. Successful BIDDER(s) will be responsible for making any and all claims against<br />
carriers for missing or damaged items.<br />
16. SURETY AND INSURER QUALIFICATIONS<br />
All bonds, insurance contracts, and certificates of insurance shall be either executed by or<br />
countersigned by a licensed resident agent of the surety or insurance <strong>com</strong>pany, having<br />
his/her place of business in the State of Florida, and in all ways <strong>com</strong>plying with the<br />
insurance laws of the State of Florida. Further, the said surety or insurance <strong>com</strong>pany shall<br />
be duly licensed and qualified to do business in the State of Florida.<br />
42
GENERAL CONDITIONS<br />
TABLE OF CONTENTS<br />
Article<br />
DEFINITIONS<br />
1. AS APPROVED<br />
2. AS SHOWN, AND AS INDICATED<br />
3. BIDDER<br />
4. CONTRACT DOCUMENTS<br />
5. CONTRACTOR<br />
6. CONTRACT COMPLETION<br />
7. DAYS<br />
8. DRAWINGS<br />
9. ENGINEER<br />
10. NOTICE<br />
11. OR EQUAL<br />
12. OWNER<br />
<strong>13</strong>. PLANS<br />
14. SPECIFICATIONS<br />
15. NOTICE TO PROCEED<br />
16. SUBSTANTIAL COMPLETION<br />
17. WORK<br />
CONTRACT DOCUMENTS<br />
18. INTENT OF CONTRACT DOCUMENTS<br />
19. DISCREPANCIES & OMISSIONS<br />
20. CHANGES IN THE WORK<br />
21. EXAMINATIONS AND VERIFICATION<br />
OF CONTRACT DOCUMENTS<br />
22. DOCUMENTS TO BE KEPT ON THE<br />
JOBSITE<br />
23. ADDITIONAL CONTRACT<br />
DOCUMENTS<br />
24. OWNERSHIP OF CONTRACT<br />
DOCUMENTS<br />
THE ENGINEER<br />
25. AUTHORITY OF THE ENGINEER<br />
26. DUTIES & RESPONSIBILITIES OF THE<br />
ENGINEER<br />
27. LIMITATIONS ON ENGINEER’S<br />
RESPONSIBILITIES<br />
28. REJECTED WORK<br />
29. LINES AND GRADES<br />
30. SUBMITTALS<br />
31. DETAIL DRAWINGS AND<br />
Article<br />
INSTRUCTIONS<br />
THE CONTRACTOR & HIS EMPLOYEES<br />
32. CONTRACTOR, AN INDEPENDENT AGENT<br />
32 (a). ASSIGNMENT OF CONTRACT<br />
33. SUBCONTRACTING<br />
34. INSURANCE AND LIABILITY<br />
A. GENERAL<br />
B. CONTRACTOR & SUBCONTRACTOR<br />
INSURANCE<br />
C. COMPENSATION & EMPLOYER’S<br />
LIABILITY INSURANCE<br />
D. GENERAL LIABILITY INSURANCE<br />
(INCLUDING AUTOMOBILE)<br />
E. BUILDERS RISK ALL RISK INSURANCE<br />
F. NO PERSONAL LIABILITY OF PUBLIC<br />
OFFICIALS<br />
G. SURETY AND INSURER<br />
QUALIFICATIONS<br />
35. INDEMNITY<br />
36. EXCLUSION OF CONTRACTOR CLAIMS<br />
37. TAXES AND CHARGES<br />
38. REQUIREMENTS OF STATE LAW FOR<br />
PUBLIC WORKS PROJECTS<br />
39. CODES, ORDINANCES, PERMITS, AND<br />
LICENSES<br />
40. SUPERINTENDENCE<br />
40(a). CONTRACTOR’S RESPONSIBILITIES<br />
41. RECEPTION OF ENGINEER’S<br />
COMMUNICATIONS<br />
42. SAFETY<br />
43. PROTECTION OF WORK AND PROPERTY<br />
43(a). HISTORIC PRESERVATION<br />
44. RESPONSIBILITY OF CONTRACTOR TO<br />
ACT IN AN EMERGENCY<br />
45. MATERIALS AND APPLIANCES<br />
46. CONTRACTORS’ AND MANUFACTURERS’<br />
COMPLIANCE WITH STATE SAFETY, OSHA,<br />
AND OTHER CODE REQUIREMENTS<br />
47. SUBSTITUTION OF MATERIALS<br />
48. TESTS, SAMPLES, AND OBSERVATIONS<br />
49. ROYALTIES AND PATENTS<br />
50. CONTRACTOR’S RIGHT TO TERMINATE<br />
CONTRACT<br />
51. CORRECTION OF DEFECTIVE WORK<br />
DURING WARRANTY PERIOD<br />
43
Article<br />
PROGRESS OF THE WORK<br />
52. BEGINNING OF THE WORK<br />
53. SCHEDULES AND PROGRESS REPORTS<br />
54. PROSECUTION OF THE WORK<br />
55. OWNER’S RIGHT TO RETAIN IMPERFECT<br />
WORK<br />
55(a). OWNER’S RIGHT TO STOP WORK<br />
56. OWNER’S RIGHT TO DO WORK<br />
57. OWNER’S RIGHT TO TRANSFER<br />
EMPLOYMENT<br />
58. DELAYS AND EXTENSIONS OF TIME<br />
59. DIFFERING SITE CONDITION<br />
60. LIQUIDATED DAMAGES<br />
61. OTHER CONTRACTS<br />
62. USE OF PREMISES<br />
63. SUBSTANTIAL COMPLETION DATE<br />
64. PERFORMANCE TESTING<br />
65. OWNER’S USE OF PORTION OF THE<br />
WORK<br />
66. CUTTING AND PATCHING<br />
67. CLEANING UP<br />
Article<br />
PAYMENT<br />
68. PAYMENT FOR CHANGE ORDERS<br />
A. UNIT PRICE<br />
B. LUMP SUM<br />
C. COST REIMBURSEMENT WORK<br />
69. PARTIAL PAYMENTS<br />
A. GENERAL<br />
B. ESTIMATE<br />
C. DEDUCTION FROM ESTIMATE<br />
D. QUALIFICATIONS FOR PARTIAL<br />
PAYMENT FOR MATERIALS<br />
DELIVERED<br />
E. PAYMENT<br />
70. CLAIMS FOR EXTRA WORK<br />
71. RELEASE OF LIENS OR CLAIMS<br />
72. FINAL PAYMENT<br />
73. NO WAIVER OF RIGHTS<br />
74. ACCEPTANCE OF FINAL PAYMENT<br />
CONSTITUTES RELEASE<br />
44
DEFINITIONS<br />
Whenever in the Contract Documents the following terms are used, the intent and meaning shall be<br />
interpreted as follows:<br />
1. AS APPROVED<br />
The words "as approved", unless otherwise qualified, shall be understood to be followed by<br />
the words "by the Engineer for conformance with the Contract Document".<br />
2. AS SHOWN, AND AS INDICATED<br />
The words "as shown" and "as Indicated" shall be understood to be followed by the words<br />
"on the Drawings".<br />
3. BIDDER<br />
The person or persons, partnership, firm, or corporation submitting a Bid for the work<br />
contemplated.<br />
4. CONTRACT DOCUMENTS<br />
The "Contract Documents" consist of the Bid Requirements, Contract Forms, Conditions of<br />
the Contact, Specifications, Drawings, all modifications thereof incorporated into the<br />
Documents before their execution, Change Orders, and all other requirements incorporated<br />
by specific reference thereto. These form the Contract.<br />
5. CONTRACTOR<br />
The person or persons, partnership, firm, or corporation who enters into the Contract<br />
awarded him by the Owner.<br />
6. CONTRACT COMPLETION<br />
The "Contract Completion" is the date the Owner accepts the entire work as being in<br />
<strong>com</strong>pliance with the Contract Documents, or formally waives nonconforming work to<br />
extent of nonconformity, and issues the final payment in accordance with the requirements<br />
set forth in Article, "Final Payment" of these General Conditions.<br />
7. DAYS<br />
Unless otherwise specifically stated, the term "days" will be understood to mean calendar<br />
days. Business day or working day means any day other than Saturday, Sunday, or legal<br />
holiday.<br />
8. DRAWINGS<br />
The term "Drawings" refers to the official Drawings, profiles, cross sections, elevations,<br />
details, and other working drawings and supplementary drawings, or reproductions thereof<br />
which shows the location, character, dimensions, and details of the work to be performed.<br />
45
9. ENGINEER<br />
The person or organization identified as such in the Contract Documents. The Term<br />
"Engineer" means the Owner’s Engineer, Owner’s contracted Engineer, or its authorized<br />
representative.<br />
9 (a). PROJECT MANAGER<br />
The person or organization identified as such in the Contract Documents. The Term<br />
"Project Manager" means the Owner’s authorized representative overseeing the project for<br />
the City.<br />
10. NOTICE<br />
The term "notice" or the requirement to notify, as used in the Contract Documents or<br />
applicable state or federal statutes, shall signify a written <strong>com</strong>munication delivered in<br />
person or by registered mail to the individual, or to a member of the firm, or to an officer of<br />
the corporation for whom it is intended. Certified or registered mail shall be addressed to<br />
the last business address known to him who gives the notice.<br />
11. OR EQUAL<br />
The term "or equal" shall be understood to indicate that the "equal" product is equivalent to<br />
or better than the product named in function, performance, reliability, quality, and general<br />
configuration. The Engineer will make determination of equality in reference to the project<br />
design requirements. Such equal products shall not be purchased or installed by the<br />
Contractor without written authorization.<br />
12. OWNER<br />
The person, organization, or public body identified as such in the Contract Documents.<br />
Wherever in these Documents the word "Owner" appears, it shall be understood to mean<br />
the City of <strong>Key</strong> <strong>West</strong> whose address is 3140 Flagler Ave, <strong>Key</strong> <strong>West</strong>, Florida 33040.<br />
<strong>13</strong>. PLANS (See Drawings)<br />
14. SPECIFICATIONS<br />
The term "Specifications" refers to those portions of the Contract Documents consisting of<br />
written technical descriptions of materials, equipment, construction systems, standards, and<br />
workmanship as applied to the work and certain administrative details applicable thereto.<br />
Where standard specifications, such as those of ASTM, AASHTO, etc., have been referred<br />
to, the applicable portions of such standard specifications shall be<strong>com</strong>e a part of these<br />
Contract Documents. If referenced specifications conflict with specifications contained<br />
herein, the requirements contained herein shall prevail.<br />
FEDERAL, STATE, COUNTY, AND LOCAL STANDARD SPECIFICATIONS<br />
46
Where portions of the work traverse or cross federal, state, county, or local highways,<br />
roads, or streets, and the agency in control of such property has established standard<br />
specifications governing items of work that differ from these Specifications, the most<br />
stringent requirements shall apply.<br />
The Contractor shall <strong>com</strong>ply with all regulations and requirements of the State Highway<br />
Department and the County Road Department wherever the work traverses or crosses<br />
state or county highways.<br />
15. NOTICE TO PROCEED<br />
A written notice given by the Owner to the Contractor (with a copy to the Engineer) fixing<br />
the date on which the Contract time will <strong>com</strong>mence to run and on which the Contractor<br />
shall start to perform his obligation under the Contract Documents. The Owner will give<br />
the Notice to Proceed within thirty (30) calendar days following the execution of the<br />
Contract.<br />
16. SUBSTANTIAL COMPLETION<br />
"Substantial Completion" shall be that degree of <strong>com</strong>pletion of the project or a defined<br />
portion of the project, as evidenced by the Engineer's written notice of Substantial<br />
Completion, sufficient to provide the Owner, at his discretion, the full-time use of the<br />
project or defined portion of the project for the purposes for which it was intended.<br />
"Substantial Completion" of an operating facility shall be that degree of <strong>com</strong>pletion that<br />
has provided a minimum of seven (7) continuous days of successful, trouble-free,<br />
operation, which period shall begin after all performance and acceptance testing has been<br />
successfully demonstrated to the Engineer. All equipment contained in the work, plus all<br />
other <strong>com</strong>ponents necessary to enable the Owner to operate the facility in a manner that<br />
was intended, shall be <strong>com</strong>plete on the substantial <strong>com</strong>pletion date.<br />
17. WORK<br />
The word "work" within these Contract Documents shall include all material, labor, tools,<br />
and all appliances, machinery, transportation, and appurtenances necessary to perform and<br />
<strong>com</strong>plete the Contract, and such additional items not specifically indicated or described<br />
which can be reasonably inferred as belonging to the item described or indicated and as<br />
required by good practice to provide a <strong>com</strong>plete and satisfactory system or structure. As<br />
used herein, "provide" shall be understood to mean, "furnish and install, <strong>com</strong>plete inplace".<br />
CONTRACT DOCUMENTS<br />
18. INTENT OF CONTRACT DOCUMENTS<br />
The Contract Documents are <strong>com</strong>plementary, and what is called for by one shall be as<br />
binding as if called for by all. The intent of the Documents is to describe a functionally<br />
<strong>com</strong>plete project (or part thereof) to be constructed in accordance with the Contract<br />
Documents. Any work, materials, or equipment that may reasonably be inferred from the<br />
Contract Documents, as being required to produce the intended result shall be supplied<br />
whether or not specifically called for. When words, which have a well-known technical or<br />
47
trade meaning, are used to describe work, materials, or equipment, such words shall be<br />
interpreted in accordance with that meaning.<br />
Reference to standard specifications, manuals, or codes of any technical society,<br />
organization or association, or to the laws or regulations of any governmental authority,<br />
whether such reference be specific or by implication, shall mean the latest standard<br />
specification, manual, code or laws or regulations in effect on the first published date of the<br />
Invitation to Bid, except as may be otherwise specifically stated. However, no provision of<br />
any referenced standard specification, manual or code (whether or not specifically<br />
incorporated by reference in the Contract Documents) shall be effective to change the<br />
duties and responsibilities of Owner, Contractor, or Engineer, or any of their Contractors,<br />
agents, or employees from those set forth in the Contract Documents, nor shall it be<br />
effective to assign to Engineer, or any Engineer's Contractors, agents, or employees, any<br />
duty or authority to supervise or direct the furnishing or performance of the work or any<br />
duty or authority to undertake responsibility contrary to the provisions of Article<br />
LIMITATIONS ON ENGINEER'S RESPONSIBILITIES.<br />
19. DISCREPANCIES AND OMISSIONS<br />
Any discrepancies or omissions found in the Contract Documents shall be reported to the<br />
Engineer immediately. The Engineer will clarify discrepancies or omissions, in writing,<br />
within a reasonable time.<br />
In resolving inconsistencies among two or more sections of the Contract Documents,<br />
precedence shall be given in the following order:<br />
A. CONTRACT<br />
B. BID<br />
C. SPECIAL CONDITIONS<br />
D. SUPPLEMENTARY CONDITIONS<br />
E. REQUEST FOR BIDS<br />
F. INSTRUCTIONS TO BIDDERS<br />
G. GENERAL CONDITIONS<br />
H. SPECIFICATIONS<br />
I. DRAWINGS<br />
Addenda shall take precedence over all sections referenced therein. Figure dimensions on<br />
Drawings shall take precedence over scale dimensions. Detailed Drawings shall take<br />
precedence over general Drawings.<br />
20. CHANGES IN THE WORK<br />
The Owner, without notice to the Sureties and without invalidating the Contract, may order<br />
changes in the work within the general scope of the Contract by altering, adding to, or<br />
deducting from the work, the Contract being adjusted accordingly. All such work shall be<br />
executed under the conditions of the original Contract, except as specifically adjusted at the<br />
48
time of ordering such change.<br />
In giving instructions, the Engineer may order minor changes in the work not involving<br />
extra cost and not inconsistent with the purposes of the project, but otherwise, except in an<br />
emergency endangering life and property, additions or deductions from the work shall be<br />
performed only in pursuance of an approved Change Order from the Owner, countersigned<br />
by the Engineer.<br />
If the work is reduced by alterations, such action shall not constitute a claim for damages<br />
based on loss of anticipated profits.<br />
21. EXAMINATIONS AND VERIFICATION OF CONTRACT DOCUMENTS<br />
The Contractor shall thoroughly examine and be<strong>com</strong>e familiar with all of the various parts<br />
of these Contract Documents and determine the nature and location of the work, the general<br />
and local conditions, and all other matters, which can in any way affect the work under this<br />
Contract. Failure to make an examination necessary for this determination shall not release<br />
the Contractor from the obligations of this Contract. No verbal agreement or conversation<br />
with any officer, agent, or employee of the Owner, or with the Engineer either before or<br />
after the execution of this Contract, shall affect or modify any of the terms or obligations<br />
herein contained.<br />
22. DOCUMENTS TO BE KEPT ON THE JOBSITE<br />
The Contractor shall keep one copy of the Contract Documents on the job- site, in good<br />
order, available to the Engineer and to his/her representatives.<br />
The Contractor shall maintain on a daily basis at the jobsite, and make available to the<br />
Engineer on request, one current record set of the Drawings which have been accurately<br />
