fufonk ifji - irpmu.railnet.gov.in
fufonk ifji - irpmu.railnet.gov.in
fufonk ifji - irpmu.railnet.gov.in
Create successful ePaper yourself
Turn your PDF publications into a flip-book with our unique Google optimized e-Paper software.
IRPMU<br />
INDIAN RAILWAYS PROJECT MANAGEMENT UNIT<br />
SHIVAJI BRIDGE (IRCOT Complex),<br />
NEW DELHI – 110 001<br />
Tender Document<br />
Design, Supply, Installation and<br />
commission<strong>in</strong>g of IP DSLAM at<br />
various locations over Northern &<br />
North Central Railways and Central<br />
Organization of Railway<br />
Electrification<br />
Tender No. IRPMU/ W / 2008/144/ IP DSLAM (NR & NCR) dated 08.02.2008<br />
Copy No.___<br />
Sold to M/s …………….<br />
Price Rs. 10000/-<br />
By Post Rs. 10500/-
INDEX<br />
SECTION CHAPTER SUBJECT<br />
I 1 Tender Notice<br />
2 Preamble<br />
3 Schedule of Requirement<br />
II 1 Instructions to tenderer &<br />
Conditions of tender<strong>in</strong>g<br />
2 Special conditions of contract<br />
3 Forms of tenderer etc.<br />
III<br />
Technical Specification<br />
1 Technical Overview<br />
2 Equipment Requirement &<br />
Configuration<br />
3 Technical Specifications of IP<br />
DSLAM<br />
4 Technical Specifications of NMS /<br />
EMS<br />
5 IP DSLAM Equipment<br />
Characteristics<br />
6 Technical Specifications of ADSL<br />
Modem<br />
7 Technical Specifications of Router<br />
8 Technical Specifications of Layer –<br />
3 Switches<br />
9 Technical Specifications of ADSL<br />
L<strong>in</strong>e Tester<br />
1
Section – I<br />
Chapter – 1<br />
Tender Notice<br />
2
Hkkjrh; jsy ifj;kstuk izcU/ku bdkbZ<br />
bjdkWV ifjlj] f'kokth fczt ('kadj ekfdZV ds ihNs),<br />
ubZ fnYyh & 110001<br />
nwjHkk"k% 91&11&23412260 @ 23414161] QSDl% 91&11&23412556<br />
izFake 'kqf/n i=<br />
<strong>fufonk</strong> la-% vkbZvkjih,e;w@MCY;w@2008@144@ Mh,l,y,,e (,uvkj ,oa ,ulhvkj) fnukad<br />
08-02-08<br />
25-2-08<br />
dk;Z dk<br />
uke<br />
mRrj jsyos] mRrj e/; jsyos ,oa dsUnzh; jsy fo|qfRkdj.k laxBu ds fofHkUu<br />
LFkkuksa ij vkbZih Mh,l,y,,e dk;ksZ dk vfHkdYi] iwrhZ] laLFkkiu] ijh{k.k ,oa<br />
pkyw djuk<br />
mijkssDr <strong>fufonk</strong> lwpuk es U;wure ;ksX;rk ekun.M ds vUrxZr le:i dk;Z dk vFkZ vkbZih<br />
Mh,l,y,,e dk;ksZ dk vfHkdYi] fofuekZ.k] iwrhZ] laLFkkiu] ijh{k.k ,oa pkyw djuk ds<br />
LFkku ij vkbZih vk/kkfjr usVodZ dk vfHkdYi] fofuekZ.k] iwrhZ] laLFkkiu] ijh{k.k ,oa<br />
pkyw djauk i
TENDER NOTICE<br />
E-mail address: adm@<strong>irpmu</strong>.<strong>railnet</strong>.<strong>gov</strong>.<strong>in</strong> Tel.: +91-11-2341 2260 /2341 4161<br />
Fax: +91-11-2341 2556<br />
Tender No.: IRPMU/ W / 2008/144/ IP DSLAM (NR & NCR)<br />
Dated: 08/02/2008<br />
Chief Adm<strong>in</strong>istrative Officer, Indian Railway Project Management Unit, New Delhi, for<br />
and on behalf of the President of India <strong>in</strong>vites sealed Open tenders from the established,<br />
reliable and experienced manufacturers or their authorized agents with sufficient proven<br />
experience <strong>in</strong> similar work as per follow<strong>in</strong>g details.<br />
Name of Work:<br />
Design, Supply, Installation and commission<strong>in</strong>g of IP DSLAM<br />
at various locations over Northern & North Central Railways<br />
and Central Organization of Railway Electrification.<br />
Approximate cost<br />
Rs. 20,237,370<br />
Earnest Money<br />
Price of Tender Docs<br />
(Non refundable):<br />
Forward<strong>in</strong>g Charges<br />
(if required by post / courier)<br />
Completion Period:<br />
Rs. 251190/-<br />
(Rupees Two lakhs fifty one thousand one hundred n<strong>in</strong>ety<br />
only)<br />
Rs 10000.00<br />
(Rupees ten thousand only)<br />
Rs 500.00<br />
(Rupees five hundred only)<br />
6 Months<br />
Sale of Tender Documents Between 1030 hrs to 1500 hrs from 22/02/2008 to 24/03/2008<br />
Last Date / Time of Tender<br />
Receipt<br />
Tender Open<strong>in</strong>g Date / Time<br />
Place of Open<strong>in</strong>g<br />
Validity of Offer<br />
25/03/2008 up to 1430 Hrs<br />
25/03/2008 at 1500 Hrs.<br />
In the office of CAO/IRPMU, IRCOT complex, Shivaji<br />
Bridge, New Delhi.<br />
6 months from date of open<strong>in</strong>g.<br />
Tenders without Earnest Money will be summarily rejected.<br />
The tender documents can be obta<strong>in</strong>ed from the office of Chief Adm<strong>in</strong>istrative Officer (IRPMU),<br />
IRCOT Complex, Shivaji Bridge, New Delhi - 110001 Between 1030 hrs to 1500 hrs from<br />
22/02/2008 to 24/03/2008 on production of Pay order/Demand Draft from a<br />
Nationalized/Scheduled Indian Bank drawn <strong>in</strong> favour of Dy FA & CAO / IRPMU New Delhi<br />
towards the cost of tender document shown above. Tender document can also be purchased<br />
through post / courier by send<strong>in</strong>g Demand Draft / Pay Order for Rs 10500 (Rupees ten thousand<br />
five hundred only) drawn <strong>in</strong> favour of Dy FA & CAO / IRPMU. However IRPMU will not be<br />
responsible for any forward<strong>in</strong>g delay. Tender document can also be downloaded from IRPMU’s<br />
website www.<strong>irpmu</strong>.<strong>railnet</strong>.<strong>gov</strong>.<strong>in</strong>. Tenderer submitt<strong>in</strong>g downloaded tender document, should<br />
submit cost of tender document as given above <strong>in</strong> the form of Pay order/Demand Draft from a<br />
Nationalized/Scheduled IndianBank drawn <strong>in</strong> favour of Dy FA & CAO / IRPMU New Delhi<br />
along with bid. Payment to contractor will be made through EFT/ECS.<br />
M<strong>in</strong>imum Qualification Eligibility Criteria:<br />
4
1. The tenderer should have completed successfully at least one work of similar nature to<br />
that of this tender cost<strong>in</strong>g not less than 35% of advertised value of the tender, <strong>in</strong> the last<br />
three f<strong>in</strong>ancial years (i.e. current year and three previous f<strong>in</strong>ancial years.) Mean<strong>in</strong>g of<br />
similar work for this tender is as under:<br />
“Supply, Installation, test<strong>in</strong>g and commission<strong>in</strong>g of IP DSLAM work”<br />
2. As a proof of sufficient f<strong>in</strong>ancial capacity and organizational resources, contractor should<br />
have received total payment aga<strong>in</strong>st satisfactory execution of completed/ongo<strong>in</strong>g works<br />
(of all types) dur<strong>in</strong>g preced<strong>in</strong>g three years as per current ITCC/Audited Balance Sheet of<br />
a value not less than 150% of the advertised cost of work.<br />
If the tenderer deliberately give(s) wrong <strong>in</strong>formation whose credentials/documents <strong>in</strong> his/their<br />
tenders and thereby create(s) circumstances for acceptance of his/their tender, Railway reserves<br />
the right to reject such tender at any stage, besides, shall suspend the Bus<strong>in</strong>ess for one year.<br />
Note: 1.<br />
Tender Forms are non transferable.<br />
2. In case, any of the days here<strong>in</strong> mentioned above is declared a holiday or closed on<br />
any account, the said date, shall automatically be substituted by the date of the next<br />
work<strong>in</strong>g day.<br />
3. The tender notice & tender document can also be seen at official website of IRPMU<br />
"www.<strong>irpmu</strong>.<strong>railnet</strong>.<strong>gov</strong>.<strong>in</strong>".<br />
(Shailesh Tiwari)<br />
Dy.CSTE/HQ<br />
Indian Railway Project Management Unit<br />
New Delhi, India<br />
for & behalf of the President of India<br />
5
Hkkjrh; jsy ifj;kstuk izcU/ku bdkbZ<br />
bjdkWV ifjlj] f'kokth fczt ('kadj ekfdZV ds ihNs),<br />
ubZ fnYyh & 110001<br />
<strong>fufonk</strong> lwpuk<br />
nwjHkk"k% 91&11&23412260 @ 23414161] QSDl% 91&11&23412556<br />
<strong>fufonk</strong> la-% vkbZvkjih,e;w@MCY;w@2008@144@ Mh,l,y,,e (,uvkj ,oa ,ulhvkj)<br />
fnukad 08-02-08<br />
Hkkjr ds jk"Vzifr ds fy;s dh vksj ls eq[; iz'kklfud vf/kdkjh] Hkkjrh;<br />
jsyos ifj;kstuk izca/ku bdkbZ] bjdkWV ifjlj] f'kokth fczt] ubZ fnYyh }kjk jsyos<br />
ladsr dk;Z ds fy;s fo'oLuh;] vuqHkoh ,oa LFkkfir Bsdsjknksa] ftuds ikl izekf.kr<br />
i;kZIr vuqHko gks] ls fuEufyf[kr ^[kqyh <strong>fufonk</strong>^ vkeaf=r dh tkrh gS %&<br />
dk;Z dk uke<br />
mRrj jsyos] mRrj e/; jsyos ,oa dsUnzh; jsy fo|qfRkdj.k<br />
laxBu ds fofHkUu LFkkuksa ij vkbZih Mh,l,y,,e dk;ksZ<br />
dk vfHkdYi] iwrhZ] laLFkkiu] ijh{k.k ,oa pkyw djuk<br />
dk;Z dh vuqekfur ykxr #-20]237]370-00<br />
c;kuk jkf'k #- 251190-00 :I;s nks yk[k bdkou gtkj ,d lkS uCcs<br />
dsoy !<br />
<strong>fufonk</strong> izys[k dh dher #-10000@& #i;s nl gtkj ek=<br />
(vgLrkarj.kh;<br />
izs"k.k 'kqYd (;fn Mkd @ #-500@&<br />
dksfj;j }kjk izkIr djuk #-ikWap lkS ek=<br />
gks)<br />
dk;Z iwjk djus dh N% ekg<br />
vof/k<br />
<strong>fufonk</strong> tek djus dh fnukad 25-03-2008 dks cts 14-30 cts rd<br />
vafre frfFk<br />
<strong>fufonk</strong> [kqyus dh frfFk]<br />
le; ,oa Lfkku<br />
fnukad 25-03-2008 dks 15-00 cts eq[; iz'kklfud<br />
vf/kdkjh dk;kZy;] bjdkWV ifjlj] f'kokth fczt] ubZ<br />
fnYyh&110001<br />
<strong>fufonk</strong> izLrko dh oS/krk <strong>fufonk</strong> [kqyus ds fnu ls N% ekg<br />
<strong>fufonk</strong> izys[k izkfIr dh fnukad 22-02-08 ls 24-03-08 rd le; 10-30 cts<br />
6
frfFk ,oa le;<br />
ls 15-00 cts rd<br />
fcuk /kjksgj jkf'k ds <strong>fufonk</strong>;sa fujLr dj nh tk;saxh<br />
vU; fooj.k ,oa <strong>fufonk</strong> eq[; iz'kklfud vf/kdkjh] vkbZ vkj ih ,e ;w<br />
@bjdkV ifjlj] f'kokth fczt] ubZ fnYyh dk;kZy; esa #-10000@& #i;s nl gtkj<br />
ek= dk Hkqxrku] mi foRr lykgdkj ,oa eq[; ys[kk vf/kdkjh@ Hkkjrh; jsyos<br />
ifj;kstuk izca/ku bdkbZ] ubZ fnYyh ds i{k esa jk"Vzh; @ vuqlwfpr Hkkjrh; cSad }kjk<br />
tkjh Hkqxrku vkns'k @ fMek.M MzkQ~V izLrqr dj dz; fd;k tk ldrk gS ! Mkd<br />
}kjk <strong>fufonk</strong> izys[k #- 10500@& esa dz; fd;k tk ldrk gS ! <strong>fufonk</strong> izys[k dh dz;<br />
jkf'k izfrns; ugha gS ! Hkkjrh; jsyos ifj;kstuk izca/ku bdkbZ dk;kZy; fdlh Hkh izdkj<br />
ds foyEc ds fy;s mRrjnk;h ugha gksxk ! <strong>fufonk</strong> dh ykxr vkSj nLrkost<br />
vgLrkarj.kh; gS A <strong>fufonk</strong> izi= osolkbV ls Mkmu yksM fd;s tk ldrsa gSa] Mkmu<br />
yksM dh x;h <strong>fufonk</strong> ds lkFk <strong>fufonk</strong> nLrkost dk ewY ; <strong>fufonk</strong> ds lkFk tek<br />
djkuk gksxk rFkk <strong>fufonk</strong> rHkh ekU; gksxh A Bsdsnkj dks b,QVh @ bZlh,l ds }kjk<br />
Hkqxrku fd;k tk;sxk A<br />
<strong>fufonk</strong>dkjksa ds fy;s U;wure ;ksX;rk ekun.M%<br />
1- <strong>fufonk</strong>dkj }kjk fiNys rhu o"kksZ esa vFkkZr pkyw ,oa rhu fiNys foRrh; o"kksZ esa<br />
de ls de ,d le:i dk;Z dk lQy lekiu djok;k gks ftldh ykxr mDr<br />
<strong>fufonk</strong> dh jkf'k ls 35% ls de ugha gksuh pkfg;s !<br />
le:i dk;Z dk vFkZ vkbZih Mh,l,y,,e dk;ksZ dk vfHkdYi] fofuekZ.k] iwrhZ]<br />
laLFkkiu] ijh{k.k ,oa pkyw djuk %&<br />
2- Bsdsnkj dh foRrh; {kerk ,oa laxBu lalk/ku dh izekf.kdrk ds fy;s mls pkyw<br />
vkbZVhlhlh@,oa ys[kk ijhf{kr rqyui= fiNys rhu o"kksZ ds vuqlkj iw.kZ ,oa pkyw dk;ksZ<br />
ds larks"k tud fu"iknu }kjk <strong>fufonk</strong> ewY; ds 150% ls de dk Hkqxrku izkIr ugha<br />
fd;k gksuk pkfg;s A<br />
;fn <strong>fufonk</strong>nkrk tkucw>dj nks"kiw.kZ lwpuk izLrqr djrk gS] ftlds vk/kkj ij<br />
mldh <strong>fufonk</strong> dks Lohdkj dj fy;k tkrk gS rks jsyos ;g vf/kdkj j[krh gS fd og<br />
fdlh Hkh le; mls vLohd`r dj ns lkFk gh ,d o"kZ ds fy;s mldk O;olk;<br />
fuyafcr dj ldrh gS !<br />