marked to indicate all modifications in the <strong>com</strong>pleted work that differ from the design<br />
information shown on the Drawings. Upon Substantial <strong>com</strong>pletion of the work, the<br />
Contractor shall give the Engineer one (1) <strong>com</strong>plete set of these marked up record<br />
Drawings.<br />
23. ADDITIONAL CONTRACT DOCUMENTS<br />
Copies of Contract Documents or Drawings may be obtained on request from the Engineer<br />
and by paying the actual cost of reproducing the Contract Documents or Drawings.<br />
24. OWNERSHIP OF CONTRACT DOCUMENTS<br />
All portions of the Contract Documents, and copies thereof furnished by the Engineer are<br />
instruments of service for this project. They are not to be used on other work and are to be<br />
returned to the Engineer on request at the <strong>com</strong>pletion of the work. Any reuse of these<br />
materials without specific written verification or adaptation by the Engineer will be at the<br />
risk of the user and without liability or legal expense to the Engineer. Such user shall hold<br />
the Engineer harmless from any and all damages, including reasonable attorneys' fees, from<br />
any and all claims arising from any such reuse. Any such verification and adaptation shall<br />
entitle the Engineer to further <strong>com</strong>pensation at rates to be agreed upon by the user and the<br />
Engineer.<br />
49
THE ENGINEER<br />
25. AUTHORITY OF THE ENGINEER<br />
The Engineer will be the Owner's representative during the construction period. His/her<br />
authority and responsibility will be limited to the provisions set forth in these Contract<br />
Documents. The Engineer will have the Authority to reject work that does not conform to<br />
the Contract Documents. However, neither the Engineer's authority to act under this<br />
provision, nor any decision made by him/her in good faith either to exercise or not to<br />
exercise such authority, shall give rise to any duty or responsibility of the Engineer to the<br />
Contractor, any Subcontractor, their respective Sureties, any of their agents or employees,<br />
or any other person performing any of the work.<br />
26. DUTIES AND RESPONSIBILITIES OF THE ENGINEER<br />
The Engineer will make visits to the site at intervals appropriate to the various stages of<br />
construction to observe the progress and quality of the work and to determine, in general, if<br />
the work is proceeding in accordance with the intent of the Contract Documents. He/she<br />
will not make <strong>com</strong>prehensive or continuous review or observation to check quality or<br />
quantity of the work, and he/she will not be responsible for construction means, methods,<br />
techniques, sequences, or procedures, or for safety precautions and programs in connection<br />
with the work. Visits and observations made by the Engineer shall not relieve the<br />
Contractor of his/her obligation to conduct <strong>com</strong>prehensive inspections of the work and to<br />
furnish materials and perform acceptable work, and to provide adequate safety precautions,<br />
in conformance with the intent of the Contract.<br />
The Engineer will make re<strong>com</strong>mendations to the Owner, in writing, on all claims of the<br />
Owner or the Contractor arising from interpretation or execution of the Contract<br />
Documents. Such re<strong>com</strong>mendations will be of factual and/or technical nature, and will not<br />
include the legal interpretation of the Contract Documents. The Owner will make any<br />
necessary legal interpretation of the Contract Document. Such re<strong>com</strong>mendation shall be<br />
necessary before the Contractor can receive additional money under the terms of the<br />
Contract. Changes in work ordered by the Engineer shall be made in <strong>com</strong>pliance with<br />
Article CHANGES IN THE WORK.<br />
One or more project representatives may be assigned to observe the work. It is understood<br />
that such project representatives shall have the authority to issue notice of nonconformance<br />
and make decisions within the limitations of the authority of the Engineer. The Contractor<br />
shall furnish all reasonable assistance required by the Engineer or project representatives<br />
for proper observation of the work. The above-mentioned project representatives shall not<br />
relieve the Contractor of his/her obligations to conduct <strong>com</strong>prehensive inspections of the<br />
work and to furnish materials and perform acceptable work, and to provide adequate safety<br />
precautions, in conformance with the intent of the Contract.<br />
27. LIMITATIONS ON ENGINEER'S RESPONSIBILITIES<br />
Engineer will not be responsible for Contractor's means, methods, techniques, sequences,<br />
50
or procedures of construction, or the safety precautions and programs incident thereto, and<br />
Engineer will not be responsible for Contractor's failure to perform or furnish the work in<br />
accordance with the Contract Documents.<br />
Engineer will not be responsible for the acts or omissions of Contractor or of any<br />
Subcontractor, any supplier, or of any other person or organization performing or<br />
furnishing any of the work.<br />
Whenever in the Contract Documents the terms "as ordered", "as directed", "as required",<br />
"as allowed", "as approved", or terms of like effect or import are used, or the adjectives<br />
"reasonable", "suitable", "acceptable", "proper", or "satisfactory", or adjectives of like<br />
effect or import are used to describe a requirement, direction, review or judgment of<br />
Engineer as to the work, it is intended that such requirement, direction, review, or judgment<br />
will be solely to evaluate the work for <strong>com</strong>pliance with the Contract Documents (unless<br />
there is a specific statement indicating otherwise). The use of any such term or adjective<br />
shall not be effective to assign to Engineer any duty or authority to supervise or direct the<br />
furnishing or performance of the work or any duty or authority to undertake responsibility<br />
contrary to the provisions of this Article.<br />
28. REJECTED WORK<br />
Any defective work or nonconforming materials or equipment that may be discovered at<br />
any time prior to expiration of the warranty period shall be removed and replaced by work<br />
which shall conform to the provisions of the Contract Documents. Any material<br />
condemned or rejected shall be removed at once from the project site.<br />
Failure on the part of the Engineer to condemn or reject bad or inferior work or to note<br />
nonconforming materials or equipment on Contractor submittals shall not be construed to<br />
imply acceptance of such work. The Owner shall reserve and retain all of its rights and<br />
remedies at law against the Contractor and its Surety for correction of any and all latent<br />
defects discovered after the guarantee period.<br />
29. LINES AND GRADES<br />
Lines and grades shall be established as provided in the supplementary conditions. All<br />
stakes, marks, and other reference information shall be carefully preserved by the<br />
Contractor, and in case of their careless or unnecessary destruction or removal by him/her<br />
or his/her employees, such stakes, marks, and other information shall be replaced at the<br />
Contractor's expense.<br />
It will be the Contractor's responsibility to layout the work and to transfer elevations from<br />
benchmarks. Where new construction connects to existing facilities, the Contractor shall<br />
check and establish the exact location prior to construction of the facilities.<br />
The Contractor shall furnish all surveys, labor, and equipment, including setting all<br />
alignment and gradient, grade stakes, batter boards, and everything necessary to lay out<br />
his/her work. The Contractor shall be responsible for maintaining and re-establishing at<br />
his expense, all control points. After <strong>com</strong>pletion of his construction, he shall reset all<br />
permanent monuments at their original locations and elevations.<br />
51
The Engineer may check all layout work, and the Contractor shall furnish all necessary<br />
labor, equipment, and materials, and shall cooperate and assist the Engineer in making<br />
such checks.<br />
The dimensions for lines and elevations for grades of the fuel system structures,<br />
appurtenances, and utilities will be shown on Drawings produced by the Contractor for<br />
the issuance of all required permits, together with other pertinent information required for<br />
laying out the work. If site conditions vary from those indicated, the Contractor shall<br />
notify the Engineer immediately, who will make any minor adjustments as required.<br />
30. SUBMITTALS<br />
After checking and verifying all field measurements and after <strong>com</strong>plying with applicable<br />
procedures specified in Division I, GENERAL REQUIREMENTS, Contractor shall submit<br />
to Engineer, in accordance with the schedule for submittals for review, shop drawings,<br />
electrical diagrams, and catalog cuts for fabricated items and manufactured items<br />
(including mechanical and electrical equipment), which shall bear a stamp or specific<br />
written indication that Contractor has satisfied Contractor's responsibilities under the<br />
Contract Documents with respect to the review of the submittal. All submittals shall be<br />
identified as Engineer may require. The data shown shall be <strong>com</strong>plete with respect to<br />
quantities, dimensions specified, performance and design criteria, materials, and similar<br />
data to enable Engineer to review the information. Contractor shall also submit to Engineer<br />
for review, with such promptness as to cause no delay in work, all samples required by the<br />
Contract Documents. All samples shall have been checked by and ac<strong>com</strong>panied by a<br />
specific written indication that Contractor has satisfied Contractor's responsibilities under<br />
the Contract Documents with respect to the review of the submission and shall be identified<br />
clearly as to material, supplier, pertinent data such as catalog numbers and the use for<br />
which intended.<br />
Before submission of each submittal, Contractor shall have determined and verified all<br />
quantities, dimensions, specified performance criteria, installation requirements, materials,<br />
catalog numbers, and similar data with respect thereto and reviewed or coordinated each<br />
submittal with other submittals and with the requirements of the work and the Contract<br />
Documents.<br />
At the time of each submission, Contractor shall give Engineer specific written notice of<br />
each variation that the submittal may have from the requirements of the Contract<br />
Documents, and, in addition, shall cause a specific notation to be made on each shop<br />
drawing submitted to Engineer for review and approval of each variation.<br />
Engineer will review submittals with reasonable promptness, but Engineer's review will be<br />
only for conformance with the design concept of the project and for <strong>com</strong>pliance with the<br />
information given in the Contract Documents and shall not extend to means, methods,<br />
techniques, sequences, or procedures of construction (except where a specific means,<br />
method, technique, sequence, or procedure of construction is indicated in or required by the<br />
Contract Documents) or to safety precautions or programs incident thereto. The review of<br />
a separate item as such will not indicate review of the assembly in which the item<br />
functions. Contractor shall make corrections required by Engineer, and shall return the<br />
required number of corrected copies of shop drawings and submit as required new samples<br />
for review. Contractor shall direct specific attention in writing to revisions other than the<br />
52
corrections called for by Engineer on previous submittals.<br />
Engineer's review of submittals shall not relieve Contractor from the responsibility for any<br />
variation from the requirements of the Contract Documents unless Contractor has in<br />
writing called Engineer's attention to each such variation at the time of submission and<br />
Engineer has given written approval of each such variation by a specific written notation<br />
thereof incorporated therein or ac<strong>com</strong>panying the shop drawing or sample approval; nor<br />
will any approval by Engineer relieve Contractor from responsibility for errors or<br />
omissions in the shop drawings or from responsibility for having <strong>com</strong>plied with the<br />
provisions herein.<br />
Where a shop drawing or sample is required by the specifications, any related work<br />
performed prior to Engineer's review and approval of the pertinent submission shall be at<br />
the sole expense and responsibility of the Contractor.<br />
31. DETAIL DRAWINGS AND INSTRUCTIONS<br />
The Engineer will furnish, with reasonable promptness, additional instructions by means of<br />
Drawings or otherwise, if, in the Engineer's opinion, such are required for the proper<br />
execution of the work. All such Drawings and instructions will be consistent with the<br />
Contract Documents, true developments thereof, and reasonably inferable there from.<br />
THE CONTRACTOR AND HIS EMPLOYEES<br />
32. CONTRACTOR, AN INDEPENDENT AGENT<br />
The Contractor shall independently perform all work under this Contract and shall not be<br />
considered as an agent of the Owner or of the Engineer, nor shall the Contractor's<br />
Subcontractors or employees be subagents of the Owner or of the Engineer.<br />
32. (a) ASSIGNMENT OF CONTRACT<br />
Assignment of any part or the whole of this Contract shall be subject to review and<br />
approval of the City Commission.<br />
33. SUBCONTRACTING<br />
Unless modified in the Supplementary Conditions, within ten (10) calendar days after the<br />
execution of the Contract, the Contractor shall submit to the Engineer the names of all<br />
Subcontractors proposed for the work, including the names of any Subcontractors that were<br />
submitted with the Bid. The Contractor shall not employ any subcontractors to which the<br />
Owner may object to as lacking capability to properly perform work of the type and scope<br />
anticipated.<br />
The Contractor is as fully responsible to the Owner for the acts and omissions of his<br />
Subcontractors and of persons either directly or indirectly employed by them as he is for<br />
the acts and omissions of persons directly employed by him.<br />
Nothing contained in the Contract Documents shall create any contractual relationship<br />
between any Subcontractor and the Owner or Engineer.<br />
53
34. INSURANCE AND LIABILITY<br />
A. GENERAL<br />
The Contractor shall provide (from insurance <strong>com</strong>panies acceptable to the Owner)<br />
the insurance coverage designated hereinafter and pay all costs.<br />
Before <strong>com</strong>mencing work under this Contract, Contractor shall furnish the Owner<br />
with certificates of insurance specified herein showing the type, amount class of<br />
operations covered, effective dates, and date of expiration of policies, and<br />
containing substantially the following statement:<br />
"The insurance covered by this certificate shall not be canceled or materially<br />
altered, except after 30 days' written notice has been received by the Owner."<br />
In case of the breach of any provision of this Article, the Owner, at his option, may<br />
take out and maintain, at the expense of the Contractor, such insurance as the<br />
Owner may deem proper and may deduct the cost of such insurance from any<br />
monies which may be due or be<strong>com</strong>e due the Contractor under this Contract.<br />
B. CONTRACTOR AND SUBCONTRACTOR INSURANCE<br />
The Contractor shall not <strong>com</strong>mence work under this Contract until he has<br />
obtained all the insurance required hereunder and such insurance has been<br />
reviewed by the Owner, nor shall the Contractor allow any Subcontractor to<br />
<strong>com</strong>mence work on his subcontract until insurance specified below has been<br />
obtained. Review of the insurance by the Owner shall not relieve or decrease the<br />
liability of the Contractor hereunder.<br />
C. COMPENSATION AND EMPLOYER'S LIABILITY INSURANCE<br />
The Contractor shall maintain during the life of this Contract the statutory amount<br />
of Workmen's Compensation Insurance, in addition, Employer's Liability Insurance<br />
in an amount as specified in the Supplementary Conditions, for each occurrence, for<br />
all of his employees to be engaged in work on the project under this Contract. In<br />
case any such work is subcontracted, the Contractor shall require the Subcontractor<br />
to provide similar Workmen's Compensation and Employer's Liability Insurance for<br />
all of the Subcontractor's employees to be engaged in such work.<br />
D. GENERAL LIABILITY INSURANCE (INCLUDING AUTOMOBILE)<br />
See Supplementary Conditions<br />
E. BUILDERS RISK ALL RISK INSURANCE<br />
Unless otherwise modified in the Supplementary Conditions, the Contractor shall<br />
secure and maintain during the life of this Contact, Builders Risk All Risk<br />
Insurance Coverage in an amount equal to the full value of the facilities under<br />
construction. Deductible shall be no greater then $5,000. Such insurance shall<br />
54
include coverage for earthquake, landslide, flood, collapse, loss due to the result<br />
of faulty workmanship or design, and all other normally covered risks, and shall<br />
provide losses to be paid to the Contractor, Owner, and Engineer as their interests<br />
may appear.<br />
The Owner and Engineer, their officers, agents, and employees shall be named as<br />
additional insureds on the Contractor’s and any subcontractors Builders Risk All<br />
Risk insurance policies for any claims arising out of work performed under this<br />
Contract.<br />
This insurance shall include a waiver of subrogation as to the Engineer, the<br />
Owner, the Contractor, and their respective officers, agents, employees, and<br />
subcontractors.<br />
F. NO PERSONAL LIABILITY OF PUBLIC OFFICIALS<br />
In carrying out any of the provisions hereof in exercising any authority granted by<br />
the Contract, there will be no personal liability upon any public official.<br />
G. SURETY AND INSURER QUALIFICATIONS<br />
35. INDEMNITY<br />
All bonds, insurance contracts, and certificates of insurance shall be either<br />
executed by or countersigned by a licensed resident agent of the Surety or<br />
insurance <strong>com</strong>pany, having his place of business in the State of Florida, and in all<br />
ways <strong>com</strong>plying with the insurance laws of the State of Florida. Further, the said<br />
Surety or insurance <strong>com</strong>pany shall be duly licensed and qualified to do business<br />
in the State of Florida. If requested, Contractor shall provide proof of Florida<br />
Licensure for all insurance <strong>com</strong>panies.<br />
The following shall be made a provision of any resulting agreement:<br />
To the fullest extent permitted by law, the Contractor expressly agrees to indemnify and<br />
hold harmless the City of <strong>Key</strong> <strong>West</strong>, their officers, directors, agents, and employees<br />
(herein called the “indemnities”) from liabilities, damages, losses and costs, including,<br />
but not limited to, reasonable attorney’s fees and court costs, such legal expenses to<br />
include costs incurred in establishing the indemnification and other rights agreed to in<br />
this Paragraph, to persons or property, to the extent caused by the negligence,<br />
recklessness, or intentional wrongful misconduct of the Contractor its Subcontractors or<br />
persons employed or utilized by them in the performance of the Contract. Claims by<br />
indemnities for indemnification shall be limited to the amount of Contractor’s insurance<br />
or $1 million per occurrence, whichever is greater. The parties acknowledge that the<br />
amount of the indemnity required hereunder bears a reasonable <strong>com</strong>mercial relationship<br />
to the Contract and it is part of the project specifications or the bid documents, if any.<br />
The indemnification obligations under the Contract shall not be restricted in any way by<br />
any limitation on the amount or type of damages, <strong>com</strong>pensation, or benefits payable by or<br />
for the Contractor under workers’ <strong>com</strong>pensation acts, disability benefits acts, or other<br />
employee benefits acts, and shall extend to and include any actions brought by or in the<br />
55
name of any employee of the Contractor or of any third party to whom Contractor may<br />
subcontract a part or all of the Work. This indemnification shall continue beyond the date<br />
of <strong>com</strong>pletion of the work.<br />
36. EXCLUSION OF CONTRACTOR CLAIMS<br />
In performing its obligations, the Engineer and its Contractors may cause expense for the<br />
Contractor or its subcontractors and equipment or material suppliers. However, those<br />
parties and their sureties shall maintain no direct action against the Engineer, its officers,<br />
employees, agents, and Contractors for any claim arising out of, in connection with, or<br />
resulting from the engineering services performed or required to be performed.<br />
37. TAXES AND CHARGES<br />
The Contractor shall withhold and pay any and all sales and use taxes and all withholding<br />
taxes, whether State or Federal, and pay all Social Security charges and also all State<br />
Unemployment Compensation charges, and pay or cause to be withheld, as the case may<br />
be, any and all taxes, charges, or fees or sums whatsoever, which are now or may hereafter<br />
be required to be paid or withheld under any laws.<br />
38. REQUIREMENTS OF STATE LAW FOR PUBLIC WORKS PROJECTS<br />
When the Contract Documents concern public works of the state or any county,<br />
municipality, or political subdivision created by its laws, the applicable statutes shall apply.<br />
All parties to this Contract shall determine the contents of all applicable statutes and<br />
<strong>com</strong>ply with their provisions throughout the performance of the Contract.<br />
39. CODES, ORDINANCES, PERMITS, AND LICENSES<br />
The Contractor shall keep himself fully informed of all local codes and ordinances, as well<br />
as state and federal laws, which in any manner affect the work herein specified. The<br />
Contractor shall at all times <strong>com</strong>ply with said codes and ordinances, laws, and regulations,<br />
and protect and indemnify the Owner, the Engineer and their respective employees, and its<br />
officers and agents against any claim or liability arising from or based on the violation of<br />
any such laws, ordinances, or regulations. All permits, licenses and inspection fees<br />
necessary for prosecution and <strong>com</strong>pletion of the work shall be secured and paid for by the<br />
Contractor, unless otherwise specified.<br />
A. PERMIT FOR WORK WITHIN LOCAL RIGHTS-OF-WAY<br />
The Contractor shall obtain from the City of <strong>Key</strong> <strong>West</strong> the necessary permits for<br />
work within the rights-of-way. The Contractor shall abide by all regulations and<br />
conditions, including maintenance of traffic, FDOT Standard.<br />
B. NOISE ORDINANCE<br />
The Contractor shall <strong>com</strong>ply with the City of <strong>Key</strong> <strong>West</strong> Noise Ordinance.<br />
56
C. LICENSES<br />
BIDDER must represent that he holds all applicable state, county, and City of<br />
<strong>Key</strong> <strong>West</strong> licenses and permits required to do business as a contractor with<br />
respect to the work described in the Contract Documents before he may Bid on<br />
the project.<br />
The following licenses and certificates are required as a minimum:<br />
A. All licenses or certificates required by federal, state or local statutes or<br />
regulations.<br />
B. A valid Business Tax Receipt issued by the City of <strong>Key</strong> <strong>West</strong>, if required.<br />
C. A valid Certificate of Competency issued by the Building Official of the<br />
City of <strong>Key</strong> <strong>West</strong> which shall remain valid throughout the time period of<br />
the Contract, if required.<br />
Further, the successful BIDDER must, within ten (10) calendar days of Notice of<br />
Award, furnish documentation showing that, as a minimum, he has <strong>com</strong>plied with<br />
the provisions of Chapter 91 of the Code of Ordinances of the City of <strong>Key</strong> <strong>West</strong><br />
in order to enter into the Agreement contained in the Contract Documents.<br />
40. SUPERINTENDENCE<br />
The Contractor shall keep at the project site, <strong>com</strong>petent supervisory personnel. The<br />
Contractor shall designate, in writing, before starting work, a project superintendent who<br />
shall be an employee of the Contractor and shall have <strong>com</strong>plete authority to represent and<br />
to act for the Contractor. Engineer shall be notified in writing prior to any change in<br />
superintendent assignment. The Contractor shall give efficient supervision to the work,<br />
using his best skill and attention. The Contractor shall be solely responsible for all<br />
construction means, methods, techniques, and procedures, and for providing adequate<br />
safety precautions and coordinating all portions of the work under the Contract. It is<br />
specifically understood and agreed that the Engineer, its employees and agents, shall not<br />
have control or charge of and shall not be responsible for the construction means, methods,<br />
techniques, procedures, or for providing adequate safety precautions in connection with the<br />
work under Contract.<br />
40(a). CONTRACTOR'S RESPONSIBILITIES:<br />
A. The Contractor shall employ such superintendents, foremen, and workmen as are<br />
careful and <strong>com</strong>petent. Whenever the Engineer shall determine that any person<br />
employed by the Contractor is in his opinion, in<strong>com</strong>petent, unfaithful, disorderly<br />
or insubordinate, such person shall, upon notice, be discharged from the work and<br />
shall not again be employed on it except with the written consent of the Engineer.<br />
Should the Contractor fail to remove such person or persons, or fail to furnish<br />
suitable or sufficient machinery, equipment or force for the proper prosecution of<br />
the work the Engineer may withhold all estimates which are, or may be<strong>com</strong>e due,<br />
or may suspend the work until such orders are <strong>com</strong>plied with.<br />
57
B. The Contractor shall provide qualified personnel to assist the Engineer in making<br />
field checks, measurements, asbuilt checks, inspection, test runs, and the<br />
necessary quality check work related to the project work. An english speaking<br />
superintendent or foreman shall be onsight at all times.<br />
C. The Contractor shall provide and maintain at his own expense, in a sanitary<br />
condition, such ac<strong>com</strong>modations for the use of his employees as is necessary to<br />
<strong>com</strong>ply with the requirements and regulations of the State and County Boards of<br />
Health. He shall <strong>com</strong>mit no public nuisance.<br />
D. The Contractor shall conduct the work so as to insure the least obstruction to<br />
traffic practicable, and shall provide for the convenience of the general public and<br />
of the residents along and adjacent to the work in a manner satisfactory to the<br />
Engineer. Materials and equipment stored on the work site shall be placed so as<br />
to cause as little obstruction to the public as possible and shall be lighted and<br />
barricaded as hereinafter provided. Keep driveways and entramces serving the<br />
premises clear and available to the Owner and the Owner’s employees at all<br />
times. Do not use these areas for parking or storage of materials and equipment on<br />
site.<br />
E. Unless otherwise expressly stipulated herein, the use of explosives is not<br />
contemplated in the prosecution of the Contract, and in no case will their use be<br />
permitted within a municipality without the written permission of the City<br />
Engineer and a permit issued by the Chief of the Fire Department. Where such<br />
permission for the use of explosives is obtained, the Contractor shall use the<br />
utmost care so as not to endanger life or property, and whenever directed the size<br />
and number of charges shall be reduced. All explosives shall be stored in a secure<br />
manner, and all such storage places shall be marked clearly, "DANGEROUS<br />
EXPLOSIVES", and shall be in care of <strong>com</strong>petent watchmen<br />
41. RECEPTION OF ENGINEER'S COMMUNICATIONS<br />
The superintendent shall receive for the Contractor all <strong>com</strong>munications from the Engineer.<br />
Communications of major importance will be confirmed in writing upon request from the<br />
Contractor.<br />
The Engineer may schedule project meetings for the purposes of discussing and resolving<br />
matters concerning the various elements of the work. The Engineer shall determine the<br />
time and place for these meetings, and the names of persons required being present. The<br />
Contractor shall <strong>com</strong>ply with these attendance requirements and shall also require his/her<br />
Subcontractors to <strong>com</strong>ply.<br />
42. SAFETY<br />
The Contractor shall be solely and <strong>com</strong>pletely responsible for conditions of the jobsite,<br />
including safety of all persons (including employees) and property during performance of<br />
the work. This requirement shall apply continuously and not be limited to normal working<br />
hours. Safety provisions shall conform to U.S. Department of Labor (OSHA), and all other<br />
applicable federal, state, county, and local laws, ordinances, codes, and regulations. Where<br />
any of these are in conflict, the more stringent requirement shall be followed. The<br />
58
Contractor's failure to thoroughly familiarize himself/herself with the aforementioned<br />
safety provisions shall not relieve him from <strong>com</strong>pliance with the obligations and penalties<br />
set forth therein.<br />
The Contractor shall develop and maintain for the duration of this Contract, a safety<br />
program that will effectively incorporate and implement all required safety provisions. The<br />
Contractor shall appoint an employee who is qualified and authorized to supervise and<br />
enforce <strong>com</strong>pliance with the safety program.<br />
The duty of the Engineer to conduct construction review of the work does not include<br />
review or approval of the adequacy of the Contractor's safety program, safety supervisor, or<br />
any safety measures taken in, on, or near the construction site.<br />
The Contractor, as a part of his safety program, shall maintain at hi/hers office or other<br />
well-known place at the jobsite, safety equipment applicable to the work as prescribed by<br />
the aforementioned authorities, all articles necessary for giving first-aid to the injured, and<br />
shall establish the procedure for the immediate removal to a hospital or a doctor's care of<br />
persons (including employees) who may be injured on the jobsite.<br />
If death or serious injuries or serious damages are caused, the accident shall be reported<br />
immediately by telephone or messenger to both the Engineer and the Owner. In addition,<br />
the Contractor must promptly report in writing to the Engineer all accidents whatsoever<br />
arising out of, or in connection with, the performance of the work whether on, or adjacent<br />
to, the site, giving full details and statements of witnesses.<br />
If a claim is made by anyone against the Contractor or any Subcontractor on account of any<br />
accident, the Contractor shall promptly report the facts in writing to the Engineer, giving<br />
full details of the claim.<br />
A. OWNER’S RIGHT TO STOP WORK<br />
If the Contractor or Subcontractor fails to provide adequate safety provisions as<br />
required by the Contract Documents the Owner has the right to stop all<br />
construction work at the location with inadequate safety provisions until adequate<br />
provisions are in place. The Owner shall not be liable for any delays caused by the<br />
Contractor's failure to provide and maintain required safety provisions.<br />
B. CLEANUP PROCEDURES FOR HURRICANE WARNINGS AND<br />
HURRICANE WATCH<br />
In the event the National Oceanographic and Atmospheric Administration<br />