lHkh izi=ks ds lkFk ,d fyQkQs esa lhy gq;h <strong>fufonk</strong> ftlds mij dk;Z dk<br />
uke vafdr gksuk pkfg;s] eq[; iz'kklfud vf/kdkjh] vkbZ vkj ih ,e ;w] bjdkWV<br />
ifjlj] f'kokth fczt] ubZ fnYyh & 110001 dh fu/kkZfjr <strong>fufonk</strong> isVh esa tek dh<br />
tkuh pkfg;s ! ;Fkkfof/k lhy dh gq;h <strong>fufonk</strong> iathd`r Mkd }kjk Hkh<br />
7
izsf"kr fd;k tk ldrk gS ftls fu/kkZfjr le; ,oa frfFk ls iwoZ vkbZ vkj ih<br />
,e ;w dk;kZy; esa izkIr gks tkuk pkfg;s ! fu/kkZfjr le; ds i'pkr~ izkIr<br />
<strong>fufonk</strong> vLohdk;Z gksxh !<br />
uksV%<br />
1- <strong>fufonk</strong> i= vgLrkrajf.k; gS !<br />
2- ;fn fdlh dkj.ko'k mijksDr frfFk;ksa dks dk;kZy; dk vodk'k gks tkrk gS<br />
rks Lor% vxys dk;Zfnol dks nLrkost izLrqr fd, tk ldrs gSa !<br />
3-<strong>fufonk</strong> lwpuk ,oa <strong>fufonk</strong> <strong>ifji</strong>= vkbZ vkj ih ,e ;w dh vf/kdkfjd<br />
csclkbVwww.<strong>irpmu</strong>.<strong>railnet</strong>.<strong>gov</strong>.<strong>in</strong> ij Hkh miyC/k gS !<br />
('kSys'k frokjh)<br />
mi eq[; ladsr ,oa flxuy vfHk;Urk@eq[;ky;@vkbZvkjih,e;w<br />
bjdkWV ifjlj] f'kokth fczt] ubZ fnYyh & 110001<br />
Hkkjr ds jk"Vzifr dh vksj ls @ ds fy;s<br />
8
Section – I<br />
Chapter – 2<br />
Preamble<br />
9
PREAMBLE<br />
Tender No. IRPMU/ W / 2008/144/IP DSLAM(NR&NCR)<br />
1 NAME OF WORK:<br />
Design, Supply, Installation Test<strong>in</strong>g and commission<strong>in</strong>g of IP-DSLAM at various<br />
locations of Nothern & North Central Railways and Centre for Railway<br />
Electrification<br />
2 SCOPE OF WORK:<br />
2.1) The scope of work for the tender shall <strong>in</strong>clude, <strong>in</strong> general, but not be limited to<br />
cover Design, Supply, Installation, Test<strong>in</strong>g, Commission<strong>in</strong>g of IP-DSLAM<br />
Equipment to provide voice and broadband connectivity to Railway’s staff as<br />
mentioned <strong>in</strong> the annexure to preamble. The work is to be executed at the Zonal<br />
Headquarters of Northern & North Central Railway at Delhi and Allahabad,<br />
Headquarter of Centre for Railway Electrification at Allahabad & Divisions of<br />
Northern & North Central Railway as per list attached.<br />
2.2) Completion Schedule: The IP DSLAM network for Indian Railways should be<br />
fully operational with<strong>in</strong> 180 days of issue of LOA by Indian Railways. The<br />
bidders must ensure that they shall be able to meet these timel<strong>in</strong>es of the project.<br />
There is no scope for any delay <strong>in</strong> the project implementation. This should be<br />
kept <strong>in</strong> m<strong>in</strong>d while submission of the bids.<br />
2.3) Network Topology : Any type of medium, such as Fiber Optic Transmission,<br />
Copper Transmission shall be able to <strong>in</strong>terpose between DSLAM-Railway<br />
Network, DSLAM-DSLAM or DSLAM-soft switch, where ever applicable. The<br />
required transmission medium shall be decided on a case by case basis.<br />
2.4) Contract Requirements<br />
i) The proposed DSLAM shall have the capability to provide broadband<br />
connectivity to Railway Staff by us<strong>in</strong>g Railway’s exist<strong>in</strong>g or new <strong>in</strong>frastructure.<br />
The Bidder shall provide fully detailed description of upgradeability and<br />
expandability of the equipment offered.<br />
ii).<br />
iii)<br />
Availability: Network availability is the essence of this contract. The solution<br />
offered should be able to meet the availability requirement of at least 99% per<br />
Quarter.<br />
The solution shall adequately address related issues, so that the specified<br />
network uptime is achievable.<br />
10
The solution offered should be based on robust and state of art products and<br />
technology, and should ensure <strong>in</strong>vestment protection to Indian Railways, through<br />
the period of the contract.<br />
iv)<br />
Voice connectivity : The solution offered should provide voice and broadband<br />
connectivity to Railway’s staff countrywide.<br />
v) Data Security: The bidder should ensure end-to-end security of data<br />
transmission through their network. The bidder shall specify the security<br />
measures be<strong>in</strong>g deployed <strong>in</strong> the bidder’s network, so that IP DSLAM data is<br />
protected from external hack<strong>in</strong>g.<br />
vi)<br />
vii)<br />
viii)<br />
ix)<br />
Response time: Indian Railways shall <strong>in</strong>timate the bidder about the problem<br />
occurrence <strong>in</strong> case it is required. In most cases of problem occurrence, it is<br />
envisaged that the contractor shall get alerts generated by NMS. A maximum<br />
time of 12 hours to respond from the time of <strong>in</strong>timation, and a maximum problem<br />
resolution time of 6 hours thereafter, shall be allowed. For other regions of<br />
deployment, the contractor shall plan his support offices accord<strong>in</strong>gly, to meet<br />
these response times. These Service Support Centres shall be made<br />
operational to match the commission<strong>in</strong>g of IP DSLAM network <strong>in</strong> the respective<br />
regions.<br />
Network Reports: The bidder shall provide reports of the network, on a monthly<br />
basis. Additionally, any such reports should also be made available to Indian<br />
Railways, whenever requested. The contractor shall ma<strong>in</strong>ta<strong>in</strong> record of all the<br />
logs, perta<strong>in</strong><strong>in</strong>g to the IP DSLAM network, dur<strong>in</strong>g the currency of the contract.<br />
Also, two eng<strong>in</strong>eers of Indian railways shall be made conversant with the NMS<br />
configuration for IP DSLAM network at each location.<br />
Electrical Power: At all the field <strong>in</strong>stallation sites regulated AC and DC Ma<strong>in</strong>s<br />
/Generator power shall be made available with sufficient power back up by<br />
Railway.<br />
Project Key Dates: Time is the essence of the contract. It, therefore,<br />
emphasized that the implementation time schedules mentioned <strong>in</strong> the tender<br />
document shall be strictly adhered to. Further, the bidders are required to submit<br />
details of the project implementation plans.<br />
x) Network Management System / Element Management System<br />
The NMS / EMS shall be offered, enabl<strong>in</strong>g centralized monitor<strong>in</strong>g and<br />
configuration of each DSLAM equipment.<br />
The NMS / EMS shall have a user-friendly GUI, with first level diagnostic<br />
capability.<br />
The NMS / EMS shall have fault management, alarm monitor<strong>in</strong>g, fault<br />
localization, configuration management, performance management, security<br />
management, software download, subscriber l<strong>in</strong>e test functions.<br />
Each DSLAM shall have <strong>in</strong>dependent NMS / EMS.<br />
11
In future, it should be possible to have central EMS to manage all the NMS<br />
countrywide.<br />
3. TENDER BID<br />
The tender bid shall be submitted <strong>in</strong> two separate sealed covers as under <strong>in</strong> time<br />
with<strong>in</strong> the last date of tender submission <strong>in</strong> the sealed Tender Box to be kept for<br />
the purpose <strong>in</strong> the office of Chief Adm<strong>in</strong>istrative Officer /IRPMU, Shivaji Bridge<br />
(IRCOT complex),New Delhi 110001.<br />
Part-I – technical and credential elements of the tender bid here<strong>in</strong>after called"<br />
Credential bid”<br />
Part-II - Price element of the tender bid here<strong>in</strong>after called “price bid”<br />
The details to be <strong>in</strong>cluded with the bid are given <strong>in</strong> Para 6 of `Instructions to<br />
Tenderers and Conditions of Tender<strong>in</strong>g'.<br />
4. QUALIFYING CRITERIA<br />
To qualify for the bid, the Contractor shall be required to meet the eligibility<br />
requirements as given <strong>in</strong> Para - 18 of Instructions to Tenderers and Conditions of<br />
Tender<strong>in</strong>g.<br />
5. LAST DATE OF SUBMISSION:<br />
The Tender shall be received up to 1430 hrs on 25.03.2008 at New Delhi <strong>in</strong> the<br />
office of Chief Adm<strong>in</strong>istrative Officer /IRPMU, Shivaji Bridge (IRCOT complex),<br />
New Delhi 110001.<br />
6. DATE OF OPENING OF TENDER:<br />
The Tender will be opened at 1500 hrs on 25.03.2008 at the same address as<br />
mentioned <strong>in</strong> Para-5 above.<br />
7. COMPLETION PERIOD OF WORK:<br />
The entire work is to be completed with<strong>in</strong> 180 (one hundred & Eighty) days from<br />
the date of issue of Letter of Acceptance of the Tender.<br />
8. THE LIST OF ADDRESS TO WHICH CORRESPONDENCE AND<br />
DOCUMENTS RELATING TO THE CONTRACT SHOULD BE SENT.<br />
(a) Prior to award of the contract:<br />
Chief Adm<strong>in</strong>istrative Officer / IRPMU, Shivaji Bridge (IRCOT complex), New<br />
Delhi Telephone no. +91 11 23412260, Fax No. +91 11 23412556.<br />
(b) After the award of the Contract:<br />
12
The Chief Adm<strong>in</strong>istrative Officer / IRPMU, Shivaji Bridge (IRCOT complex),New<br />
Delhi or his Successor Nom<strong>in</strong>ee (Whose address will be <strong>in</strong>timated <strong>in</strong> due<br />
course).<br />
9. EARNEST MONEY:<br />
The Tenderer should furnish the requisite Earnest Money along with their offer <strong>in</strong><br />
favour of the Dy F<strong>in</strong>ancial Advisor& Chief Accounts Officer/IRPMU, Shivaji<br />
Bridge New Delhi’ as <strong>in</strong>dicated <strong>in</strong> Para-5 of Instructions to Tenderers and<br />
Conditions of Tender<strong>in</strong>g.<br />
10. SECURITY DEPOSIT:<br />
(i)<br />
(ii)<br />
(iii)<br />
(iv)<br />
Security deposit shall be 5% of the contract value<br />
The rate of recovery shall be @10% of the bill amount till the full<br />
security deposit is recovered.<br />
Security deposit will be recovered only from the runn<strong>in</strong>g bill of the<br />
contract and no other mode of collect<strong>in</strong>g SD as <strong>in</strong> the form of<br />
<strong>in</strong>struments like BG, FD etc shall be accepted towards Security<br />
Deposit.<br />
No <strong>in</strong>terest will be payable upon the Security Deposit or amounts<br />
payable to the contractor under this contract.<br />
Security Deposit will be returned to the contractor after six months of physical<br />
completion of work as certified by competent authority and settlement of all dues and<br />
disputes. The competent shall normally be the authority, who is competent to sign the<br />
contract. If this competent authority is of the rank lower than the JA grade, then a JA<br />
grade officer (concerned with the work) should issue the certificate. The certificate <strong>in</strong>ter<br />
allia should mention that the work has been completed <strong>in</strong> all respects & that all the<br />
contractual obligations have been fulfilled by the contractors and that there is no due<br />
from the contractor to Railways aga<strong>in</strong>st the contract concerned. Before releas<strong>in</strong>g the<br />
Security Deposit, contractor concerned should submit an unconditional & unequivocal no<br />
claim certificate.<br />
11. PERFORMANCE GUARANTEE<br />
The procedure for obta<strong>in</strong><strong>in</strong>g Performance Guarantee is outl<strong>in</strong>ed below:-<br />
(a).<br />
(b).<br />
The successful bidder shall submit a Performance Guarantee (PG) <strong>in</strong> the form of<br />
an irrevocable bank guarantee amount<strong>in</strong>g to 5% of the contract value.<br />
A Performance Guarantee shall be submitted by the successful bidder after the<br />
letter of acceptance has been issued, but before sign<strong>in</strong>g of the agreement. The<br />
agreement should normally be signed with<strong>in</strong> 15 days after the issue of LOA and<br />
Performance Guarantee shall also be submitted with<strong>in</strong> this time limit. This<br />
guarantee shall be <strong>in</strong>itially valid up to the stipulated date of completion plus 60<br />
days beyond that. In case, the time for completion of work gets extended, the<br />
13
contractor shall get the validity of Performance Guarantee extended to cover such<br />
extended time for completion of work plus 60 days.<br />
(c ). The Performance Guarantee (PG) shall be released after the physical completion<br />
of the work based on the “Completion Certificate” issued by the competent<br />
authority stat<strong>in</strong>g that the contractor has completed the work <strong>in</strong> all respects<br />
satisfactorily . The security deposit, however, shall be released only after the<br />
expiry of the ma<strong>in</strong>tenance period and after pass<strong>in</strong>g the f<strong>in</strong>al bill based on “NO<br />
Claim Certificate.<br />
(d).<br />
(e).<br />
Wherever the contracts is resc<strong>in</strong>ded, the security deposit shall be forfeited and<br />
Performance Guarantee shall be encashed and the balance work shall be got done<br />
<strong>in</strong>dependently without risk and cost of the failed contractor. The failed contractor<br />
shall be debarred from participat<strong>in</strong>g <strong>in</strong> the tender for execut<strong>in</strong>g the balance work.<br />
If the failed contractor is a JV or a partnership firm, then every member/partner<br />
of such a firm shall be debarred from participat<strong>in</strong>g <strong>in</strong> the tender for the balance<br />
work either <strong>in</strong> his/her <strong>in</strong>dividual capacity or as a partner of any other<br />
JV/partnership firm.<br />
The Eng<strong>in</strong>eer shall not make a claim under the Performance Guarantee except for<br />
amounts to which the President of India is entitled under the contract ( not<br />
withstand<strong>in</strong>g and /or without prejudice to any other provisions <strong>in</strong> the contract<br />
agreement) <strong>in</strong> the event of :<br />
1. Failure by the contractor to extend the validity of the Performance Guarantee<br />
as described here<strong>in</strong> above, <strong>in</strong> which event the Eng<strong>in</strong>eer may claim the full<br />
amount of the Performance Guarantee.<br />
2. Failure by contractor to pay President of India any amount due, either as<br />
agreed by the contractor or determ<strong>in</strong>ed under any of the Clauses/Conditions<br />
of the agreement, with<strong>in</strong> 30 days of the service of notice to this effect by<br />
Eng<strong>in</strong>eer.<br />
3. The contract be<strong>in</strong>g determ<strong>in</strong>ed or resc<strong>in</strong>ded under provision of the GCC the<br />
Performance Guarantee shall be forfeited <strong>in</strong> full and shall be absolutely at the<br />
disposal of the President of India.<br />
12. SPECIFICATIONS / DRAWINGS:<br />
Reference of specification/draw<strong>in</strong>g of the important equipment, components and<br />
other materials required for the execution of the Contract is given <strong>in</strong> the Technical<br />
Supplement. The work shall be executed <strong>in</strong> compliance with all the technical<br />
requirements given there.<br />
13. SCHEDULE OF QUANTITIES:<br />
14
The Schedule of Quantities for Supply & Execution of various works are<br />
<strong>in</strong>dicated <strong>in</strong> Schedule of Requirement. The tenderers are advised to quote for all<br />
items.<br />
NOTE:- If it is considered necessary that the item of Supply and works<br />
<strong>in</strong>cluded <strong>in</strong> Schedule of requirement would not cover all works <strong>in</strong>volved <strong>in</strong> the<br />
execution of the work, additional item of work which are considered necessary<br />
and unit prices of such items shall be given separately as Schedule `Y' along with<br />
Explanatory Notes.<br />
15
S.No.<br />
Annexure to Preamble<br />
Calculation of quantity of items required at<br />
Place of HQ Qty of<br />
central<br />
office<br />
equipment S.N. Divisions<br />
Qty of<br />
Central<br />
office<br />
equipment<br />
Railway<br />
1 Northern Railway New Delhi,<br />
Baroda House 1 1 Delhi 4<br />
2 Northern Central<br />
Railway<br />
Allahabad<br />
6 CORE Allahabad 1<br />
Total no of<br />
systems for<br />
Zonal Railway 3<br />
Summary 1. Total IP DSLAMs for Zonal Hd<br />
Qtrs 3<br />
2. Total IP DSLAMs for Divisions 5<br />
3. No of subscribers at a Zonal HQ 528<br />
4. No of subscribers at a division 192<br />
1 2 Allahabad 1<br />
Sub Total 5<br />
16
Section – I<br />
Chapter – 3<br />
Schedule of Requirement<br />
17
Schedule-A (SUPPLY)<br />
S.NO. DESCRIPTION OF ITEM Unit Qty Unit Rate Total<br />
1 Supply of IP DSLAM<br />
Systemwith equipped<br />
capacity of 528 Ports and<br />
expandable up to 640<br />
Ports with 2 Nos of<br />
Gigabit Ethernet Optical<br />
Upl<strong>in</strong>k Module ( 1000<br />
Base -LX , 10 KM )<br />
alongwith element<br />
management system,<br />
Rack, Sub-Racks, Power<br />
Supply, and Installation<br />
material like 528 Primary /<br />
Secondary MDF, krone<br />
block for term<strong>in</strong>at<strong>in</strong>g 528<br />
l<strong>in</strong>es,Patch Cords , 12<br />
Core FDF etc. confirm<strong>in</strong>g<br />
to technical specification<br />
of tender document.<br />
2 Supply of 528 port splitter<br />
unit alongwith splitter<br />
shelf , covered rack Unit<br />
and associated Krone<br />
Block with 19" Rack Mount<br />
alongwith accessories like<br />
<strong>in</strong>terconnect<strong>in</strong>g cables,<br />
switchboard cables and<br />
0.5 mm copper cables etc.<br />
as required at site<br />
confirm<strong>in</strong>g to technical<br />
specification of tender<br />
document.<br />
3 Supply of IP DSLAM<br />
System with equipped<br />
capacity of 192 Ports and<br />
expandable up to 256<br />
Ports with 2 Nos of<br />
Gigabit Ethernet Optical<br />
Upl<strong>in</strong>k Module ( 1000<br />
Base -LX , 10 KM ) along<br />
with<br />
element<br />
management system,<br />
Rack, Sub-Racks, Power<br />
Supply, and Installation<br />
Nos. 3<br />
Set 3<br />
Nos. 5<br />
18
material like 192 Primary /<br />
Secondary MDF, krone<br />
block for term<strong>in</strong>at<strong>in</strong>g 192<br />
l<strong>in</strong>e Patch Cords , 12 Core<br />
FDF etc. confirm<strong>in</strong>g to<br />
technical specification of<br />
tender document.<br />
4 Supply of 192 port splitter<br />
unit alongwith splitter<br />
shelf , covered rack Unit<br />
and associated Krone<br />
Block with 19" Rack Mount<br />
alongwithl accessories<br />
like <strong>in</strong>terconnect<strong>in</strong>g<br />
cables, switchboard cables<br />
and 0.5 mm copper<br />
cables etc. as required at<br />
site confirm<strong>in</strong>g to technical<br />
specification of tender<br />
document.<br />
5 Supply of Local crafts<br />
term<strong>in</strong>al for provisio<strong>in</strong>g ,<br />
configuration,<br />
management etc of<br />
DSLAM and CPEs<br />
confirm<strong>in</strong>g to technical<br />
specification of tender<br />
document.<br />
6 Supply of ADSL2+<br />
Modem with Built<strong>in</strong> Splitter<br />
( CPE ) ,USB, ethernet<br />
and wireless ports etc<br />
confirm<strong>in</strong>g to technical<br />
specification of tender<br />
document.<br />
7 Supply of Portable ADSL<br />
Tester<br />
8 Supply of 8 port ADSL 2+<br />
extender confirm<strong>in</strong>g to<br />
technical specification of<br />
tender document.<br />
9 Supply of managed layer<br />
3 gigabit ethernet switch<br />
/router confirm<strong>in</strong>g to<br />
technical specification of<br />
tender document.<br />
10 Supply of router with<br />
G.703 and ethernet ports<br />
Set 5<br />
Nos. 1<br />
Nos. 2544<br />
Nos. 8<br />
Nos. 32<br />
Nos. 8<br />
Nos. 8<br />
19
confirm<strong>in</strong>g to technical<br />
specification<br />
11 Spares as per para 13 of LS 1<br />
SCC (detail of spares<br />
along with rates to be<br />
submitted by bidder)<br />
confirm<strong>in</strong>g to technical<br />
specification of tender<br />
document.<br />
Schedule-B (SERVICES)<br />
1 Installation , test<strong>in</strong>g and Set 3<br />
commssion<strong>in</strong>g of IP<br />
DSLAM and splitter<br />
System with equipped<br />
capacity of 528 Ports and<br />
expandable up to 640<br />
Ports with 2 Nos of<br />
Gigabit Ethernet Optical<br />
Upl<strong>in</strong>k Module ( 1000<br />
Base -LX , 10 KM )<br />
alongwith element<br />
management system,<br />
Rack, Sub-Racks, Power<br />
Supply, and Installation<br />
material like 528 Primary /<br />
Secondary MDF, Patch<br />
Cords , 12 Core FDF etc. ,<br />
alonwith splitter unit and<br />
associated equipment<br />
confirm<strong>in</strong>g to technical<br />
specification of tender<br />
document.<br />
2 Installation , test<strong>in</strong>g and Set 5<br />
commssion<strong>in</strong>g of IIP<br />
DSLAM and splitter<br />
System with equipped<br />
capacity of 192 Ports and<br />
expandable up to 256<br />
Ports with 2 Nos of<br />
Gigabit Ethernet Optical<br />
Upl<strong>in</strong>k Module ( 1000<br />
Base -LX , 10 KM )<br />
alongwith element<br />
management system,<br />
Rack, Sub-Racks, Power<br />
Supply, and Installation<br />
material like 192 Primary /<br />
20
Secondary MDF, Patch<br />
Cords , 12 Core FDF<br />
etc.alongwith splitter unit<br />
and associated equipment<br />
confirm<strong>in</strong>g to technical<br />
specification of tender<br />
document.<br />
3 Installation , test<strong>in</strong>g and Set 2544<br />
commssion<strong>in</strong>g of ADSL2+<br />
Modem with Built<strong>in</strong> Splitter<br />
( CPE ) ,USB, ethernet<br />
and wireless ports at<br />
various locations alongwith<br />
Installation Material like<br />
wir<strong>in</strong>gs and connectors ,<br />
rosette and splitter<br />
confirm<strong>in</strong>g to technical<br />
specification of tender<br />
document.<br />
4 Installation, test<strong>in</strong>g and Nos 32<br />
commissio<strong>in</strong>g of of 8 port<br />
ADSL 2+ extender<br />
confirm<strong>in</strong>g to technical<br />
specification of tender<br />
document.<br />
5 Installation, test<strong>in</strong>g and Nos. 8<br />
commissio<strong>in</strong>g of managed<br />
layer 3 gigabit ethernet<br />
switch /routerconfirm<strong>in</strong>g to<br />
technical specification of<br />
tender document.<br />
6 Installation, test<strong>in</strong>g and Nos 8<br />
commissio<strong>in</strong>g of router<br />
with G.703 and ethernet<br />
ports confirm<strong>in</strong>g to<br />
technical specification of<br />
tender document.<br />
7 Tra<strong>in</strong><strong>in</strong>g of Railway staff man<br />
weeks<br />
4<br />
21
Section – II<br />
Chapter – 1<br />
Instructions to<br />
Tenderer &<br />
Conditions of<br />
Tender<strong>in</strong>g<br />
22
Section – II<br />