(NOAA) issues a Tropical Storm Watch or a Hurricane Watch for the <strong>Key</strong>s the<br />
Engineer will Contact the Contractor informing him that the Watch has been<br />
established. Within four (4) hours of the notice the Contractor shall provide the<br />
Engineer with a written plan and schedule describing how and when the<br />
Contractor will remove all unnecessary items from the work area and tie down all<br />
necessary supplies and barricades in the event a Tropical Storm Warning or a<br />
Hurricane Warning is issued. The Contractor shall remove all unnecessary items<br />
from work areas and shall tie down all movable objects (under 200 lbs.) The<br />
Engineer will determine "necessary" items. The Owner shall not be liable for any<br />
59
financial hardship or delays caused as a result of demobilization or remobilization<br />
of work due to the above.<br />
C. OCCUPATIONAL SAFETY AND HEALTH<br />
The Contractor shall observe and <strong>com</strong>ply with all applicable local, state, and<br />
federal occupational safety and health regulations during the prosecution of work<br />
under this Contract. In addition, full <strong>com</strong>pliance by the Contractor with the U.S.<br />
Department of Labor's Occupational Safety and Health Standards, as established<br />
in Public Law 91-596, will be required under the terms of this Contract.<br />
43. PROTECTION OF WORK AND PROPERTY<br />
The Contractor shall at all times safely guard and protect from damage the Owner's<br />
property, adjacent property, and his/her own work from injury or loss in connection with<br />
this Contract. All facilities required for protection by federal, state, or municipal laws and<br />
regulations and local conditions must be provided and maintained.<br />
The Contractor shall protect his/her work and materials from damage due to the nature of<br />
the work, the elements, carelessness of other contractors, or from any cause whatever until<br />
the <strong>com</strong>pletion and acceptance of the work. All loss or damages arising out of the nature of<br />
the work to be done under these Contract Documents, or from any unforeseen obstruction<br />
or defects which may be encountered in the prosecution of the work, or from the action of<br />
the elements, shall be sustained by the Contractor.<br />
43(a). HISTORIC PRESERVATION<br />
The Contractor shall <strong>com</strong>ply with Florida Historical Resources Act (Florida Statutes,<br />
Chapter 267) and the regulations of the local historic preservation board as applicable and<br />
protect against the potential loss or destruction of significant historical or archaeological<br />
data, sites, and properties in connection with the project.<br />
44. RESPONSIBILITY OF CONTRACTOR TO ACT IN AN EMERGENCY<br />
In case of an emergency that threatens loss or injury of property, and/or safety of life, the<br />
Contractor shall act, without previous instructions from the Owner or Engineer, as the<br />
situation may warrant. The Contractor shall notify the Engineer thereof immediately<br />
thereafter. Any claim for <strong>com</strong>pensation by the Contractor, together with substantiating<br />
documents in regard to expense, shall be submitted to the Owner through the Engineer and<br />
the amount of <strong>com</strong>pensation shall be determined by agreement.<br />
45. MATERIALS AND APPLIANCES<br />
Unless otherwise stipulated, the Contractor shall provide and pay for all materials, labor,<br />
water, tools, equipment, heat, light, fuel, power, transportation, construction equipment and<br />
machinery, appliances, telephone, sanitary facilities, temporary facilities and other facilities<br />
and incidentals necessary for the execution and <strong>com</strong>pletion of the work.<br />
Unless otherwise specified, all materials shall be new, and both workmanship and materials<br />
shall be of good quality. The Contractor shall, if required, furnish satisfactory evidence as<br />
60
to the kind and quality of materials.<br />
In selecting and/or approving equipment for installation in the project, the Owner and<br />
Engineer assume no responsibility for injury or claims resulting from failure of the<br />
equipment to <strong>com</strong>ply with applicable federal, state, and local safety codes or requirements,<br />
or the safety requirements of a recognized agency, or failure due to faulty design concepts,<br />
or defective workmanship and materials.<br />
46. CONTRACTORS' AND MANUFACTURERS' COMPLIANCE WITH STATE<br />
SAFETY, OSHA, AND OTHER CODE REQUIREMENTS<br />
The <strong>com</strong>pleted work shall include all necessary permanent safety devices, such as<br />
machinery guards and similar ordinary safety items required by the state and federal<br />
(OSHA) industrial authorities and applicable local and national codes. Further, any<br />
features of the work subject to such safety regulations shall be fabricated, furnished, and<br />
installed (including Owner-furnished equipment) in <strong>com</strong>pliance with these requirements.<br />
Contractors and manufacturers of equipment shall be held responsible for <strong>com</strong>pliance with<br />
the requirements included herein. Contractors shall notify all equipment suppliers and<br />
Subcontractors of the provisions of this Article.<br />
47. SUBSTITUTION OF MATERIALS<br />
Except for Owner-selected equipment items, and items where no substitution is clearly<br />
specified, whenever any material, article, device, product, fixture, form, type of<br />
construction, or process is indicated or specified by patent or proprietary name, by name of<br />
manufacturer, or by catalog number, such specifications shall be deemed to be used for the<br />
purpose of establishing a standard of quality and facilitating the description of the material<br />
or process desired. This procedure is not to be construed as eliminating from <strong>com</strong>petition<br />
other products of equal or better quality by other manufacturers where fully suitable in<br />
design, and shall be deemed to be followed by the words "or equal". The Contractor may,<br />
in such cases, submit <strong>com</strong>plete data to the Engineer for consideration of another material,<br />
type, or process, which shall be substantially equal in every respect to that so indicated or<br />
specified. Substitute materials shall not be used unless approved in writing. The Engineer<br />
will be the sole judge of the substituted article or material.<br />
48. TESTS, SAMPLES, AND OBSERVATIONS<br />
The Contractor shall furnish, without extra charge, the necessary test pieces and samples,<br />
including facilities and labor for obtaining the same, as requested by the Engineer. When<br />
required, the Contractor shall furnish certificates of tests of materials and equipment made<br />
at the point of manufacture by a recognized testing laboratory.<br />
The Owner, Engineer, and authorized government agents, and their representatives shall at<br />
all times be provided safe access to the work wherever it is in preparation or progress, and<br />
the Contractor shall provide facilities for such access and for observations, including<br />
maintenance of temporary and permanent access.<br />
If the Specifications, laws, ordinances, or any public authority require any work, to be<br />
specially tested or approved, the Contractor shall give timely notice of its readiness for<br />
observations. If any work should be covered up without approval or consent of the<br />
61
Engineer, it shall, if required by the Engineer, be uncovered for examination at the<br />
Contractor's expense.<br />
The Engineer may order re-examination of questioned work, and, if so ordered, the<br />
Contractor shall uncover the work. If such work is found to be in accordance with the<br />
Contract Documents, the Owner will pay the cost of uncovering, exposure, observation,<br />
inspection, testing and reconstruction. If such work is found to be not in accordance with<br />
the Contract Documents, the Contractor shall correct the defective work, and the cost of<br />
reexamination and correction of the defective work shall be paid by the Contractor.<br />
49. ROYALTIES AND PATENTS<br />
The Contractor shall pay all royalty and licenses fees, unless otherwise specified. The<br />
Contractor shall defend all suits or claims for infringement of any patent rights and shall<br />
save the Owner and the Engineer harmless from any and all loss, including reasonable<br />
attorneys' fees, on account thereof.<br />
50. CONTRACTOR'S RIGHT TO TERMINATE CONTRACT<br />
If the work should be stopped under an order of any court or other public authority for a<br />
period of more than three (3) months, through no act or fault of the Contractor, its<br />
Subcontractors, or respective employees or if the Engineer should fail to make<br />
re<strong>com</strong>mendation for payment to the Owner or return payment request to Contractor for<br />
revision within thirty (30) calendar days after it is due, or if the Owner should fail to pay<br />
the Contractor within thirty (30) calendar days after time specified in Article PARTIAL<br />
PAYMENTS, any sum re<strong>com</strong>mended by the Engineer, then the Contractor may, upon 15<br />
days' written notice to the Owner and the Engineer, stop work or terminate this Contract<br />
and recover from the Owner payment for all acceptable work performed and reasonable<br />
termination expenses, unless said default has been remedied.<br />
51. CORRECTION OF DEFECTIVE WORK DURING WARRANTY PERIOD<br />
The Contractor hereby agrees to make, at his own expense, all repairs or replacements<br />
necessitated by defects in materials or workmanship, provided under terms of this Contract,<br />
and pay for any damage to other works resulting from such defects, which be<strong>com</strong>e evident<br />
within two (2) year after the date of final acceptance of the work or within two (2) year<br />
after the date of substantial <strong>com</strong>pletion established by the Engineer for specified items of<br />
equipment, or within such longer period as may be prescribed by law or by the terms of any<br />
applicable special guarantee required by the Contract Documents. Un-remedied defects<br />
identified for correction during the warranty period but remaining after its expiration shall<br />
be considered as part of the obligations of the warranty. Defects in material, workmanship,<br />
or equipment, which are remedied as a result of obligations of the warranty, shall subject<br />
the remedied portion of the work to an extended warranty period of two (2) year after the<br />
defect has been remedied.<br />
The Contractor further assumes responsibility for a similar guarantee for all work and<br />
materials provided by Subcontractors or manufacturers of packaged equipment<br />
<strong>com</strong>ponents. The effective date for the start of the guarantee or warranty period for<br />
equipment qualifying as substantially <strong>com</strong>plete is defined in Article SUBSTANTIAL<br />
62
COMPLETION, AND Article SUBSTANTIAL COMPLETION DATE, in these General<br />
Conditions.<br />
The Contractor also agrees to hold the Owner and the Engineer harmless from liability of<br />
any kind arising from damage due to said defects. The Contractor shall make all repairs<br />
and replacements promptly upon receipt of written order for same from the Owner. If the<br />
Contractor fails to make the repairs and replacements promptly, or in an emergency where<br />
delay would cause serious risk, or loss, or damage, the Owner may have the defective work<br />
corrected or the rejected work removed and replaced, and the Contractor and his Surety<br />
shall be liable for the cost thereof.<br />
PROGRESS OF THE WORK<br />
52. BEGINNING OF THE WORK<br />
Following execution of the Contract, the Contractor shall meet with the Owner and<br />
Engineer relative to his arrangements for prosecuting the work.<br />
53. SCHEDULES AND PROGRESS REPORTS<br />
Prior to starting the construction, the Contractor shall prepare and submit to the Engineer, a<br />
progress schedule showing the dates on which each part or division of the work is expected<br />
to be started and finished, and a preliminary schedule for submittals. The progress schedule<br />
for submittals shall be brought up to date and submitted to the Engineer at the end of each<br />
month or at such other times the Engineer may request.<br />
The Contractor shall forward to the Engineer, at the end of each month, an itemized report<br />
of the delivery status of major and critical items of purchased equipment and material,<br />
including shop drawings and the status of shop and field fabricated work. These progress<br />
reports shall indicate the date of the purchase order, the current percentage of <strong>com</strong>pletion,<br />
estimated delivery, and cause of delay, if any.<br />
If the <strong>com</strong>pletion of any part of the work or the delivery of materials is behind the<br />
submitted progress schedule, the Contractor shall submit in writing a plan acceptable to the<br />
Owner and Engineer for bringing the work up to schedule.<br />
The Owner shall have the right to withhold progress payments for the work if the<br />
Contractor fails to update and submit the progress schedule and reports as specified.<br />
Unless specifically authorized by the Engineer, work shall not be performed during the<br />
Goombay Festival, Fantasy Fest, Thanksgiving, or Christmas.<br />
54. PROSECUTION OF THE WORK<br />
It is expressly understood and agreed that the time of beginning, rate of progress, and time<br />
of <strong>com</strong>pletion of the work are the essence of this Contract. The work shall be prosecuted at<br />
such time, and in or on such part or parts of the project as may be required, to <strong>com</strong>plete the<br />
project as contemplated in the Contract Documents and the progress schedule.<br />
If the Contractor desires to carry on work at night or outside the regular hours, he shall give<br />
63
timely notice to the Engineer to allow satisfactory arrangements to be made for observing<br />
the work in progress.<br />
55. OWNER'S RIGHT TO RETAIN IMPERFECT WORK<br />
If any part or portion of the work <strong>com</strong>pleted under this Contract shall prove defective and<br />
not in accordance with the Drawings and Specifications, and if the imperfection in the same<br />
shall not be of sufficient magnitude or importance as to make the work dangerous or<br />
unsuitable, or if the removal of such work will create conditions which are dangerous or<br />
undesirable, the Owner shall have the right and authority to retain such work but will make<br />
such deductions in the final payment therefore as may be just and reasonable.<br />
55(a). OWNER’S RIGHT TO STOP WORK<br />
If the Contractor or any subcontractor should fail to provide adequate safety provisions<br />
required by the Contract Documents, including but not limited to maintenance of traffic,<br />
trench safety devices and procedures, safety fencing, barricading, signage or unsafe work<br />
practices, the Owner has the right to issue a Stop Work Notice and stop all construction<br />
work at the location with the inadequate safety provisions until such time that adequate<br />
safety provisions are in place. The Owner shall not be liable for delays caused by the<br />
Contractor's failure to provide and maintain required safety provisions. No extension of<br />
time will be granted to the Contractor for delays occurring due to a Stop Work Notice.<br />
56. OWNER'S RIGHT TO DO WORK<br />
Should the Contractor neglect to prosecute the work in conformance with the Contract<br />
Documents or neglect or refuse at his own cost to remove and replace work rejected by the<br />
Engineer, then the Owner may notify the Surety of the condition, and after ten (10)<br />
calendar days' written notice to the Contractor and the Surety, or without notice if an<br />
emergency or danger to the work or public exists, and without prejudice to any other right<br />
which the Owner may have under Contract, or otherwise, take over that portion of the work<br />
which has been improperly or non-timely executed, and make good the deficiencies and<br />
deduct the cost thereof from the payments then or thereafter due the Contractor.<br />
57. OWNER'S RIGHT TO TRANSFER EMPLOYMENT<br />
If the Contractor should abandon the work or if he should persistently or repeatedly refuse<br />
or should fail to make prompt payment to Subcontractors for material or labor, or to<br />
persistently disregard laws, ordinances, or to prosecute the work in conformance with the<br />
Contract Documents, or otherwise be guilty of a substantial violation of any provision of<br />
the Contract or any laws or ordinance, then the Owner may, without prejudice to any other<br />
right or remedy, and after giving the Contractor and Surety 10 days' written notice, transfer<br />
the employment for said work from the Contractor to the Surety. Upon receipt of such<br />
notice, such Surety shall enter upon the premises and take possession of all materials, tools,<br />
and appliances thereon for the purpose of <strong>com</strong>pleting the work included under this Contract<br />
and employ by Contract or otherwise, any qualified person or persons to finish the work<br />
and provide the materials therefore, in accordance with the Contract Documents, without<br />
termination of the continuing full force and effect of this Contract. In case of such transfer<br />
of employment to such Surety, the Surety shall be paid in its own name on estimates<br />
according to the terms hereof without any right of the Contractor to make any claim for the<br />
same or any part thereof.<br />
64
If, after the furnishing of said written notice to the Surety, the Contractor and the Surety<br />
still fail to make reasonable progress on the performance of the work, the Owner may<br />
terminate the employment of the Contractor and take possession of the premises and of all<br />
materials, tools, and appliances thereon and finish the work by whatever method he may<br />
deem expedient and charge the cost thereof to the Contractor and the Surety. In such case,<br />
the Contractor shall not be entitled to receive any further payment until the work is<br />
finished. If the expense of <strong>com</strong>pleting the Contract, including <strong>com</strong>pensation for additional<br />
managerial and administrative services, shall exceed such unpaid balance, the Contractor<br />
and the Surety shall pay the difference to the Owner.<br />
58. DELAYS AND EXTENSION OF TIME<br />
If the Contractor is delayed in the progress of the work by any act or neglect of the Owner<br />
or the Engineer, or by any separate Contractor employed by the Owner, or by strikes,<br />
lockouts, fire, adverse weather conditions not reasonably anticipated, or acts of Nature, and<br />
if the Contractor, within forty-eight (48) hours of the start of the occurrence, gives written<br />
notice to the Owner of the cause of the potential delay and estimate of the possible time<br />
extension involved, and within ten (10) calendar days after the cause of the delay has been<br />
remedied, the Contractor gives written notice to the Owner of any actual time extension<br />
requested as a result of the aforementioned occurrence, then the Contract time may be<br />
extended by change order for such reasonable time as the Engineer determines. It is agreed<br />
that no claim shall be made or allowed for any damages, loss, or expense which may arise<br />
out of any delay caused by the above referenced acts or occurrences other than claims for<br />
the appropriate extension of time.<br />
No extension of time will be granted to the Contractor for delays occurring to parts of the<br />
work that have no measurable impact on the <strong>com</strong>pletion of the total work under this<br />
Contract. No extension of time will be considered for weather conditions reasonably<br />
anticipated for the area in which the work is being performed. Reasonably anticipated<br />
weather conditions will be based on official records of monthly precipitation and other<br />
historical data. Adverse weather conditions, if determined to be of a severity that would<br />
impact progress of the work, may be considered as cause for an extension of Contract<br />
<strong>com</strong>pletion time.<br />
Delays in delivery of equipment or material purchased by the Contractor or his<br />
Subcontractors, including Owner-selected equipment shall not be considered as a just cause<br />
for delay, unless the Owner determines that for good cause the delay is beyond the control<br />
of the Contractor. The Contractor shall be fully responsible for the timely ordering,<br />
scheduling, expediting, delivery, and installation of all equipment and materials.<br />
Within a reasonable period after the Contractor submits to the Owner a written request for<br />
an extension of time, the Engineer will present his written opinion to the Owner as to<br />
whether an extension of time is justified, and, if so, his re<strong>com</strong>mendation as to the number<br />
of days for time extension. The Owner will make the final decision on all requests for<br />
extension of time.<br />
59. DIFFERING SITE CONDITIONS<br />
The Contractor shall promptly, and before the conditions are disturbed, give a written<br />
65
notice to the Owner and Engineer of:<br />
A. Subsurface or latent physical conditions at the site which differ materially from<br />
those indicated in this contract,<br />
B. Unknown physical conditions at the site, of an unusual nature, which differ<br />
materially from those ordinarily encountered and generally recognized as inherent<br />
in work of the character provided for in the Contract.<br />
The Engineer will investigate the site conditions promptly after receiving the notice. If the<br />
conditions do materially so differ and cause an increase or decrease in the Contractor's cost<br />
of, or the time required for, performing any part of the work under this Contract, whether or<br />
not changed as a result of the conditions, and equitable adjustment shall be made under this<br />
Article and the Contract modified in writing accordingly.<br />
No request by the Contractor for an equitable adjustment to the Contract under this Article<br />
will be allowed, unless the Contractor has given the written notice required; provided that<br />
the time prescribed above for giving written notice may be extended by the Owner.<br />
No request by the Contractor for an equitable adjustment to the Contract for differing site<br />
conditions will be allowed if made after final payment under this Contract.<br />
60. LIQUIDATED DAMAGES<br />
Should the Contractor fail to <strong>com</strong>plete the work, or any part thereof in the time agreed<br />
upon in each Work Order or within such extra time as may have been allowed for delays<br />
by extensions granted as provided in the Contract, the Contractor shall reimburse the<br />
Owner for the additional expense and damage for each calendar day, Sundays, and legal<br />
holidays included, that project outlined in each Work Order remains un<strong>com</strong>pleted after<br />
the Work Order <strong>com</strong>pletion date. Liquidated damages shall be assessed individually<br />
against each Work Order. It is agreed that the amount of such additional expense and<br />
damage incurred by reason of failure to <strong>com</strong>plete the work is the per diem rate, as<br />
stipulated in the Bid. The said amount is hereby agreed upon as a reasonable estimate of<br />
the costs that may be accrued by the Owner after the expiration of the time of <strong>com</strong>pletion.<br />
It is expressly understood and agreed that this amount is not to be considered in the<br />
nature of a penalty, but as liquidated damages that have accrued against the Contractor.<br />
The Owner shall have the right to deduct such damages from any amount due, or that<br />
may be<strong>com</strong>e due the Contractor, or the amount of such damages shall be due and<br />
collectible from the Contractor or Surety.<br />
61. OTHER CONTRACTS<br />
The Owner reserves the right to let other Contracts in connection with the work. The<br />
Contractor shall afford other Contractors reasonable opportunity for the introduction and<br />
storage of their materials and the execution of their work and shall properly connect and<br />
coordinate his work with theirs.<br />
If any part of the work under this Contract depends for proper execution or results upon the<br />
work of any other Contractor, utility service <strong>com</strong>pany or Owner, the Contractor shall<br />
inspect and promptly report to the Engineer in writing any patent or apparent defects to<br />
deficiencies in such work that render it unsuitable for such proper execution and results.<br />
66
The Contractor's failure to so report shall constitute and acceptance of the work by others<br />
as being fit and proper for integration with work under this Contract, except for latent or<br />
non-apparent defects and deficiencies in the work.<br />
62. USE OF PREMISES<br />
The Contractor shall confine his equipment, the storage of materials and the operation of<br />
his workers to limits shown on the Drawings or indicated by law, ordinances, permits, or<br />
directions of the Engineer, and shall not unreasonably encumber the premises with his<br />
materials. The Contractor shall provide, at his own expense, the necessary rights-of-way,<br />
and access to the work, which may be required outside the limits of the Owner's property<br />
and shall furnish the Engineer copies of permits and agreements for use of the property<br />
outside that provided by the Owner.<br />
The Contractor shall not load nor permit any part of the structure to be loaded in any<br />
manner that will endanger the structure, nor shall Contractor subject any part of the work or<br />
adjacent property to stresses or pressures that will endanger it.<br />
63. SUBSTANTIAL COMPLETION DATE<br />
The Engineer may issue a written notice of substantial <strong>com</strong>pletion for the purpose of<br />
establishing the starting date for specific equipment guarantees, and to establish the date<br />
that the Owner will assume the responsibility for the cost of operating such equipment.<br />
Said notice shall not be considered as final acceptance of any portion of the work or relieve<br />
the Contractor from <strong>com</strong>pleting the remaining work within the specified time and in full<br />
<strong>com</strong>pliance with the Contract Documents. See SUBSTANTIAL COMPLETION under<br />
DEFINITIONS of these General Conditions.<br />
64. PERFORMANCE TESTING<br />
Operating equipment and systems shall be performance tested in the presence of the<br />
Engineer to demonstrate <strong>com</strong>pliance with the specified requirements. Performance testing<br />
shall be conducted under the specified design operating conditions or under such simulated<br />
operating conditions as re<strong>com</strong>mended or approved by the Engineer. Such testing will be<br />
scheduled with the Engineer at least one week in advance of the planned date for testing.<br />
65. OWNER'S USE OF PORTIONS OF THE WORK<br />
Following issuance of the written notice of Substantial Completion, the Owner may initiate<br />
operation of the facility. Such use shall not be considered as final acceptance of any<br />
portion of the work, nor shall such use be considered as cause for an extension of the<br />
Contract <strong>com</strong>pletion time, unless authorized by a Change Order issued by the Owner.<br />
66. CUTTING AND PATCHING<br />
The Contractor shall do all cutting, fitting, or patching of his work that may be required to<br />
make its several parts <strong>com</strong>e together properly and fit it to receive or be received by work of<br />
other Contractors shown upon or reasonably implied by the Drawings.<br />
67
67. CLEANING UP<br />
PAYMENT<br />
The Contractor shall, at all times, keep property on which work is in progress and the<br />
adjacent property free from accumulations of waste material or rubbish caused by<br />
employees or by the work. Upon <strong>com</strong>pletion of the construction, the Contractor shall<br />
remove all temporary structures, rubbish, and waste materials resulting from his operations.<br />
68. PAYMENT FOR CHANGE ORDERS<br />
The Owner's request for quotations on alterations to the work shall not be considered<br />
authorization to proceed with the work prior to the issuance of a formal Change Order, nor<br />
shall such request justify any delay in existing work. Quotations for alterations to the work<br />
shall include substantiating documentation with an itemized breakdown of Contractor and<br />
Subcontractor costs, including labor, material, rentals, approved services, overhead, and<br />
profit. Owner may require detailed cost data in order to substantiate the reasonableness of<br />
the proposed costs.<br />
Any <strong>com</strong>pensation paid in conjunction with the terms of a Change Order shall <strong>com</strong>prise<br />
total <strong>com</strong>pensation due the Contractor for the work or alteration defined in the Change<br />
Order. By signing the Change Order, the Contractor acknowledges that the stipulated<br />
<strong>com</strong>pensation includes payment for the work or alteration plus all payment for the<br />
interruption of schedules, extended overhead, delay, or any other impact claim or ripple<br />
effect, and by such signing specifically waives any reservation or claim for additional<br />
<strong>com</strong>pensation in respect to the subject Change Order.<br />
At the Owner's option, payment or credit for any alterations covered by a Change Order<br />
shall be determined by one or a <strong>com</strong>bination of the methods set forth in A, B, or C below,<br />
as applicable:<br />
A. UNIT PRICES<br />
Those unit prices stipulated in the Bid shall be utilized where they are applicable.<br />
In the event the Change Order results in a change in the original quantity that is<br />
materially and significantly different from the original Bid quantity, a new unit<br />
price shall be negotiated upon demand of either party. Unit prices for new items<br />
included in the Change Order shall be negotiated and mutually agreed upon.<br />
B. LUMP SUM<br />
A total lump sum for the work negotiated and mutually acceptable to the Contractor<br />
and the Owner.<br />
Lump sum quotations for modifications to the work shall include substantiating<br />
documentation with an itemized breakdown of Contractor and Subcontractor costs,<br />
including labor, material, rentals, approved services, overhead, and profit, all<br />
calculated as specified under "C" below.<br />
68
C. COST REIMBURSEMENT WORK<br />
The term “cost reimbursement" shall be understood to mean that payment for the<br />
work will be made on a time and expense basis, that is, on an accounting of the<br />
Contractor's forces, materials, equipment, and other items of cost as required and<br />
used to do the work.<br />
If the method of payment cannot be agreed upon prior to the beginning of the work,<br />
and the Owner directs by written Change Order that the work be done on a cost<br />
reimbursement basis, then the Contractor shall furnish labor, and furnish and install<br />
equipment and materials necessary to <strong>com</strong>plete the work in a satisfactory manner<br />
and within a reasonable period of time. For the work performed, payment will be<br />
made for the documented actual cost of the following:<br />
1. Labor including foremen for those hours they are assigned and participating<br />
in the cost reimbursement work (actual payroll cost, including wages, fringe<br />
benefits as established by negotiated labor agreements, labor insurance, and<br />
labor taxes as established by law). No other fixed labor burdens will be<br />
considered, unless approved in writing by the Owner.<br />
2. Material delivered and used on the designated work, including sales tax, if<br />
paid by the Contractor or his Subcontractor.<br />
3. Rental, or equivalent rental cost of equipment, including necessary<br />
transportation for items having a value in excess of one hundred (100)<br />
dollars.<br />
Rental or equivalent rental cost will be allowed for only those days or hours<br />
during which the equipment is in actual use. Rental and transportation<br />
allowances shall not exceed the current rental rates prevailing in the locality.<br />
The rentals allowed for equipment will, in all cases, be understood to cover<br />
all fuel, supplies, repairs, and renewals, and no further allowances will be<br />
made for those items, unless specific agreement to that effect is made.<br />