Chapter – 1<br />
Instructions to Tenderer & Conditions of Tender<strong>in</strong>g<br />
INDEX<br />
1. GENERAL INSTRUCTIONS<br />
2. INTERPRETATIONS<br />
3. LOCAL CONDITIONS<br />
4. COMPLIANCE TO TENDER CONDITIONS, TECHNICAL<br />
SPECIFICATION & DRAWINGS<br />
5. EARNEST MONEY/BID GUARANTEE<br />
6. SUBMISSION OF OFFERS<br />
7. CONSTITUTION OF FIRM & POWER OF ATTORNEY<br />
8. UNIT PRICES<br />
9. VALIDITY OF OFFER<br />
10. RATES DURING NEGOTIATION<br />
11. INCOME TAX CLEARANCE CERTIFICATE<br />
12. PERIOD OF COMPLETION & TIME PROGRESS GRAPH<br />
13. OPENING OF TENDER<br />
14. NON-TRANSFERABILITY & NON-REFUNDABILITY<br />
15. ERRORS OMISSIONS & DISCREPANCIES<br />
16. WRONG INFORMATION BY TENDERER<br />
17. CONSORTIUM BIDS<br />
18. QUALIFICATION CRITERIA<br />
19 DETERMINATION OF RESPONSIVENESS<br />
20. CORRECTION OF ERRORS<br />
23
21. CONVERSION TO SINGLE CURRENCY i.e. RUPEES<br />
22. SYSTEM PERFORMANCE GUARANTEE<br />
23. AUTHORITY FOR ACCEPTANCE<br />
24. PURCHASE PREFERENCE<br />
25. AGREEMENT<br />
26. TENDERER'S ADDRESS<br />
27. FOREIGN EXCHANGE<br />
24
INSTRUCTIONS TO TENDERERS<br />
AND CONDITIONS OF<br />
TENDERING<br />
1. GENERAL INSTRUCTIONS:<br />
1.1 Chief Adm<strong>in</strong>istrative Officer, Indian Railway Project Management Unit, New<br />
Delhi, for and on behalf of the President of India <strong>in</strong>vites sealed Open tenders<br />
from the established, reliable and experienced manufacturers or their<br />
authorized agents with sufficient proven experience <strong>in</strong> similar work for the<br />
work of Design, Supply, Installation Test<strong>in</strong>g and commission<strong>in</strong>g of IP-<br />
DSLAM at various locations of Nothern & North Central Railways and<br />
Centre for Railway Electrification as given <strong>in</strong> the Preamble.<br />
1.2 The General Conditions of contract, Special Conditions of Contract,<br />
Instructions to Tenderers and Conditions of Tender<strong>in</strong>g, Technical<br />
Specifications, Preamble <strong>in</strong>clud<strong>in</strong>g Schedule of Work & Supplies <strong>in</strong>clud<strong>in</strong>g<br />
all Annexure & forms etc. shall, hereafter, be collectively referred to as the<br />
"Tender papers".<br />
1.3 Any clarifications required by the tenderer may be obta<strong>in</strong>ed from the Chief<br />
Adm<strong>in</strong>istrative Officer / IRPMU, Shivaji Bridge (IRCOT Complex), New<br />
Delhi 110001.<br />
2. INTERPRETATIONS:<br />
The follow<strong>in</strong>g terms wherever occurr<strong>in</strong>g <strong>in</strong> the tender papers and wherever<br />
used throughout the execution of the work, shall, unless excluded by or<br />
repugnant to the context, have the mean<strong>in</strong>g attributed there to as follows: -<br />
"CONTRACT" Means the Agreement or Work Order result<strong>in</strong>g from the<br />
acceptance by the Purchaser of this tender either <strong>in</strong> whole or <strong>in</strong> part.<br />
"CONTRACTOR” Means the successful Tenderer, i.e., the Tenderer<br />
whose Tender has been accepted either <strong>in</strong> whole or <strong>in</strong> part.<br />
“CONTRACTOR’S REPRESENTATIVE” Shall mean a person <strong>in</strong><br />
supervisory capacity who shall be so declared by the contractor and who shall<br />
be authorised under a duly executed power of attorney to receive materials<br />
issued by the Purchaser to the Contractor for the works. He shall be<br />
responsible for proper execution of works at each or all places and shall take<br />
orders from Purchaser's Eng<strong>in</strong>eers and carry out the same.<br />
25
"ENGINEER” Shall mean the Divisional Eng<strong>in</strong>eer/Divisional Electrical<br />
Eng<strong>in</strong>eer/Divisional Signal & Telecom. Eng<strong>in</strong>eer or the Assistant Eng<strong>in</strong>eers<br />
<strong>in</strong> executive charge of the Railway works and shall <strong>in</strong>clude the superior<br />
officers of the Railway. He is responsible for ensur<strong>in</strong>g that all field works<br />
covered by the contract are carried out <strong>in</strong> accordance with approved designs,<br />
draw<strong>in</strong>gs and specifications and conditions of contract as agreed to.<br />
“ENGINEER’S REPRESENTATIVE" Shall mean the Sr. Section<br />
Eng<strong>in</strong>eers/ Section Eng<strong>in</strong>eers <strong>in</strong> direct charge of the works of Signal &<br />
Telecom./Civil/Electrical Eng<strong>in</strong>eer<strong>in</strong>g department of Railway.<br />
"EQUIPMENT" Means all or any equipment considered necessary by the<br />
Purchaser's Eng<strong>in</strong>eers for the satisfactory operation, as a whole, of the<br />
<strong>in</strong>stallations.<br />
“GENERAL MANAGER” Means the officer <strong>in</strong> Adm<strong>in</strong>istrative charge of<br />
this Railway and shall mean and <strong>in</strong>clude the officers to whom the functions<br />
are delegated. His postal address shall be <strong>in</strong>timated to the successful<br />
Tenderers <strong>in</strong> due course.<br />
"MONTH” Means One English Calendar Month.<br />
"MATERIALS” Means all equipment, components, fitt<strong>in</strong>gs and other<br />
materials <strong>in</strong>clud<strong>in</strong>g raw materials required to complete the work.<br />
"PURCHASER” Means the President of India act<strong>in</strong>g through his accredited<br />
officers or any one of them. The Chief Adm<strong>in</strong>istrative Officer / IRPMU,<br />
North Central Railway New Delhi shall be deemed to be one of such<br />
accredited officers.<br />
Subject as otherwise provided <strong>in</strong> this contract, all notices to be given and all<br />
other action to be taken on behalf of President of India may be given or taken<br />
on his behalf by General Manager, North Central Railway Allahabad/ Chief<br />
Adm<strong>in</strong>istrator Officer, IRPMU, IRCOT Complex, Shivaji Bridge, New Delhi<br />
or any other representative of the North Central Railway Adm<strong>in</strong>istration<br />
nom<strong>in</strong>ated by him.<br />
“PURCHASER’S ENGINEERS" Means the Chief Adm<strong>in</strong>istrative Officer /<br />
IRPMU North Central Railway or successor who will decide all matters<br />
relat<strong>in</strong>g to survey, design, manufacture, <strong>in</strong>stallation and commission<strong>in</strong>g of<br />
the plant and equipment at site.<br />
"RAILWAY” Shall mean the President of the Republic of India or the<br />
Adm<strong>in</strong>istrative Officers of the Railway or of the successor Railway<br />
authorised to deal with any matters with which these present are concerned<br />
on his behalf.<br />
26
"SUB-CONTRACTOR" Means an <strong>in</strong>dividual or a firm of Contractor<br />
or a Company registered under Indian Company Act or an approved supplier<br />
of materials to whom the Contractor sublets portions of the contract after<br />
obta<strong>in</strong><strong>in</strong>g specific prior approval of the Purchaser <strong>in</strong> writ<strong>in</strong>g to sub-lett<strong>in</strong>g of<br />
contract.<br />
"SITE" Means the areas to be taken up for the execution of works,<br />
together with any other area or areas as shall be determ<strong>in</strong>ed by the<br />
Purchaser's Eng<strong>in</strong>eers, which may be placed at the disposal of the Contractor<br />
for the purpose of the contract and also such area or areas as the Purchaser'<br />
Eng<strong>in</strong>eers may have authorised as an extension of the site, irrespective of the<br />
terms and conditions under which they are occupied by the Contractor.<br />
"TENDERER" Means and <strong>in</strong>cludes any firm of eng<strong>in</strong>eers or Contractors or<br />
any company or body, corporate or otherwise, who submit the Tender which<br />
has been <strong>in</strong>vited.<br />
“WORK OR WORKS" Means all or any of the items of the work for<br />
which the Tenderer/ Contractor has Tendered/contracted accord<strong>in</strong>g to the<br />
specifications, draw<strong>in</strong>gs and Annexure hereto annexed or to be implied there<br />
from, or <strong>in</strong>cidental thereto or to be hereafter specified or required <strong>in</strong><br />
such explanatory <strong>in</strong>structions and draw<strong>in</strong>gs, be<strong>in</strong>g <strong>in</strong> conformity with the<br />
orig<strong>in</strong>al specifications, draw<strong>in</strong>gs, Annexure and schedules, and also such<br />
<strong>in</strong>structions and draw<strong>in</strong>gs additional to the aforementioned as may from time<br />
to time be issued by the Purchaser's Eng<strong>in</strong>eer dur<strong>in</strong>g the progress of the<br />
contracted work.<br />
"WRITING" Includes all matters written, typewritten or pr<strong>in</strong>ted either <strong>in</strong><br />
whole or <strong>in</strong> part.<br />
3. LOCAL CONDITIONS :<br />
3.1 It will be imperative on each tenderer to fully acqua<strong>in</strong>t himself with all the<br />
local conditions and factors which would have any effect on the<br />
performance of the contract and cost of the stores. The purchaser shall not<br />
enterta<strong>in</strong> any request for clarifications from the tenderer regard<strong>in</strong>g such local<br />
conditions. No request for the change of price or time schedule of delivery of<br />
stores shall be enterta<strong>in</strong>ed after the offer is accepted by the purchaser on<br />
account of any local condition or factor.<br />
3.2 In the event of the tenderer desir<strong>in</strong>g to have a field survey before furnish<strong>in</strong>g<br />
his quotations, he may apply to Railways for permission <strong>in</strong> this regard. Such<br />
permission will be given <strong>in</strong> writ<strong>in</strong>g by the Railways but the expenses <strong>in</strong> this<br />
regard will be borne by the tenderer completely.<br />
3. 3 The <strong>in</strong>tend<strong>in</strong>g tenderer is advised to study the tender papers carefully. Any<br />
submission of a quotation by the tenderer shall be deemed to have been done<br />
after a careful study and exam<strong>in</strong>ation of these documents with full<br />
27
understand<strong>in</strong>g of the implication thereof. These conditions and specifications<br />
shall be deemed to have been accepted unless otherwise, specifically<br />
commented upon by the Tenderer <strong>in</strong> his quotation. Failure to adhere to<br />
anyone or all these <strong>in</strong>structions may render his offer liable to be ignored<br />
without any reference.<br />
3.4 Should a tenderer f<strong>in</strong>d discrepancies <strong>in</strong> or omission from the draw<strong>in</strong>g or any<br />
of the Tender papers or he has any doubt to their mean<strong>in</strong>g, he should at once<br />
notify the Railway who may send a written clarification to all tenderers.<br />
4. COMPLIANCE TO TENDER CONDITIONS, TECHNICAL<br />
SPECIFICATION & DRAWINGS :<br />
4.1 Tenderer should note that the IP DSLAM equipment offered should be<br />
complete and compatible with the Railway equipments <strong>in</strong>stalled on Indian<br />
Railways. Any equipment/work required to make the <strong>in</strong>terface equipments<br />
match with Railway equipments is the responsibility of the contractor. Indian<br />
Railway will not undertake any change <strong>in</strong> their equipments, nor shall bear any<br />