4. Additional bond, as required and approved by the owner.<br />
5. Additional insurance (other than labor insurance) as required and approved<br />
by the Owner.<br />
In addition to items 1 through 5 above, an added fixed fee for general overhead and profit<br />
shall be negotiated and allowed for the Contractor (or approved Subcontractor) actually<br />
executing the Cost Reimbursement work.<br />
An additional fixed fee shall be negotiated and allowed the Contractor for the<br />
administrative handling of portions of the work that are executed by an approved<br />
Subcontractor. No additional fixed fee will be allowed for the administrative handling of<br />
work executed by a Subcontractor of a Subcontractor, unless by written permission from<br />
the Owner.<br />
The added fixed fees shall be considered to be full <strong>com</strong>pensation, covering the cost of<br />
general supervision, overhead, profit, and any other general expense. The Contractor's<br />
records shall make clear distinction between the direct costs of work paid for on a cost<br />
69
eimbursement basis and the costs of other work. The Contractor shall furnish the Engineer<br />
report sheets in duplicate of each day's cost reimbursement work no later than the working<br />
day following the performance of said work. The daily report sheets shall itemize the<br />
materials used, and shall cover the direct cost of labor and the charges for equipment rental,<br />
whether furnished by the Contractor, Subcontractor or other forces. The daily report sheets<br />
shall provide names or identifications and classifications of workers, the hourly rate of pay<br />
and hours worked, and also the size, type, and identification number of equipment and<br />
hours operated.<br />
Valid copies of vendors’ invoices shall substantiate material charges. Such invoices shall<br />
be submitted with the daily report sheets, or, if not available, they shall be submitted with<br />
subsequent daily report sheets. Said daily report sheets shall be signed by the Contractor or<br />
his authorized agent.<br />
The Owner reserves the right to furnish such materials and equipment as he deems<br />
expedient and the Contractor shall have no claim for profit or added fees on the cost of<br />
such materials and equipment. To receive partial payments and final payment for cost<br />
reimbursement work, the Contractor shall submit to the Engineer, detailed and <strong>com</strong>plete<br />
documented verification of the Contractor's and any of his Subcontractors' actual costs<br />
involved in the cost reimbursement work. Such costs shall be submitted within 30 days<br />
after said work has been performed.<br />
69. PARTIAL PAYMENTS<br />
A. GENERAL<br />
Nothing in this Article shall be construed to affect the right, hereby reserved, to<br />
reject the whole or any part of the aforesaid work, should such work be later found<br />
not to <strong>com</strong>ply with the provisions of the Contract Documents. All estimated<br />
quantities of work for which partial payments have been made are subject to review<br />
and correction on the final estimate. Payment by the Owner and acceptance by the<br />
Contractor of partial payments based on periodic estimates of quantities of work<br />
performed shall not, in any way, constitute acceptance of the estimated quantities<br />
used as a basis for <strong>com</strong>puting the amounts of the partial payments.<br />
B. ESTIMATE<br />
No more than once each month, the Contractor shall submit to the Engineer a<br />
detailed estimate of the amount earned during the preceding month for the<br />
separate portions of the work, and request payment. As used in this Article, the<br />
words "amount earned" means the value, on the date of the estimate for partial<br />
payment, of the work <strong>com</strong>pleted in accordance with the Contract Documents, and<br />
the value of approved materials delivered to the project site suitably stored and<br />
protected prior to incorporation into the work.<br />
The Owner will make payment to the Contractor within forty five (45) calendar<br />
days upon receipt of the written re<strong>com</strong>mendation of payment from the Engineer.<br />
The Engineer will, within seven (7) calendar days after receipt of each request for<br />
payment, both indicate in writing a re<strong>com</strong>mendation of payment and present the<br />
70
equest to Owner, or return the request to Contractor indicating in writing<br />
Engineer's reasons for refusing to re<strong>com</strong>mend payment. In the latter case,<br />
Contractor may, within seven (7) calendar days, make the necessary corrections and<br />
resubmit the request.<br />
Engineer may refuse to re<strong>com</strong>mend the whole or any part of any payment if, in his<br />
opinion, it would be incorrect to make such representations to Owner. Engineer<br />
may also refuse to re<strong>com</strong>mend any such payment, or, because of subsequently<br />
discovered evidence or the results of subsequent inspections or tests, nullify any<br />
such payment previously re<strong>com</strong>mended to such an extent as may be necessary in<br />
Engineer's opinion to protect the Owner from loss because:<br />
1. The work is defective, or <strong>com</strong>pleted work has been damaged requiring<br />
correction or replacement.<br />
2. Written claims have been made against Owner or Liens have been filed in<br />
connection with the work.<br />
3. The Contract Price has been reduced because of Change Orders.<br />
4. Owner has been required to correct defective work or <strong>com</strong>plete the work in<br />
accordance with Article OWNER'S RIGHT TO DO WORK;<br />
5. Of Contractor's unsatisfactory prosecution of the work in accordance with<br />
the Contract Documents; or<br />
6. Contractor's failure to make payment to Subcontractors or for labor,<br />
materials, or equipment.<br />
C. DEDUCTION FROM ESTIMATE<br />
Unless modified in the Supplementary Conditions, deductions from the estimate<br />
will be as described below:<br />
1. The Owner will deduct from the estimate, and retain as part security, ten<br />
(10) percent of the amount earned for work satisfactorily <strong>com</strong>pleted. A<br />
deduction and retainage of ten (10) percent will be made on the estimated<br />
amount earned for approved items of material delivered to and properly<br />
stored at the jobsite but not incorporated into the work. When the work is<br />
fifty (50) percent <strong>com</strong>plete, the Owner may reduce the retainage to five (5)<br />
percent of the dollar value of all work satisfactorily <strong>com</strong>pleted to date<br />
provided the Contractor is making satisfactory progress and there is no<br />
specific cause for a greater retainage. The Owner may reinstate the<br />
retainage up to ten (10) percent if the Owner determines, at his discretion,<br />
that the Contractor is not making satisfactory progress or where there is<br />
other specific cause for such withholding.<br />
71
D. QUALIFICATION FOR PARTIAL PAYMENT FOR MATERIALS<br />
DELIVERED<br />
Unless modified in the Supplementary Conditions, qualification for partial payment<br />
for materials delivered but not yet incorporated into the work shall be as described<br />
below:<br />
1. Materials, as used herein, shall be considered to be those items that are<br />
fabricated and manufactured material and equipment. No consideration<br />
shall be given to individual purchases of less than two hundred (200) dollars<br />
for any one item.<br />
2. To receive partial payment for materials delivered to the site, but not<br />
incorporated in the work, it shall be necessary for the Contractor to include<br />
a list of such materials on the Partial Payment Request. At his sole<br />
discretion, the Engineer may approve items for which partial payment is to<br />
be made. Partial payment shall be based on the Contractor's actual cost for<br />
the materials as evidenced by invoices from the supplier. Proper storage<br />
and protection shall be provided by the Contractor, and as approved by the<br />
Engineer. Final payment shall be made only for materials actually<br />
incorporated in the work and, upon acceptance of the work, all materials<br />
remaining for which advance payments had been made shall revert to the<br />
Contractor, unless otherwise agreed, and partial payments made for these<br />
items shall be deducted from the final payment for the work.<br />
3. Contractor warrants and guarantees that title to all work, materials, and<br />
equipment covered by any Application for Payment, whether incorporated<br />
in the project or not, will pass to Owner at the time of payment free and<br />
clear of all liens, claims, security interests, and encumbrances.<br />
4. If requested by the Engineer, the Contractor shall provide, with subsequent<br />
pay requests, invoices receipted by the supplier showing payment in full has<br />
been made.<br />
E. PAYMENT<br />
After deducting the retainage and the amount of all previous partial payments<br />
made to the Contractor from the amount earned, the amount due will be made<br />
payable to the Contractor. Re<strong>com</strong>mendations for payment received by the Owner<br />
less than forty five (45) calendar days prior to the scheduled day for payment will<br />
not be processed or paid until the following month.<br />
70. CLAIMS FOR EXTRA WORK<br />
In any case where the Contractor deems additional time or <strong>com</strong>pensation will be<strong>com</strong>e due<br />
him under this Contract for circumstances other than those defined in Article DELAYS<br />
AND EXTENSION OF TIME, the Contractor shall notify the Engineer, in writing, of his<br />
intention to make claim for such time or <strong>com</strong>pensation before he begins the work on which<br />
72
he bases the claim, in order that such matters may be settled, if possible, or other<br />
appropriate action taken. The notice of claim shall be in duplicate, in writing, and shall<br />
state the circumstances and the reasons for the claim, but need not state the amount. If such<br />
notification is not given, or if the Engineer is not afforded proper facilities by the<br />
Contractor for keeping strict account of actual costs, then the Contractor hereby agrees to<br />
waive the claim for such additional time or <strong>com</strong>pensation. Such notice by the Contractor,<br />
and fact that the Engineer has kept account of the cost as aforesaid, shall not in any way be<br />
construed as proving the validity of the claim.<br />
No extension of time will be granted to the Contractor for delays resulting from extra work<br />
that have no measurable impact on the <strong>com</strong>pletion of the total Work under this Contract.<br />
Claims for additional time or <strong>com</strong>pensation shall be made in itemized detail and submitted,<br />
in writing, to the Owner and Engineer within ten (10) calendar days following <strong>com</strong>pletion<br />
of that portion of the work for which the Contractor bases his claim. Failure to make the<br />
claim for additional <strong>com</strong>pensation in the manner and within the time specified above shall<br />
constitute waiver of that claim. In case the claim is found to be just, it shall be allowed and<br />
paid for as provided in Article PAYMENT FOR CHANGE ORDERS.<br />
71. RELEASE OF LIENS OR CLAIMS<br />
The Contractor shall indemnify and hold harmless the Owner from all claims for labor and<br />
materials furnished under this Contract. Prior to the final payment, the Contractor shall<br />
furnish to the Owner, as part of his final payment request, a certification that all of the<br />
Contractor's obligations on the project have been satisfied and that all monetary claims and<br />
indebtedness have been paid. The Contractor shall furnish <strong>com</strong>plete and legal effective<br />
releases or waivers, satisfactory to the Owner, of all liens arising out of or filed in<br />
connection with the work.<br />
72. FINAL PAYMENT<br />
Upon <strong>com</strong>pletion of the work, the Contractor shall notify the Engineer, in writing, that he<br />
has <strong>com</strong>pleted it and shall request final payment for that Work Performed. The<br />
Contractor shall be responsible for keeping an accurate and detailed record of his actual<br />
construction. Upon <strong>com</strong>pletion of construction and before final acceptance and payment,<br />
the Contractor shall furnish the Engineer record drawings (if applicable) of his<br />
construction. Upon receipt of a request for final payment and the record drawings, the<br />
Engineer will inspect and, if acceptable, submit to the Owner his re<strong>com</strong>mendation as to<br />
acceptance of the <strong>com</strong>pleted work and as to the final estimate of the amount due the<br />
Contractor. Upon approval of this final estimate by the Owner and <strong>com</strong>pliance by the<br />
Contractor with provisions in Article 71. RELEASE OF LIENS OR CLAIMS, and other<br />
provisions as may be applicable, the Owner shall pay to the Contractor all monies due<br />
him under the provisions of these Contract Documents.<br />
73. NO WAIVER OF RIGHTS<br />
Neither the inspection by the Owner, through the Engineer or any of his employees, nor<br />
any order by the Owner for payment of money, nor any payment for, or acceptance of, the<br />
whole or any part of the work by the Owner or Engineer, nor any extension of time, nor<br />
any possession taken by the owner or its employees, shall operate as a waiver of any<br />
provision of this Contract, or any power herein reserved to the Owner, or any right to<br />
73
damages herein provided, nor shall any waiver of any breach in this Contract be held to be<br />
a waiver of any other or subsequent breach. Acceptance or final payment shall not be final<br />
and conclusive with regards to latent defects, fraud, or such gross mistakes as may amount<br />
to fraud, or as regards the Owner's rights under the warranty.<br />
74. ACCEPTANCE OF FINAL PAYMENT CONSTITUTES RELEASE<br />
The acceptance by the Contractor of the final payment shall release the Owner and the<br />
Engineer, as representatives of the Owner, from all claims and all liability to the Contractor<br />
for all things done or furnished in connection with the work, and every act of the Owner<br />
and others relating to or arising out of the work except claims previously made in writing<br />
and still unsettled. No payment, however, final or otherwise, shall operate to release the<br />
Contractor or his Sureties from obligations under this Contract and the Performance Bond,<br />
Payment Bond, and other bonds and warranties, as herein provided.<br />
74
SUPPLEMENTARY CONDITIONS<br />
REVISIONS AND ADDITIONS TO THE GENERAL CONDITIONS<br />
The General Conditions are hereby revised as follows:<br />
ARTICLE 9 "ENGINEER"<br />
Add the following:<br />
Wherever in these Documents the word "Engineer" appears, it shall be understood<br />
to mean the Owner’s representative overseeing the project for the City.<br />
ARTICLE 34 INSURANCE AND LIABILITY<br />
CONTRACTOR is to secure, pay for, and file with the City of <strong>Key</strong> <strong>West</strong>, prior to <strong>com</strong>mencing<br />
any work under the Contract, all certificates for Workers’ Compensation, Public Liability, and<br />
Property Damage Liability Insurance and such other insurance coverages as may be required by<br />
specifications and addenda thereto, in at least the following minimum amounts with specification<br />
amounts to prevail if greater than minimum amounts indicated. Notwithstanding any other<br />
provision of the Contract, the CONTRACTOR shall provide the minimum limits of liability<br />
insurance coverages as follows:<br />
Auto Liability $1,000,000 Combined Single Limit<br />
General Liability $2,000,000 Aggregate (Per Project)<br />
$2,000,000 Products Aggregate<br />
$1,000,000 Any One Occurrence<br />
$1,000,000 Personal Injury<br />
$ 300,000 Fire Damage/Legal<br />
Additional Umbrella Liability $_,000,000 Occurrence/Aggregate<br />
CONTRACTOR shall furnish an original Certificate of Insurance indicating, and such policy<br />
providing coverage to, City of <strong>Key</strong> <strong>West</strong> named as “Additional Insured” on PRIMARY and<br />
NON CONTRIBUTORY basis utilizing an ISO standard endorsement at least as broad as CG<br />
2010 (11/85) or its Equivalent, (COMBINATION OF CG 20 10 07 04 and CG 20 37 07 04,<br />
providing coverage for <strong>com</strong>pleted operations is acceptable) INCLUDING A “Waiver of<br />
Subrogation” clause in favor of City of <strong>Key</strong> <strong>West</strong> on all policies. CONTRACTOR will maintain<br />
the General Liability and Umbrella Liability insurance coverages summarized above with<br />
coverage continuing in full force including the “additional insured” endorsement until at least 3<br />
years beyond <strong>com</strong>pletion and delivery of the work contracted herein.<br />
Notwithstanding any other provision of the Contract, the CONTRACTOR shall maintain<br />
<strong>com</strong>plete Workers’ Compensation coverage for each and every employee, principal, officer,<br />
representative, or agent of the CONTRACTOR who is performing any labor, services, or<br />
material under the Contract. Further, CONTRACTOR shall additionally maintain the following<br />
minimum limits of coverage:<br />
75
Bodily Injury Each Accident $1,000,000<br />
Bodily Injury by Disease Each Employee $1,000,000<br />
Bodily Injury by Disease Policy Limit $1,000,000<br />
The work being done is on or near a navigable waterway, CONTRACTOR’s Workers’<br />
Compensation policy shall be endorsed to provide USL&H Act (WC 00 01 06 A) and Jones Act<br />
(WC 00 02 01 A) coverage as specified by the City of <strong>Key</strong> <strong>West</strong>. CONTRACTOR shall provide<br />
the City of <strong>Key</strong> <strong>West</strong> with a Certificate of Insurance verifying <strong>com</strong>pliance with the workman’s<br />
<strong>com</strong>pensation coverage as set forth herein and shall provide as often as required by the City of<br />
<strong>Key</strong> <strong>West</strong> such certification which shall also show the insurance <strong>com</strong>pany, policy number,<br />
effective and expiration date, and the limits of workman’s <strong>com</strong>pensation coverage under each<br />
policy.<br />
CONTRACTOR’s insurance policies shall be endorsed to give 30 days’ written notice to the<br />
City of <strong>Key</strong> <strong>West</strong> in the event of cancellation or material change, using form CG 02 24, or its<br />
equivalent.<br />
Certificates of Insurance submitted to the City of <strong>Key</strong> <strong>West</strong> will not be accepted without copies<br />
of the endorsements being requested. This includes additional insured endorsements,<br />
cancellation/material change notice endorsements, and waivers of subrogation. Copies of<br />
USL&H Act and Jones Act endorsements will also be required if necessary. PLEASE ADVISE<br />
YOUR INSURANCE AGENT ACCORDINGLY.<br />
CONTRACTOR will <strong>com</strong>ply with any and all safety regulations required by any agency or<br />
regulatory body including but not limited to OSHA. CONTRACTOR will notify City of <strong>Key</strong><br />
<strong>West</strong> immediately by telephone at (305) 809-3811 of any accident or injury to anyone that<br />
occurs on the jobsite and is related to any of the work being performed by the CONTRACTOR.<br />
SAMPLE ENDORSEMENTS REQUIRED BY ARTICLE 34 ARE INCLUDED AS EXHIBITS A-J<br />
ARTICLE 34<br />
E. “BUILDERS RISK ALL RISK INSURANCE”<br />
Builders Risk All Risk Insurance is not required as part of this contract.<br />
76
Contractor Insurance Requirements for the City of <strong>Key</strong> <strong>West</strong>, Florida<br />
All contractors and subcontractors wishing to perform work for the City of <strong>Key</strong> <strong>West</strong>, Florida, will be required to<br />
<strong>com</strong>ply with the following minimum insurance requirements:<br />
Commercial General Liability Limits:<br />
$2,000,000 Aggregate<br />
$1,000,000 Each Occurrence<br />
$2,000,000 Products-Comp / Op Aggregate<br />
$1,000,000 Personal & Advertising Injury<br />
$300,000 Fire Damage / Legal<br />
Coverage must include the following:<br />
- Contractual Liability - Commercial Form<br />
- CG2010 (1185) or Equivalent - Broad Form Property Damage<br />
- No exclusion for XCU - Premises / Operations<br />
- Products / Completed Operations - Independent Contractors (if any part of the work is<br />
- Personal Injury to be subcontracted out)<br />
Automobile Liability:<br />
Additional Umbrella Liability:<br />
Worker’s Compensation:<br />
Employer’s Liability:<br />
$1,000,000 Combined Single Limit<br />
(Include Hired & Non-Owned Liability)<br />
$0,000,000 Occurrence / Aggregate<br />
Statutory<br />
$1,000,000 Each Accident<br />
$1,000,000 Disease-Policy Limit<br />
$1,000,000 Disease-Each Employee<br />
The City of <strong>Key</strong> <strong>West</strong> confirms that the scope of services specified in the Contract requires work on or near<br />
a navigable waterway. Water description: <strong>Key</strong> <strong>West</strong> <strong>Bight</strong>. Therefore the following coverages will indeed be<br />
required as specified in the contract documents:<br />
• Workers Compensation/Employer Liability<br />
USL&H Coverage (Longshore and Harbor Workers’ Compensation Act) Endorsement WC 000106A<br />
Jones Act Coverage* Endorsement WC 000201A<br />
• Marine Third Part Liability<br />
Protection & Indemnity<br />
$1,000,000 Limit<br />
Note: Jones Act (Crew) coverage may be provided under the P&I policy, if Contractor is using an OWNED vessel<br />
during the course of the work.<br />
The above reflects the minimum requirements for working with the City of <strong>Key</strong> <strong>West</strong>. Any requirements found in a<br />
particular job’s contract that are of a higher standard will prevail.<br />
The City of <strong>Key</strong> <strong>West</strong> must be named as an additional insured under all policies other than worker’s <strong>com</strong>pensation.<br />
Contractor’s or subcontractor’s general liability shall be written on a primary and non-contributory basis.<br />
Certificates of insurance must be ac<strong>com</strong>panied by a copy of the additional insured endorsement (CG 20101185 or<br />
<strong>com</strong>bination of CG20100704 and CG20370704 will be accepted).<br />
Contractors and subcontractors must obtain an endorsement from their carrier that waives and relinquishes any right<br />
of subrogation against the City of <strong>Key</strong> <strong>West</strong> and its agents, representatives, employees, and affiliates they might<br />
possess for any policy of insurance provided under this requirement or under any state or federal worker’s<br />
<strong>com</strong>pensation or employer’s liability act.<br />
Contractor’s policies must be endorsed to give no less than thirty (30) days notice to the City in the event of material<br />
change or cancellation.<br />
The City of <strong>Key</strong> <strong>West</strong> must be given a certificate of insurance showing that the above requirements have been met.<br />
The certificate of insurance must remain current and must include copies of the requested endorsements (additional<br />
insured, cancellation notice, and waiver of subrogation) in order for the City to issue payments to the contractor or<br />
subcontractor.<br />
77
Agreement Articles<br />
2012-09-01 00:00:00.0<br />
U.S. Department of Homeland Security<br />
Washington, D.C. 20472<br />
AGREEMENT ARTICLES<br />
Port Security Grant Program<br />
GRANTEE:<br />
City of <strong>Key</strong> <strong>West</strong> Port<br />
PROGRAM:<br />
Port Security Grant Program<br />
AGREEMENT NUMBER: EMW-2012-PU-00056-S01<br />
TABLE OF CONTENTS<br />
Article I<br />
Summary Description of Project<br />
Article II<br />
Administrative Requirements<br />
Article III GPD - Trafficking Victims Protection Act of 2000<br />
Article IV<br />
GPD - Drug-Free Workplace Regulations<br />
Article V Fly America Act of 1974<br />
Article VI<br />
Lobbying Prohibitions<br />
Article VII<br />
Activities Conducted Abroad<br />
Article VIII<br />
Acknowledgement of Federal Funding from DHS<br />
Article IX<br />
Copyright<br />
Article X<br />
Use of DHS Seal, Logo and Flags<br />
Article XI<br />
DHS Specific Achnowledgements and Assurances<br />
Article XII Civil Rights Act of 1964<br />
Article XIII Civil Right Act of 1968<br />
Article XIV Americans with Disabilities Act of 1990<br />
Article XV Age Discrimination Act of 1975<br />
Article XVI Title IX of the Education Amendments of 1972<br />
Article XVII Rehabilitation Act of 1973<br />
Article XVIII<br />
Limited English Proficiency<br />
- 9 -<br />
88
Article XIX Animal Welfare Act of 1966<br />
Article XX Clean Air Act of 1970 and Clean Water Act of 1977<br />
Article XXI<br />
Protection of Human Subjects<br />
Article XXII National Environmental Policy Act (NEPA) of 1969<br />
Article XXIII National Flood Insurance Act of 1968<br />
Article XXIV Flood Distaster Protection Act of 1973<br />
Article XXV<br />
Article XXVI USA Patriot Act of 2001<br />
Coastal Wetlands Planning, Protection, and Restoration Act<br />
of 1990<br />
Article I - Summary Description of Project<br />
Project 1: Security Fence is approved for funding in the amount of $45,000.<br />
Project 2: <strong>Boat</strong> Lifts is approved for funding in the amount of $45,000.<br />
Article II - Administrative Requirements<br />
The administrative requirements that apply to most DHS award recipients through a grant or cooperative agreement arise from<br />
two sources: - Office of Management and Budget (OMB) Circular A-102, Uniform Administrative Requirements for Grants and<br />
Cooperative Agreements to State and Local Governments (also known as the "A-102 Common Rule"), found under FEMA<br />
regulations at Title 44, Code of Federal Regulations (CFR) Part <strong>13</strong>, "Uniform Administrative Requirements for Grants and<br />
Cooperative Agreements to State and Local Governments." - OMB Circular A-110, Uniform Administrative Requirements for<br />
Grants and Agreements with Institutions of Higher Education, Hospitals, and Other Non-Profit Organizations, relocated to 2<br />
CFR Part 215. The requirements for allowable costs/cost principles are contained in the A-102 Common Rule, OMB Circular<br />
A-110 (2 CFR § 215.27), DHS program legislation, Federal awarding agency regulations, and the terms and conditions of the<br />
award. The four costs principles circulars are as follows: - OMB Circular A-21, Cost Principles for Educational Institutions,<br />
relocated to 2 CFR Part 220. - OMB Circular A-87, Cost Principles for State, Local, and Indian Tribal Governments, relocated<br />
to 2 CFR Part 225. - OMB Circular A-122, Cost Principles for Non-Profit Organizations, relocated to 2 CFR Part 230. - OMB<br />
Circular A-<strong>13</strong>3, Audits of States, Local Governments and Non-Profit Organizations.<br />
Article III - GPD - Trafficking Victims Protection Act of 2000<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of the government-wide award term which implements<br />
Section 106(g) of the Trafficking Victims Protection Act (TVPA) of 2000, as amended (22 U.S.C. § 7104), located at 2 CFR<br />
Part 175. This is implemented in accordance with OMB Interim Final Guidance, Federal Register, Volume 72, No. 218,<br />
November <strong>13</strong>, 2007.In accordance with the statutory requirement, in each agency award under which funding is provided<br />
to a private entity, Section 106(g) of the TVPA, as amended, requires the agency to include a condition that authorizes the<br />
agency to terminate the award, without penalty, if the recipient or a subrecipient - (a) Engages in severe forms of trafficking in<br />
persons during the period of time that the award is in effect; (b) Procures a <strong>com</strong>mercial sex act during the period of time that<br />
the award is in effect; or (c) Uses forced labor in the performance of the award or subawards under the award. Full text of the<br />
award term is provided at 2 CFR § 175.15.<br />
Article IV - GPD - Drug-Free Workplace Regulations<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of the Drug-Free Workplace Act of 1988 (41 U.S.C. §<br />
701 et seq.), which requires that all organizations receiving grants from any Federal agency agree to maintain a drug-free<br />
workplace. The recipient must notify the awarding office if an employee of the recipient is convicted of violating a criminal<br />
drug statute. Failure to <strong>com</strong>ply with these requirements may be cause for debarment. These regulations are codified at 2 CFR<br />
3001.<br />
Article V - Fly America Act of 1974<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of the Preference for U.S. Flag Air Carriers: Travel<br />
supported by U.S. Government funds requirement, which states preference for the use of U.S. flag air carriers (air carriers<br />
holding certificates under 49 U.S.C. § 41102) for international air transportation of people and property to the extent that such<br />
service is available, in accordance with the International Air Transportation Fair Competitive Practices Act of 1974 (49 U.S.C.<br />
- 10 -<br />
89
§ 40118) and the interpretative guidelines issued by the Comptroller General of the United States in the March 31, 1981,<br />
amendment to Comptroller General Decision B<strong>13</strong>8942.<br />
Article VI - Lobbying Prohibitions<br />
None of the funds provided under an award may be expended by the recipient to pay any person to influence, or attempt to<br />
influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee<br />
of a Member of Congress in connection with any Federal action concerning the award or renewal of any Federal contract,<br />
grant, loan, cooperative agreement. These lobbying prohibitions can be found at 31 U.S.C. § <strong>13</strong>52.<br />
Article VII - Activities Conducted Abroad<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements that project activities carried on outside the United<br />
States are coordinated as necessary with appropriate government authorities and that appropriate licenses, permits, or<br />
approvals are obtained.<br />
Article VIII - Acknowledgement of Federal Funding from DHS<br />
All recipients of financial assistance will <strong>com</strong>ply with requirements to acknowledge Federal funding when issuing statements,<br />
press releases, requests for proposals, bid invitations, and other documents describing projects or programs funded in whole<br />
or in part with Federal funds.<br />
Article IX - Copyright<br />
All recipients of financial assistance will <strong>com</strong>ply with requirements that publications or other exercise of copyright for any<br />
work first produced under Federal financial assistance awards hereto related unless the work includes any information that is<br />
otherwise controlled by the Government (e.g., classified information or other information subject to national security or export<br />
control laws or regulations). For any scientific, technical, or other copyright work based on or containing data first produced<br />
under this award, including those works published in academic, technical or professional journals, symposia proceedings,<br />
or similar works, the recipient grants the Government a royalty-free, nonexclusive and irrevocable license to reproduce,<br />
display, distribute copies, perform, disseminate, or prepare derivative works, and to authorize others to do so, for Government<br />
purposes in all such copyrighted works. The recipient shall affix the applicable copyright notices of 17 U.S.C. § 401 or 402 and<br />
an acknowledgement of Government sponsorship (including award number) to any work first produced under an award.<br />
Article X - Use of DHS Seal, Logo and Flags<br />
All recipients of financial assistance must obtain DHS's approval prior to using the DHS seal(s), logos, crests or reproductions<br />
of flags or likenesses of DHS agency officials, including use of the United States Coast Guard seal, logo, crests or<br />
reproductions of flags or likenesses of Coast Guard officials.<br />
Article XI - DHS Specific Achnowledgements and Assurances<br />
All recipients of financial assistance must acknowledge and agree-and require any subrecipients, contractors, successors,<br />
transferees, and assignees acknowledge and agree-to <strong>com</strong>ply with applicable provisions governing DHS access to records,<br />
accounts, documents, information, facilities, and staff. 1. Recipients must cooperate with any <strong>com</strong>pliance review or <strong>com</strong>plaint<br />