extra cost on account of changes/addition required for ensur<strong>in</strong>g compatibility<br />
of <strong>in</strong>terface devices with their equipments.<br />
4.2 The tenderer shall <strong>in</strong>dicate paragraph by paragraph for each section and each<br />
clause and sub-clause of all annexure of technical specifications of the tender<br />
document that either his tender complies <strong>in</strong> every respect with the<br />
requirements of each clause and sub-clause or if not, precisely how they differ<br />
from the requirements of the tenderer. In later case, the tenderer shall enclose<br />
a separate statement as per pro-forma given, <strong>in</strong>dicat<strong>in</strong>g only the deviations for<br />
any clause or sub-clause of General Conditions of Contract, Special<br />
Conditions of Contract, Instructions to tenderers and conditions of tender<strong>in</strong>g,<br />
Technical Specification, Preamble etc. which he proposes with "detailed<br />
justifications for deviations proposed". The purchaser, reserves the right to<br />
accept or reject these deviations and his decision thereon shall be f<strong>in</strong>al (see<br />
Form 5).<br />
4.3 The equipment & material offered shall be <strong>in</strong> accordance with the draw<strong>in</strong>gs<br />
and specifications. Details of variation from the draw<strong>in</strong>gs and specifications,<br />
if any, should be clearly <strong>in</strong>dicated and <strong>in</strong> such an event, a certificate from the<br />
users must be furnished to the effect that the product offered performs the<br />
requisite functions satisfactorily & is an alternative acceptable <strong>in</strong> one or more<br />
other countries. The name of users <strong>in</strong> those foreign countries should also be<br />
<strong>in</strong>dicated.<br />
4.4 Firms who have not carried out the works and supplied the items tendered for<br />
<strong>in</strong> this case for the Indian Railways <strong>in</strong> the past should give details of supplies<br />
and works carried out and the customers along with their performance<br />
certificates.<br />
5. EARNEST MONEY/BID GUARANTEE :<br />
28
5.1 The tenderer shall deposit <strong>in</strong> favour of the Dy F<strong>in</strong>ancial Adviser & Chief<br />
Accounts Officer, IRPMU, Shivaji Bridge,NewDelhi-110001, a sum of Rs.<br />
251190/- (Rupees Two lakhs fifty one thousand one hundred n<strong>in</strong>ety only) as<br />
Earnest Money.<br />
5.2 The Earnest Money receipt shall be <strong>in</strong>corporated <strong>in</strong> the orig<strong>in</strong>al copy of the<br />
tender document. The other copies of the offer shall conta<strong>in</strong> true copies of<br />
Earnest Money receipt. The Earnest Money should be furnished either <strong>in</strong><br />
cash or <strong>in</strong> any of the follow<strong>in</strong>g forms:<br />
(a) Deposit receipt, pay orders, Demand Drafts. These should be either of the<br />
State Bank of India or any of the Nationalised Bank. No confirmatory advice<br />
from the Reserve Bank of India will be necessary.<br />
(b) Deposit receipt executed by the Schedule Banks (other than the State<br />
Bank of India and the Nationalised Banks) approved by RBI for this<br />
purpose. The Railways will not, however accept deposit receipt without<br />
gett<strong>in</strong>g <strong>in</strong> writ<strong>in</strong>g the concurrence of the RBI.<br />
NOTE: (a) In case the Earnest Money is deposited <strong>in</strong> cash the payment should be<br />
made to the Chief Cashier, North Central Railway, Allahabad and cash<br />
receipts obta<strong>in</strong>ed from him should be furnished along with the tender.<br />
(b)<br />
Deposit receipts, Pay Order and Demand Drafts should be drawn <strong>in</strong> favour of<br />
the Dy F<strong>in</strong>ancial Adviser & Chief Accounts Officer, IRPMU, Shivaji Bridge,<br />
New Delhi 110001, and endorsed "Account Payee". These <strong>in</strong>struments<br />
should be valid at least for the period cover<strong>in</strong>g the validity of the offer.<br />
5.3 No reference to the previous deposit of Earnest Money & Security Deposit for<br />
adjustment aga<strong>in</strong>st the present tender will be accepted and any request for<br />
recovery from any Security Deposit aga<strong>in</strong>st present tender will not be<br />
enterta<strong>in</strong>ed.<br />
5.4 The Earnest Money shall rema<strong>in</strong> deposited with the Purchaser for the period<br />
of 180 days from the date of open<strong>in</strong>g of the tender. If the validity of the offer<br />
is extended, the Earnest Money Deposit duly extended shall also be furnished,<br />
fail<strong>in</strong>g which the offer after the expiry of the aforesaid period shall not be<br />
considered by the Purchaser.<br />
5.5 No <strong>in</strong>terest will be payable by the Purchaser on the Earnest Money.<br />
5.6 The Earnest Money deposited is liable to be forfeited if the tenderer<br />
withdraws or amends impairs or derogates from the tender <strong>in</strong> any respect<br />
with<strong>in</strong> the period of validity of his offer.<br />
5.7 The Earnest Money of the successful tenderer will be returned after the<br />
contract Performance Guarantee (Security Deposit) as required under the<br />
29
special conditions of contract is furnished and formal contract duly signed is<br />
received by the Purchaser.<br />
5.8 If the successful tenderer fails to furnish a Contract Performance Guarantee<br />
& Security Deposit) as required <strong>in</strong> the Special Conditions of Contract and<br />
fails to return the formal contract duly signed with<strong>in</strong> (30) thirty days of the<br />
receipt of the formal contract, then the Earnest Money shall be liable to be<br />
forfeited by the Purchaser.<br />
5.9 The Earnest Money of all unsuccessful tenderers will be returned by the<br />
Purchaser with<strong>in</strong> reasonable time after the f<strong>in</strong>alisation of the tender.<br />
5.10 Any tender not accompanied by Earnest Money <strong>in</strong> one of the approved forms<br />
will be summarily rejected.<br />
6. SUBMISSION OF OFFERS:<br />
6.1 All offers <strong>in</strong> the prescribed forms should be submitted before the time and<br />
date fixed for the receipt of the offers. Offers received after the stipulated<br />
time and date will be dealt with as per rules <strong>in</strong> vogue <strong>in</strong> the Railways.<br />
6.2 In case the date of open<strong>in</strong>g happens to be a holiday or Bandh, the tender will<br />
be received and opened at the same time on the next work<strong>in</strong>g day.<br />
6.3 All offers shall be either type written or written neatly <strong>in</strong> <strong>in</strong>delible <strong>in</strong>k <strong>in</strong><br />
English. Each page of the offer must be numbered consecutively. A reference<br />
to total number of pages compris<strong>in</strong>g the offer must be made at the top right<br />
hand corner of the top page. All the support<strong>in</strong>g documents should be<br />
submitted either <strong>in</strong> orig<strong>in</strong>al or duly attested by a gazetted officer or notary<br />
public unless stated otherwise <strong>in</strong> these documents. The orig<strong>in</strong>al documents<br />
shall be produced for verification when called for.<br />
6.4 All copies of the tender paper shall be signed <strong>in</strong> <strong>in</strong>k by the tenderer, on each<br />
page <strong>in</strong>clud<strong>in</strong>g clos<strong>in</strong>g page, <strong>in</strong> token of his hav<strong>in</strong>g studied the Tender papers<br />
carefully.<br />
6.5 RATES IN FIGURES & WORDS: - All prices and other <strong>in</strong>formation like<br />
discounts etc. hav<strong>in</strong>g a bear<strong>in</strong>g on the price shall be written both <strong>in</strong> figures<br />
and <strong>in</strong> words <strong>in</strong> the prescribed offer form. In case of difference <strong>in</strong> words and<br />
figures the amount written <strong>in</strong> words will be taken <strong>in</strong>to consideration.<br />
6.6 ATTESTATION OF ALTERATION: - No scribbl<strong>in</strong>g is permissible <strong>in</strong> the<br />
tender documents. Tender conta<strong>in</strong><strong>in</strong>g erasures and alterations <strong>in</strong> the tender<br />
documents are liable to be rejected. Any correction made by the tenderer/<br />
tenderers <strong>in</strong> his/their entries must be attested by him/them.<br />
6.7 The tenderer shall submit his tender <strong>in</strong> two copies <strong>in</strong> sealed cover. Each copy<br />
of the tender shall be complete <strong>in</strong> all respects. The two copies should be<br />
30
marked "Orig<strong>in</strong>al" and “Duplicate”. The orig<strong>in</strong>al tender paper purchased from<br />
this office shall be returned duly signed along with the orig<strong>in</strong>al offer. Tenderer<br />
submitt<strong>in</strong>g downloaded tender document, should submit cost of tender document as<br />
given <strong>in</strong> tender notice <strong>in</strong> the form of Pay order/Demand Draft from a<br />
Nationalized/Scheduled IndianBank drawn <strong>in</strong> favour of Dy FA & CAO / IRPMU<br />
New Delhi along with bid.<br />
6.8 The tender shall conta<strong>in</strong> details mentioned <strong>in</strong> sub para a and b. Bids shall be<br />
sealed <strong>in</strong> envelope. All the envelopes should bear the tender number with its<br />
description and date of clos<strong>in</strong>g/open<strong>in</strong>g clearly written on it and addressed to<br />
the Chief Adm<strong>in</strong>istrative Officer, IRPMU, Shivaji Bridge (IRCOT complex)<br />
New Delhi 110001.<br />
(a)<br />
Full Technical specifications of the equipment and sub systems. A brief<br />
outl<strong>in</strong>e of the system be<strong>in</strong>g proposed along with diagrams and draw<strong>in</strong>gs,<br />
description of the equipment and materials used <strong>in</strong> the system, along with<br />
cross reference to the equipment specifications shall be enclosed.<br />
(b) The bid shall consist of the follow<strong>in</strong>g :-<br />
i) Offer letter complete. Form No.1<br />
ii)<br />
iii)<br />
iv)<br />
Schedule of Supply and Execution.<br />
Earnest money <strong>in</strong> prescribed form. (Para 5.0 of I.T.T.)<br />
Clause-wise compliance to tender conditions & Statements of deviations.<br />
Form No. 5 (Para 4 of I.T.T.)<br />
v) A copy of partnership deed and affidavit for proprietorship. (Para 7 of I.T.T.)<br />
vi)<br />
vii)<br />
viii)<br />
ix)<br />
Consortium agreement must accompany with the bid if the tenderer will<strong>in</strong>g to<br />
form consortia (Para 17 of I.T.T.).<br />
Tenderer's credentials and will<strong>in</strong>gness of orig<strong>in</strong>al manufacturer as per Form<br />
No.13 Qualify<strong>in</strong>g Criteria (General) (Para 18.1 of I.T.T.).<br />
Similar works executed. (para 18.2 of I.T.T.)<br />
Works <strong>in</strong> hand (para 18.2 of I.T.T.)<br />
x) Income Tax Clearance Certificate and audited balance sheet (Para 18.3 of<br />
I.T.T.)<br />
xi)<br />
xii)<br />
Eng<strong>in</strong>eer<strong>in</strong>g Organisation. (Para 18.5 of I.T.T.)<br />
Construction Mach<strong>in</strong>ery. (Para 18.6 of I.T.T.)<br />
31
xiii) Details of recommended Spares with quantities (S.C.C. Para 13).<br />
xiv) Details of special tools & <strong>in</strong>stallation materials (S.C.C. Para 10).<br />
xv)<br />
xvi)<br />
xvii)<br />
System performance guarantee (Para 22 of I.T.T.).<br />
Tenderers scheme of work and Time Schedule (Para 12 of I.T.T.).<br />
Complete technical data and particulars of the equipment offered, as specified<br />
<strong>in</strong> the Tender papers together with descriptive literature, leaflets etc.<br />
Draw<strong>in</strong>gs, if any, complete with list (Para 18.4 of I.T.T.).<br />
xviii) Name of manufacturers, place of manufacture and the certificate for proven<br />
design and performance (Para 18.4 of I.T.T.)<br />
xix)<br />
xx)<br />
xxi)<br />
xxii)<br />
Technical proposal of the tenderer <strong>in</strong> conformity with system design or<br />
alternative proposal of the tenderer, if any.<br />
Any other <strong>in</strong>formation desired to be submitted by the tenderer.<br />
The price of each item quoted exactly accord<strong>in</strong>g to the rate schedule given <strong>in</strong><br />
the tender document.<br />
Any other <strong>in</strong>formation as asked for <strong>in</strong> the preamble, Special conditions of<br />
contract or relevant to tender.<br />
7. CONSTITUTION OF FIRM & POWER OF ATTORNEY:<br />
7.1 Any <strong>in</strong>dividual(s) sign<strong>in</strong>g the tender or other documents connected therewith<br />
should specify whether he is sign<strong>in</strong>g: -<br />
(a) As sole proprietor of the concern or as attorney of the sole proprietor;<br />
(b) As a partner or partners of the firm;<br />
(c) As a Director, Manager or Secretary <strong>in</strong> the case of Limited Company duly<br />
authorised by a resolution passed by the Board of Directors or <strong>in</strong> pursuance of<br />
the authority conferred by Memorandum of Association.<br />
7.2 In the case of a firm not registered under the Indian Partnership Act, the<br />
names of all the exist<strong>in</strong>g partners and their full particulars should be furnished<br />
at the time of submitt<strong>in</strong>g the tender and all the partners with their full<br />
particulars or the attorney duly authorised by all of them should sign the<br />
tender and all other connected documents. The orig<strong>in</strong>al power of attorney or<br />
other documents empower<strong>in</strong>g the <strong>in</strong>dividual or <strong>in</strong>dividuals to sign should be<br />
furnished to the Purchaser for verification, if required.<br />
7.3 The Railway will not be bound by Power of Attorney granted by the tenderer<br />
or by the changes <strong>in</strong> the composition of the firm made subsequent to the<br />
execution of the contract. It may, however, recognise such power of attorney<br />
32
and advice, the cost of which will be chargeable to the contractor. These<br />
charges have been fixed at Rs.100/- (Rs. One Hundred only) payable by the<br />
tenderer at the time of submitt<strong>in</strong>g the Power of Attorney for Scrut<strong>in</strong>y and<br />
legal advice.<br />
7.4 In case where the Power of Attorney partnership deed has not been executed<br />
<strong>in</strong> English, the true and authenticated copies of the translation of the same by<br />
Advocate, authorised translators of Courts and Licensed Petition Writers<br />
should be supplied by the Contractor(s) while tender<strong>in</strong>g for the work.<br />
7.5 The cancellation of any documents such as Power of Attorney, Partnership<br />
deed etc. should be forthwith communicated by the contractor to the Railway<br />
Adm<strong>in</strong>istration <strong>in</strong> writ<strong>in</strong>g fail<strong>in</strong>g which the Railway Adm<strong>in</strong>istration shall<br />
have neither responsibility nor liability for any act so taken on the strength of<br />
the said documents.<br />
8. UNIT PRICES:<br />
8.1 It is necessary for the rate to be quoted separately on unit basis for each item<br />
shown <strong>in</strong> the Schedule of works.<br />
8.2 The unit Prices should be quoted by the Contractor after tak<strong>in</strong>g all the<br />
relevant factors <strong>in</strong>to consideration and these should be Firm and all <strong>in</strong>clusive<br />
without any variation clauses. The prices shall be quoted <strong>in</strong> Indian Rupees for<br />
the units under metric system. Reference may be made to para-38 of Special<br />
Conditions of Contract.<br />
8.3 Necessary 'D' form will be issued by the Railway adm<strong>in</strong>istration on<br />
Contractor’s name only for supply of materials where Central Sales Tax is<br />
levied. The tenderer may take this consideration <strong>in</strong>to account while quot<strong>in</strong>g<br />
the rates.<br />
9. VALIDITY OF OFFER:<br />
9.1 The tenderer shall keep the offer open for a m<strong>in</strong>imum period of 180 days from<br />
the date of open<strong>in</strong>g of the tender. With<strong>in</strong> that period, the tenderer can not<br />
withdraw his offer subject to the period be<strong>in</strong>g extended further if required by<br />
mutual agreement from time to time. Any contravention of the above<br />
condition will make the tenderer liable for forfeiture of his Earnest Money<br />
Deposit.<br />
10. RATES DURING NEGOTIATION:<br />
10.1 The tenderer/s shall not <strong>in</strong>crease his/their quoted rates <strong>in</strong> case the Railway<br />
Adm<strong>in</strong>istration negotiate for reduction of rates, such a negotiation shall not<br />
amount to cancellation or withdrawal of the orig<strong>in</strong>al offer and the rates<br />
orig<strong>in</strong>ally quoted will be b<strong>in</strong>d<strong>in</strong>g on the tenderer/s.<br />
33
11. INCOME TAX CLEARANCE CERTIFICATE:<br />
11.1 The Tenderers are required to enclose along with the tender a Photostat copy<br />
of the valid Income Tax clearance certificate duly attested by Notary Public.<br />
The Tenderer will however submit the orig<strong>in</strong>al Income Tax clearance<br />
certificate whenever asked for by the purchaser for verification.<br />
12. PERIOD OF COMPLETION & TIME PROGRESS GRAPH:<br />
12.1 The works/work are/is to be completed with<strong>in</strong> a period as mentioned <strong>in</strong><br />
preamble from the date of issue of Letter of Acceptance of the tender.<br />
12.2 The Tenderer shall enclose with his offer the scheme of work and time<br />
schedule <strong>in</strong> the form of PERT chart <strong>in</strong>dicat<strong>in</strong>g all activities & show<strong>in</strong>g the<br />
period of time that he will take for the various items of work listed there<strong>in</strong>.<br />
The Tenderer shall <strong>in</strong>dicate <strong>in</strong> the form of notes to the schedule the<br />
assumptions and the basis adopted for the preparation of the time schedule.<br />
12.3 The Successful Tenderer shall, however, submit their f<strong>in</strong>al programme <strong>in</strong><br />
consultation with Eng<strong>in</strong>eer of the project <strong>in</strong> terms of clause 6 of Special<br />
Condition of Contract.<br />
13. OPENING OF TENDER:<br />
13.1 The tender will be opened at the time & date of open<strong>in</strong>g of the tender given <strong>in</strong><br />
the preamble <strong>in</strong> presence of such Tenderers/Representatives who choose to be<br />
present.<br />
13.2 If the offers are sent by post, should be sent only by registered post with<br />
acknowledgement due addressed to the Chief Adm<strong>in</strong>istrative Officer,<br />
IRPMU, Shivaji Bridge (IRCOT complex) New Delhi 110001 before the<br />
clos<strong>in</strong>g time and date given <strong>in</strong> preamble.<br />
14. NON-TRANSFERABILITY & NON-REFUNDABILITY: -<br />
The tender documents are not transferable. The cost of tender paper is not<br />
refundable.<br />
15. ERRORS OMISSIONS & DISCREPANCIES:<br />
The Contractor(s) shall not take any advantage of any mis<strong>in</strong>terpretation of the<br />
conditions due to typ<strong>in</strong>g or any other error and if <strong>in</strong> doubt, shall br<strong>in</strong>g it to the<br />
notice of the Eng<strong>in</strong>eer, without delay. In case of any contradiction only the<br />
pr<strong>in</strong>ted rules, and books should be followed and no claim for the<br />
mis<strong>in</strong>terpretation shall be enterta<strong>in</strong>ed.<br />
16. WRONG INFORMATION BY TENDERER:<br />
34
If the tenderer/s deliberately gives/give wrong <strong>in</strong>formation <strong>in</strong> his/their tender,<br />
creates/create circumstances for the acceptance of his/their tender, the<br />
Railway reserve the right to reject such tender at any stage.<br />
17. CONSORTIUM BIDS:<br />
17.1 In view of nature of work covered <strong>in</strong> the Bid documents, it is anticipated that<br />
some of the <strong>in</strong>tend<strong>in</strong>g bidders will pool their resources and experience to form<br />
consortia. In their own <strong>in</strong>terest, the bidders who form such consortia are<br />
advised to <strong>in</strong>vestigate capabilities, availability of resources, experienced<br />
personnel, f<strong>in</strong>ancial soundness, past experience and concurrent engagements<br />
of constitut<strong>in</strong>g partners.<br />
17.2 Consortia of bidders, if any must clearly def<strong>in</strong>e role/scope of work of each<br />
partner/member. Further the legal agreement for a consortium must<br />
accompany the bid and should clearly def<strong>in</strong>e the leader of such a consortium<br />
who will be the prime contractor and will be responsible for timely<br />
completion of work as also dur<strong>in</strong>g execution of work, if awarded, co-ord<strong>in</strong>ate<br />
with Purchaser on behalf of the consortium, receive payments for the works<br />
executed and be liable for due performance of the contract <strong>in</strong> all respect. The<br />
tenderer must clearly write whether the offer is Consortium Bid or not.<br />
Remarks like ‘Complied’, ‘Noted’ will not suffice. In absence of clear<br />
submission, the offer will not be considered as Consortium Bid.<br />
17.3 Qualification documents, details etc., must however, be provided for each<br />
member firm complete <strong>in</strong> all respects strictly <strong>in</strong> requisite pro-forma.<br />
17.4 A consortium formed will not be subject to alteration with regard to change <strong>in</strong><br />
constitut<strong>in</strong>g firms and/or reorientation of roles. Any changes if proposed by<br />
consortium to take advantage of certa<strong>in</strong> developments dur<strong>in</strong>g evaluation stage<br />
will render the bid liable to be rejected. As all details are required to be<br />
furnished along with the bids and should be critically exam<strong>in</strong>ed dur<strong>in</strong>g<br />
evaluation of bids, it is imperative that such details should have been<br />
thoroughly exam<strong>in</strong>ed as a safeguard aga<strong>in</strong>st a possible disqualification of bids<br />
on these grounds.<br />
17.5 All partners of the consortium shall be jo<strong>in</strong>tly and severally liable to the<br />
purchaser for the execution of the entire contract <strong>in</strong> accordance with its terms.<br />
18. QUALIFICATION CRITERIA:<br />
18.1 GENERAL:<br />
18.1.1 Qualification criteria under this para lays down m<strong>in</strong>imum acceptable<br />