investigation conducted by DHS. 2. Recipients must give DHS access to and the right to examine and copy records, accounts,<br />
and other documents and sources of information related to the grant and permit access to facilities, personnel, and other<br />
individuals and information as may be necessary, as required by DHS regulations and other applicable laws or program<br />
guidance. 3. Recipients must submit timely, <strong>com</strong>plete, and accurate reports to the appropriate DHS officials and maintain<br />
appropriate backup documentation to support the reports. 4. Recipients must <strong>com</strong>ply with all other special reporting, data<br />
collection, and evaluation requirements, as prescribed by law or detailed in program guidance. 5. If, during the past three<br />
years, the recipient has been accused of discrimination on the grounds of race, color, national origin (including limited English<br />
proficiency), sex, age, disability, religion, or familial status, the recipient must provide a list of all such proceedings, pending<br />
or <strong>com</strong>pleted, including out<strong>com</strong>e and copies of settlement agreements to the DHS awarding office and the DHS Office of Civil<br />
Rights and Civil Liberties. 6. In the event any court or administrative agency makes a finding of discrimination on grounds of<br />
race, color, national origin (including limited English proficiency), sex, age, disability, religion, or familial status against the<br />
recipient, or the recipient settles a case or matter alleging such discrimination, recipients must forward a copy of the <strong>com</strong>plaint<br />
and findings to the DHS Component and/or awarding office. The United States has the right to seek judicial enforcement of<br />
these obligations.<br />
Article XII - Civil Rights Act of 1964<br />
- 11 -<br />
90
ll recipients of financial assistance will <strong>com</strong>ply with the requirements of Title VI of the Civil Rights Act of 1964 (42 U.S.C.<br />
§ 2000d et seq.), which provides that no person in the United States will, on the grounds of race, color, or national origin,<br />
be excluded from participation in, be denied the benefits of, or be subjected to discrimination under any program or activity<br />
receiving Federal financial assistance.<br />
Article XIII - Civil Right Act of 1968<br />
All recipients of financial assistance will <strong>com</strong>ply with Title VIII of the Civil Rights Act of 1968, which prohibits recipients<br />
from discriminating in the sale, rental, financing, and advertising of dwellings, or in the provision of services in connection<br />
therewith, on the basis of race, color, national origin, religion, disability, familial status, and sex (42 U.S.C.§ 3601 et seq.),<br />
as implemented by the Department of Housing and Urban Development at 24 CFR Part 100. The prohibition on disability<br />
discrimination includes the requirement that new multifamily housing with four or more dwelling units-i.e., the public and<br />
<strong>com</strong>mon use areas and individual apartment units (all units in buildings with elevators and ground-floor units in buildings<br />
without elevators)-be designed and constructed with certain accessible features (see 24 CFR § 100.201).<br />
Article XIV - Americans with Disabilities Act of 1990<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of Titles I, II, and III of the Americans with Disabilities<br />
Act, which prohibits recipients from discriminating on the basis of disability in the operation of public entities, public and private<br />
transportation systems, places of public ac<strong>com</strong>modation, and certain testing entities (42 U.S.C. §§ 12101-122<strong>13</strong>).<br />
Article XV - Age Discrimination Act of 1975<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of the Age Discrimination Act of 1975 (42 U.S.C. § 6101<br />
et seq.), which prohibits discrimination on the basis of age in any program or activity receiving Federal financial assistance.<br />
Article XVI - Title IX of the Education Amendments of 1972<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of Title IX of the Education Amendments of 1972<br />
(20 U.S.C. § 1681 et seq.), which provides that no person in the United States will, on the basis of sex, be excluded from<br />
participation in, be denied the benefits of, or be subjected to discrimination under any educational program or activity receiving<br />
Federal financial assistance. These regulations are codified at 44 CFR Part 19.<br />
Article XVII - Rehabilitation Act of 1973<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of Section 504 of the Rehabilitation Act of 1973, 29<br />
U.S.C. § 794, as amended, which provides that no otherwise qualified handicapped individual in the United States will, solely<br />
by reason of the handicap, be excluded from participation in, be denied the benefits of, or be subjected to discrimination under<br />
any program or activity receiving Federal financial assistance. These requirements pertain to the provision of benefits or<br />
services as well as to employment.<br />
Article XVIII - Limited English Proficiency<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of Executive Order <strong>13</strong>166, Improving Access to<br />
Services for Persons with Limited English Proficiency, and resulting agency guidance, national origin and resulting agency<br />
guidance, national origin discrimination includes discrimination on the basis of limited English proficiency (LEP). To ensure<br />
<strong>com</strong>pliance with Title VI, recipients must take reasonable steps to ensure that LEP persons have meaningful access to your<br />
programs. Meaningful access may entail providing language assistance services, including oral and written translation, where<br />
necessary. Recipients are encouraged to consider the need for language services for LEP persons served or encountered<br />
both in developing budgets and in conducting programs and activities. For assistance and information regarding LEP<br />
obligations, go to http://www.lep.gov.<br />
Article XIX - Animal Welfare Act of 1966<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of the Animal Welfare Act, as amended (7 U.S.C. §<br />
2<strong>13</strong>1 et seq.), which requires that minimum standards of care and treatment be provided for vertebrate animals bred for<br />
<strong>com</strong>mercial sale, used in research, transported <strong>com</strong>mercially, or exhibited to the public. Recipients must establish appropriate<br />
policies and procedures for the humane care and use of animals based on the Guide for the Care and Use of Laboratory<br />
Animals and <strong>com</strong>ply with the Public Health Service Policy and Government Principles Regarding the Care and Use of<br />
Animals.<br />
Article XX - Clean Air Act of 1970 and Clean Water Act of 1977<br />
- 12 -<br />
91
All recipients of financial assistance will <strong>com</strong>ply with the requirements of 42 U.S.C. § 7401 et seq. and Executive Order 11738,<br />
which provides for the protection and enhancement of the quality of the nation's air resources to promote public health and<br />
welfare and for restoring and maintaining the chemical, physical, and biological integrity of the nation's waters is considered<br />
research for other purposes.<br />
Article XXI - Protection of Human Subjects<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of the Federal regulations at 45 CFR Part 46,<br />
which requires that recipients <strong>com</strong>ply with applicable provisions/law for the protection of human subjects for purposes<br />
of research. Recipients must also <strong>com</strong>ply with the requirements in DHS Management Directive 026-04, Protection of<br />
Human Subjects, prior to implementing any work with human subjects. For purposes of 45 CFR Part 46, research means<br />
a systematic investigation, including research, development, testing, and evaluation, designed to develop or contribute to<br />
general knowledge. Activities that meet this definition constitute research for purposes of this policy, whether or not they are<br />
conducted or supported under a program that is considered research for other purposes. The regulations specify additional<br />
protections for research involving human fetuses, pregnant women, and neonates (Subpart B); prisoners (Subpart C); and<br />
children (Subpart D). The use of autopsy materials is governed by applicable State and local law and is not directly regulated<br />
by 45 CFR Part 46.<br />
Article XXII - National Environmental Policy Act (NEPA) of 1969<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of the National Environmental Policy Act (NEPA),<br />
as amended, 42 U.S.C. § 4331 et seq., which establishes national policy goals and procedures to protect and enhance<br />
the environment, including protection against natural disasters. To <strong>com</strong>ply with NEPA for its grant-supported activities,<br />
DHS requires the environmental aspects of construction grants (and certain non-construction projects as specified by the<br />
Component and awarding office) to be reviewed and evaluated before final action on the application.<br />
Article XXIII - National Flood Insurance Act of 1968<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of Section <strong>13</strong>06(c) of the National Flood Insurance Act,<br />
as amended, which provides for benefit payments under the Standard Flood Insurance Policy for demolition or relocation<br />
of a structure insured under the Act that is located along the shore of a lake or other body of water and that is certified by<br />
an appropriate State or local land use authority to be subject to imminent collapse or subsidence as a result of erosion or<br />
undermining caused by waves or currents of water exceeding anticipated cyclical levels. These regulations are codified at 44<br />
CFR Part 63.<br />
Article XXIV - Flood Distaster Protection Act of 1973<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of the Flood Disaster Protection Act of 1973, as<br />
amended (42 U.S.C. § 4001 et seq.), which provides that no Federal financial assistance to acquire, modernize, or construct<br />
property may be provided in identified flood-prone <strong>com</strong>munities in the United States, unless the <strong>com</strong>munity participates in the<br />
National Flood Insurance Program and flood insurance is purchased within one year of the identification. The flood insurance<br />
purchase requirement applies to both public and private applicants for DHS support. Lists of floodprone areas that are eligible<br />
for flood insurance are published in the Federal Register by FEMA.<br />
Article XXV - Coastal Wetlands Planning, Protection, and Restoration Act of 1990<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of Executive Order 11990, which provides that federally<br />
funded construction and improvements minimize the destruction, loss, or degradation of wetlands. The Executive Order<br />
provides that, in furtherance of Section 101(b)(3) of NEPA (42 U.S.C. § 4331(b)(3)), Federal agencies, to the extent permitted<br />
by law, must avoid undertaking or assisting with new construction located in wetlands unless the head of the agency finds<br />
that there is no practicable alternative to such construction, and that the proposed action includes all practicable measures<br />
to minimize harm to wetlands that may result from such use. In making this finding, the head of the agency may take into<br />
account economic, environmental, and other pertinent factors. The public disclosure requirement described above also<br />
pertains to early public review of any plans or proposals for new construction in wetlands. This is codified at 44 CFR Part 9.<br />
Article XXVI - USA Patriot Act of 2001<br />
All recipients of financial assistance will <strong>com</strong>ply with the requirements of the Uniting and Strengthening America by Providing<br />
Appropriate Tools Required to Intercept and Obstruct Terrorism Act (USA PATRIOT Act), which amends 18 U.S.C. §§<br />
175-175c. Among other things, it prescribes criminal penalties for possession of any biological agent, toxin, or delivery system<br />
of a type or in a quantity that is not reasonably justified by a prophylactic, protective, bona fide research, or other peaceful<br />
- <strong>13</strong> -<br />
92
purpose. The act also establishes restrictions on access to specified materials. "Restricted persons," as defined by the act,<br />
may not possess, ship, transport, or receive any biological agent or toxin that is listed as a select agent.<br />
- 14 -<br />
93
PART 4<br />
SCOPE OF WORK<br />
94
KEY WEST BIGHT FERRY TERMINAL BOAT LIFTS<br />
Selected Bidder shall be responsible for the design, purchase, permitting and installation of all<br />
<strong>com</strong>ponents necessary to <strong>com</strong>plete two (2) side elevator boat lifts, each with a boarding platform, at <strong>Key</strong><br />
<strong>West</strong> <strong>Bight</strong> <strong>Ferry</strong> <strong>Terminal</strong>.<br />
Installation of two (2) Marine Grade Aluminum Side Elevator <strong>Boat</strong> Lifts designed with a lifting capacity<br />
of 18,000 lbs.<br />
SPECIFICATIONS for two (2) model LBL 170 Side Elevator <strong>Boat</strong> Lift<br />
Manufactured by Lifetime <strong>Boat</strong> Lifts, Inc. (Formerly ABL <strong>Boat</strong> Lifts, Inc.)<br />
10120 Betsy Parkway, St. James City, FL 33956<br />
• Model LBL 170 Marine Grade Aluminum Side Elevator <strong>Boat</strong> Lift (or equal) Maximum 18,000<br />
lbs. Capacity each with a boarding platform.<br />
• All Aluminum <strong>Boat</strong> Lift Parts are 6061T Marine Grade Aluminum .<br />
• All Bolts and Pins are Stainless Steel<br />
• Lifting arms consist of an engineered Heavy Duty 10” x 7” Structurally Welded Aluminum Box<br />
Beam Combined with a Pair of Upper and Lower 2 ½” x 8” Pivoting and Compensating (4)Wheel<br />
Sets (8 Wheels per Car Arm) Integrated into a Heavy Duty Upper Aluminum All Welded Frame.<br />
This Car Arm is a One Piece Non-Adjustable Welded Structure. There are Two Car Arms per<br />
LBL 170 <strong>Boat</strong> Lift. The Two Car Arms are connected together with an adjustable aluminum X-<br />
Brace assembly<br />
• Each of the Two Super High Speed Drive Lifting Systems are driven by a 2 HP Electric TEFC<br />
Motor Direct Coupling Double Reduction Heavy Duty Enclosed Gearbox into a 1 ¾” O.D.<br />
Stainless Steel Drive Shaft and through bolted to a 3 ½” O.D. Heat Treated Hardened Machine<br />
Grooved Aluminum Drum Winder which is Enclosed in an Aluminum Housing. Lifting Speed is<br />
48” per minute.<br />
• The <strong>Boat</strong> will Rest on the Exclusive LBL “Pivoting” All Aluminum Bunk System, which<br />
includes fully adjustable All Aluminum Cradle Bunks with Heavy Duty High Density Fender<br />
Material<br />
• The Lifting Cables are 3/8” Diameter Stainless Steel Aircraft Style Cables<br />
• The Fully Adjustable Guide Pole System consists of a 3” O.D. x 5 Ft. Heavy Duty Aluminum<br />
Pipe inserted inside of a 4 “ O.D x 10’ High White PVC Heavy Wall Pipe.<br />
• The Underwater Cross Brace is a 3 ½” x 5 ½” I-beam.<br />
• The Top Brace is a 3” X 3” X 3/8” Aluminum Angle<br />
• Four Wireless Waterproof Dual Motor Radio Remote Control (to be installation by others) and<br />
alternate manual operation included with each LBL 170 <strong>Boat</strong> Lift<br />
95
Project Requirements<br />
• Contractor is responsible for all associated costs for the purchase and installation of<br />
<strong>com</strong>plete boat lifts.<br />
• Two (2) radio remote controls for each lift.<br />
• Contractor is required to supply all documents necessary for grant reimbursement.<br />
• Contractor will be responsible for contracting with and paying for a licensed engineer to<br />
develop signed and sealed drawings that are in accordance with local, state and federal<br />
regulations and guidelines.<br />
• Contractor will be responsible for as-built drawings and project manuals at project<br />
closeout.<br />
• Equipment and installation will have a two year warranty on parts and labor.<br />
• Contractor is responsible for obtaining all local, state & federal permits and paying for all<br />
fees associated with permits.<br />
96
PART 5<br />
SITE PHOTOS<br />
97