qualifications <strong>in</strong> various areas to ensure that qualified bidder has necessary<br />
experience, expertise, f<strong>in</strong>ancial and human resources to successfully complete<br />
the project. In case of a consortium bid, the qualification document details<br />
etc. must be provided for each member of consortium.<br />
35
18.1.2 If the tenderer proposes to buy any equipment from other suppliers/sources,<br />
documents <strong>in</strong>dicat<strong>in</strong>g their will<strong>in</strong>gness to supply the equipment and provide<br />
technical support to the tenderer that may be required dur<strong>in</strong>g <strong>in</strong>stallation,<br />
commission<strong>in</strong>g and warranty period and later on directly to the railways, shall<br />
be <strong>in</strong>cluded <strong>in</strong> the tender. Qualification documents and other details for such<br />
supplier shall be <strong>in</strong>cluded <strong>in</strong> the tender.<br />
18.1.3 The tenderer should submit the details of experience <strong>in</strong> works and services <strong>in</strong><br />
projects of similar nature br<strong>in</strong>g<strong>in</strong>g out clearly the expertise <strong>in</strong> the equipment<br />
manufacture, <strong>in</strong>stallation of IP based network.<br />
18.1.4 The tenderer shall complete the pro-forma at Form No.13 and submit a<br />
certificate from the orig<strong>in</strong>al user for whom the project was undertaken<br />
certify<strong>in</strong>g the date of award of contract, date of completion, date of<br />
commission<strong>in</strong>g and the present work<strong>in</strong>g state of the system so established.<br />
The tenderer shall provide these details for all the projects that he has<br />
executed which satisfy the m<strong>in</strong>imum requirements <strong>in</strong> each case.<br />
18.2 MINIMUM ELIGIBILITY:<br />
The tenderer or the consortium should have m<strong>in</strong>imum eligibility criteria as<br />
given <strong>in</strong> the table below:<br />
18.2.1 The tenderer should have completed successfully at least one work of similar<br />
nature to that of this tender cost<strong>in</strong>g not less than 35% of advertised value of the<br />
tender, <strong>in</strong> the last three f<strong>in</strong>ancial years (i.e. current year and three previous<br />
f<strong>in</strong>ancial years.) Mean<strong>in</strong>g of similar work for this tender is as under:<br />
“Supply, Installation, test<strong>in</strong>g and commission<strong>in</strong>g of IP based network”<br />
18.2.2 As a proof of sufficient f<strong>in</strong>ancial capacity and organizational resources, contractor<br />
should have received total payment aga<strong>in</strong>st satisfactory execution of<br />
completed/ongo<strong>in</strong>g works (of all types) dur<strong>in</strong>g preced<strong>in</strong>g three years as per<br />
current ITCC/Audited Balance Sheet of a value not less than 150% of the<br />
advertised cost of work.<br />
18.3 FINANCIAL:<br />
18.3.1 The tenderer should produce:<br />
i) Latest Income Tax clearance certificate.<br />
ii)<br />
Audited Balance Sheet and Income statement of just concluded year. Audited<br />
Balance sheets of last 3 years shall be supplied to assess f<strong>in</strong>ancial soundness f<br />
the tenderer<br />
18.3.2 The tenderer shall furnish such documents as to establish the f<strong>in</strong>ancial<br />
soundness of his company as well as that of other companies if more than one<br />
36
company is <strong>in</strong>volved <strong>in</strong> bidd<strong>in</strong>g for this tender. The latest balance sheet,<br />
audited or certified by a neutral agency shall be furnished.<br />
18.3.3 The bidder shall submit required <strong>in</strong>formation <strong>in</strong> a separate Annexure and also<br />
a certificate from the user for whom the project was executed about the<br />
correctness of the dates <strong>in</strong>volved and satisfactory performance of the<br />
equipment/system.<br />
18.4 TECHNOLOGY & EQUIPMENT:<br />
18.4.1 The requirement of the system has been described <strong>in</strong> para 2 of Preamble.<br />
System offered shall comply with this para and as per the technical<br />
specification of the tender document.<br />
18.4.2 The tenderer shall clearly identify the sources from which the equipment to be<br />
supplied under this tender will be obta<strong>in</strong>ed. Specific attention is drawn to para<br />
16 of Special Conditions of Contract.<br />
18.4.2.1The bidders should clearly <strong>in</strong>dicate the technology for which the offer has<br />
been made. If it is a case of transfer of technology, the details such as name of<br />
technology, name of company etc. should be given and the copy of<br />
Memorandum of Understand<strong>in</strong>g for transfer of technology and RBI clearance,<br />
if applicable, should be enclosed.<br />
18.4.2.2 Preference will be given to vender offer<strong>in</strong>g transfer of technology and<br />
subsequent manufactur<strong>in</strong>g <strong>in</strong> India.<br />
18.4.3 All equipment proposed to be used shall be of proven design and performance.<br />
The equipment of same family shall have been successfully commissioned<br />
and rema<strong>in</strong>ed <strong>in</strong> service at least for a period of two year on the date of tender<br />
submission. Certificate from the actual user of the equipment about<br />
satisfactory performance shall be enclosed with the tender. Any equipment<br />
proposed to be manufactured with foreign collaborator shall be covered by the<br />
performance guarantee of the foreign collaborator.<br />
Equipment not available <strong>in</strong>digenously nor proposed to be manufactured with<br />
foreign collaboration with<strong>in</strong> the time schedule of the contract, shall be<br />
covered by the performance guarantee of the orig<strong>in</strong>al foreign manufacturer.<br />
Such equipment shall have been <strong>in</strong> field service at least for a period of one<br />
year on the date of submission of the tender. Certificate from the actual user<br />
of the equipment about the satisfactory performance shall be enclosed with<br />
the tender. The tenderer shall submit a declaration from those orig<strong>in</strong>al<br />
equipment manufacturers regard<strong>in</strong>g their Indian agent and the service support<br />
available with<strong>in</strong> the country.<br />
18.5 ENGINEERING ORGANISATION:<br />
37
18.5.1 The tenderer shall make an assessment of the requirement of personnel for<br />
execution of this project and shall give details as to how he proposes to<br />
mobilise all technical manpower required for the project. Details of the<br />
qualification and experience of the personnel identified for project execution<br />
shall be <strong>in</strong>cluded <strong>in</strong> the tender.<br />
18.5.2 The successful tenderer shall appo<strong>in</strong>t a Project Manager who would have<br />
adequate experience <strong>in</strong> project management of similar nature, unless the<br />
railway so desire, the Project Manager should preferably be reta<strong>in</strong>ed till all<br />
the obligations under the contract have been fulfilled.<br />
18.5.3 The tenderers shall have at least one graduate Eng<strong>in</strong>eer and two experienced<br />
supervisors (Diploma Holders) hav<strong>in</strong>g 5/6 years experience <strong>in</strong> the relevant<br />
field, supported by at least 5 Nos. of artisan staff.<br />
18.5.4 Tenderer shall advise the number of Eng<strong>in</strong>eers, Supervisors and Cable<br />
Jo<strong>in</strong>ters/Artisans employed by him or go<strong>in</strong>g to be employed by him with their<br />
names, qualifications bio-data and experience <strong>in</strong> this particular trade under<br />
consideration along with the Tender positively. Irrevocable letters of<br />
commitment of the said Supervisors and Key Technicians/Artisans for do<strong>in</strong>g<br />
the work shall be furnished along with Tender Papers if they are not already<br />
<strong>in</strong> employment of the Tenderer.<br />
18.6 CONSTRUCTION MACHINERY:<br />
The firm should have m<strong>in</strong>imum construction mach<strong>in</strong>ery, Tools and plants, test &<br />
measur<strong>in</strong>g <strong>in</strong>struments, Vehicles etc. Details of which will be furnished by them<br />
along with the bid.<br />
No tools and plants, scaffold<strong>in</strong>g materials for shutter<strong>in</strong>g, enter<strong>in</strong>g, shor<strong>in</strong>g etc.<br />
shall be supplied by the Railway and contractor will have to make his own<br />
arrangement for execution of the work.<br />
38
19 DETERMINATION OF RESPONSIVENESS –<br />
19.1 Purchaser will determ<strong>in</strong>e whether each bid is substantively responsive to the<br />
equipment of the bidd<strong>in</strong>g documents.<br />
19.2 For the purpose of this Clause, a substantively responsive bid is one, which<br />
conforms to all the terms, conditions and specifications of the bidd<strong>in</strong>g<br />
documents without material deviation or reservation. A material deviation or<br />
reservation is one, which affects <strong>in</strong> substantial way the scope, quality or<br />
performance of the works, or which limits <strong>in</strong> any substantial way, <strong>in</strong>consistent<br />
with the bidd<strong>in</strong>g documents, the Purchaser’s right or the bidder’s obligations<br />
under the Contract and the rectification of which deviation or reservation<br />
would affect unfairly the competitive position of other bidders present<strong>in</strong>g<br />
substantively responsive bids.<br />
20. CORRECTION OF ERRORS –<br />
20.1 Bids determ<strong>in</strong>ed to be substantively responsive will be checked by the<br />
Purchaser for any arithmetic errors <strong>in</strong> computation and summation. The<br />
Purchaser will correct errors as follows: -<br />
a) Where there is a discrepancy between amounts <strong>in</strong> figures and <strong>in</strong> words, the<br />
amount <strong>in</strong> words will <strong>gov</strong>ern; and<br />
b) Where there is a discrepancy between the unit rate and the total amount<br />
derived from the multiplication of the unit rate and the quantity, the unit rate<br />
as quoted will <strong>gov</strong>ern, unless <strong>in</strong> the op<strong>in</strong>ion of the Purchaser there is an<br />
obviously gross misplacement of the decimal po<strong>in</strong>t <strong>in</strong> the unit rate, <strong>in</strong> which<br />
event the total amount as quoted will <strong>gov</strong>ern and the unit rate will be<br />
corrected.<br />
20.2 The amount stated <strong>in</strong> the Form of Bid will be adjusted by the Purchaser <strong>in</strong><br />
accordance with the above procedure for the correction of errors and with the<br />
concurrence of the bidder, shall be considered as b<strong>in</strong>d<strong>in</strong>g upon the bidder. If<br />
the bidder does not accept the corrected amount of bid, his bid will be rejected<br />
and the bid security will be forfeited.<br />
21. CONVERSION TO SINGLE CURRENCY i.e. RUPEES: -<br />
Should there be any necessity of conversion to a s<strong>in</strong>gle currency i.e. Indian<br />
Rupees for the purpose of evaluation and comparison of offers, the Purchaser<br />
will convert the foreign currency content of each tender received <strong>in</strong>to Rupees<br />
at the sell<strong>in</strong>g exchange rate for each currency established by the Reserve Bank<br />
of India or any other Commercial Bank <strong>in</strong> the Purchaser's country, for similar<br />
transactions on the earlier of the follow<strong>in</strong>g date, namely, on the day twenty<br />
eight days before the latest date of tender open<strong>in</strong>g.<br />
39
22. SYSTEM PERFORMANCE GUARANTEE:<br />
22.1 S<strong>in</strong>ce the design of the system to achieve the end objective shall be checked<br />
and confirmed by the contractor and the supply of the materials will be<br />
accord<strong>in</strong>g to this system design, the tenderer shall give unqualified and<br />
unconditional guarantee that when the equipment supplied by him is <strong>in</strong>stalled<br />
and commissioned at site, it shall achieve the desired objective and that <strong>in</strong> the<br />
event of performance of the system when <strong>in</strong>stalled not comply<strong>in</strong>g with the<br />
end objective or with the specifications, he shall provide further <strong>in</strong>puts to<br />
enable the Railways to realise the end objectives with full compliance of the<br />
specifications conta<strong>in</strong>ed <strong>in</strong> these documents. No additional payment will be<br />
made to the contractor for supply of any additional goods and service<br />
required <strong>in</strong> this regard.<br />
22.2 This certificate <strong>in</strong> the pro-forma given <strong>in</strong> Form No.7, shall accompany the<br />
offer. Absence of this certificate which will form part of the agreement shall<br />
disqualify the tenderer automatically.<br />
23. AUTHORITY FOR ACCEPTANCE:<br />
The authority for the acceptance of the tender will rest with the Purchaser.<br />
The purchaser shall not be bound to accept the lowest or any tender or to<br />
assign any reason for non-acceptance or rejection of a tender. The purchaser<br />
reserves the right to accept any tender <strong>in</strong> respect of the whole or any portion<br />
of the work specified <strong>in</strong> the tender paper or to sub-divide the work among<br />
different Tenderers or to reduce the work or to accept any tender for less<br />
than the tendered quantities without assign<strong>in</strong>g any reason whatsoever.<br />
24. PURCHASE PREFERENCE:<br />
10% Purchase preference as applicable of lowest valid bid price, other th<strong>in</strong>gs<br />
be<strong>in</strong>g equal for product & services will be admissible for Central Public<br />
Sector Under tak<strong>in</strong>g <strong>in</strong> this tender subject to satisfaction of all other Terms &<br />
Conditions.<br />
25. AGREEMENT:<br />
The successful tenderer/s shall be required to execute an agreement with the<br />
President of India act<strong>in</strong>g through the Chief Adm<strong>in</strong>istrative Officer, IRPMU,<br />
Shivaji Bridge (IRCOT Complex) New Delhi 110001 or his accredited officer<br />
for carry<strong>in</strong>g out the work accord<strong>in</strong>g to the tender documents as <strong>in</strong>dicated <strong>in</strong><br />
para 2 of Special Conditions of Contract.<br />
26. TENDERER'S ADDRESS:<br />
Tenderer shall state <strong>in</strong> the tender his postal address fully and clearly. Any<br />
communication sent to the tenderers by post at his said address, shall be<br />
40
deemed to have reached the tenderer duly & timely, notwithstand<strong>in</strong>g the fact<br />
that the communication could not reach the tenderer at all or <strong>in</strong> time for<br />
whatever reason. Important documents shall be sent by Registered post.<br />
27. FOREIGN EXCHANGE:<br />
No foreign exchange and/or import license will be released /provided to the<br />
contractor <strong>in</strong> connection with this contract.<br />
*****<br />
41
Section – II<br />
Chapter – 2<br />
SPECIAL<br />
CONDITIONS OF<br />
CONTRACT<br />
42
Section – II<br />
Chapter – 2<br />
SPECIAL CONDITIONS OF CONTRACT<br />
INDEX<br />
1. TENDER DOCUMENTS:<br />
2. AGREEMENT:<br />
3. CONTRACT PERFORMANCE GUARANTEE and SECURITY DEPOSIT<br />
4. CONTRACTOR'S OFFICE & STORES DEPOT<br />
5. USE OF RAILWAY LAND:<br />
6. PROGRAMME OF WORK:<br />
7. COMPETENT SUPERVISORS:<br />
8. SPECIFIED RAILWAY STORES:<br />
9. OTHER RAILWAY STORES:<br />
10. TESTING & MEASURING INSTRUMENTS, SPECIAL TOOLS AND<br />
INSTALLATION MATERIAL<br />
11. STORES TO BE SUPPLIED BY CONTRACTOR:<br />
12. SUPPLY OF TECHNICAL LITERATURES, DOCUMENTATION,<br />
DRAWINGS & COMPLETION PLANS ETC.<br />
13. SPARES:<br />
14. LONG TERM AVAILABILITY OF SPARES AND SYSTEM SUPPORT:<br />
15. QUALITY ASSURANCE:<br />
16. EQUIPMENT EVALUATION AND APPROVAL<br />
17. INSPECTION OF MATERIALS<br />
18. INSPECTION OF WORKS<br />
19. QUANTUM OF WORK AND VARIATION IN QUANTITIES<br />
43
20. RIGHT OF RAILWAY TO KEEP BACK FROM THE CONTRACT ANY<br />
PORTION OF WORK:<br />
21. SUBLETTING AND ASSIGNMENT<br />
22. EXECUTION OF WORK<br />
23. PROGRESS REPORTING<br />
24. MAINTENANCE OF WORKS<br />
25 CLEARANCE OF SITE<br />
26. PROVISIONAL ACCEPTANCE<br />
27. PLACING IN SERVICE & MAINTENANCE SUPERVISION<br />
28 FINAL ACCEPTANCE<br />
29. WARRANTY<br />
30. TRAINING<br />
31. INFRINGEMENT OF PATENTS<br />
32. LICENSE AS PER GOVT. OF INDIA CONTRACT LABOUR ACT<br />
33. DEFAULT & DELAYS<br />
34. LOSS SUSTAINED DUE TO DEFAULT AND DELAY<br />
35. PENALTY FOR DELAY IN COMPLETION<br />
36. EXTENSION OF TIME<br />
37. CONTRATOR'S LIABILITIES FOR COSTS AND DAMAGES<br />
38. UNIT PRICES<br />
39. MEASUREMENT OF WORKS:<br />
40. TERMS OF PAYMENT<br />
41. FINAL PAYMENT<br />
42. FINAL SETTLEMEN<br />
43. CERTIFICATE FOR MODVAT BENEFITS ON BILLS:<br />
44
44. DEDUCTION FROM ON ACCOUNT PAYMENT BILLS<br />
45. TAXES<br />
46. MOBILIZATION ADVANCE (Not applicable <strong>in</strong> Present tender)<br />
47. INSURANCE:<br />
48. FORCE MAJEURE CLAUSE:<br />
49. SETTLEMENT OF DISPUTE AND ARBITRATION:<br />
50. DEMAND FOR ARBITRATION:<br />
*****<br />
45
SPECIAL CONDITIONS OF CONTRACT<br />
1. TENDER DOCUMENTS:<br />
1.1 The goods and services required, bidd<strong>in</strong>g procedure and contract terms are<br />
prescribed <strong>in</strong> the tender documents. Bid documents can be obta<strong>in</strong>ed from the<br />
office of the Chief Adm<strong>in</strong>istrative Officer / IRPMU, (IRCOT complex) Shivaji<br />
Bridge, New Delhi-110001, after deposit<strong>in</strong>g Rs.10000.00 only <strong>in</strong> the form of bank<br />
draft made <strong>in</strong> favour of Dy. FA&CAO, IRPMU, Shivaji Bridge, New Delhi-<br />
110001 on any work<strong>in</strong>g day Between 1030 hrs to 1500 hrs from 22/02/08 to<br />
24/3/08 or the corrigendum thereof. The attention of tenderer is <strong>in</strong>vited to the<br />
follow<strong>in</strong>g documents:<br />
Section-I:<br />
Preamble along with Schedule of Requirement.<br />
Section-II: I) Instructions to tenderers and conditions of tender<strong>in</strong>g.<br />
II) Special Conditions of Contract.<br />
III) Tender Forms and Annexure etc.<br />
Section-III:<br />
Technical Supplement along with technical Instructions, specifications and<br />
Draw<strong>in</strong>gs etc. for the scope of the work <strong>in</strong>cluded <strong>in</strong> this tender.<br />
Miscellaneous:<br />
I) General Conditions of contract (G.C.C.) as amended by advance<br />
correction slips issued up to date.<br />
II) IRS conditions of contract for the stores department with up to date<br />
modification (CCSS).<br />
General Conditions of Contract (G.C.C.) as amended by advance correction slips<br />
issued up to-date and IRS conditions of contract for the stores department with up<br />
to date modification (CCSS) can be obta<strong>in</strong>ed, if need be, from the office of the<br />
CAO/IRPMU after pay<strong>in</strong>g the cost prescribed for it <strong>in</strong> the form of Bank Draft <strong>in</strong><br />
favour of Dy FA&CAO/IRPMU, Shivaji Bridge, New Delhi.<br />
1.2 If the Tender submitted by a tenderer is accepted and the contract awarded to the<br />
Tenderer, the various works com<strong>in</strong>g under purview of the contract shall be<br />
<strong>gov</strong>erned by tender documents mentioned above. Where there is any conflict<br />
between the <strong>in</strong>structions to tenderers and conditions of tender<strong>in</strong>g and special<br />
conditions of contract, Tender forms, annexure etc. on one hand and General<br />
Conditions of Contract on the other, the former shall prevail.<br />
46
1.3 Any Special conditions stated by the Tenderer <strong>in</strong> the cover<strong>in</strong>g letter submitted<br />
along with the tender shall be deemed to be a part of the Contract to such extent<br />
only, as have been explicitly accepted by the Railway.<br />
1.4 The expression General conditions of contract (GCC), wherever occurr<strong>in</strong>g <strong>in</strong> these<br />
papers shall be deemed to mean the General conditions of contract, 1969 of<br />
Northern Railway department as amended by advance correction slips issued upto-date.<br />
2. AGREEMENT:<br />
The successful Tenderer shall with<strong>in</strong> 15 days after hav<strong>in</strong>g been called upon by<br />
notice to do so be bound to execute an agreement based on accepted rates and<br />
conditions, <strong>in</strong> such form as the Railways may prescribe, and lodge the same with<br />
the Railway together with the conditions of contract, specifications and<br />
Schedule of prices referred to there<strong>in</strong> duly completed. The form for agreement is<br />
<strong>in</strong>cluded <strong>in</strong> Section II, Chapter-III, and (Form No.3).<br />
3. CONTRACT PERFORMANCE GUARANTEE and SECURITY DEPOSIT<br />
3.1 SECURITY DEPOSIT:<br />
(i)<br />
(ii)<br />
(iii)<br />
(iv)<br />
Security deposit shall be 5% of the contract value<br />
The rate of recovery shall be @10% of the bill amount till the full security<br />
deposit is recovered.<br />
Security deposit will be recovered only from the runn<strong>in</strong>g bill of the<br />
contract and no other mode of collect<strong>in</strong>g SD as <strong>in</strong> the form of <strong>in</strong>struments<br />
like BG, FD etc shall be accepted towards Security Deposit.<br />
No <strong>in</strong>terest will be payable upon the Security Deposit or amounts<br />
payable to the contractor under this contract.<br />
Security Deposit will be returned to the contractor after six months of<br />
physical completion of work as certified by competent authority and<br />
settlement of all dues and disputes. The competent shall normally be<br />
the authority, who is competent to sign the contract. If this competent<br />
authority is of the rank lower than the JA grade, then a JA grade officer<br />
(concerned with the work) should issue the certificate. The certificate<br />
<strong>in</strong>ter alia should mention that the work has been completed <strong>in</strong> all<br />
respects & that all the contractual obligations have been fulfilled by the<br />
contractors and that there is no due from the contractor to Railways<br />
aga<strong>in</strong>st the contract concerned. Before releas<strong>in</strong>g the Security Deposit,<br />
contractor concerned should submit an unconditional & unequivocal no<br />
claim certificate.<br />
3.1.1 PERFORMANCE GUARANTEE<br />
47
The procedure for obta<strong>in</strong><strong>in</strong>g Performance Guarantee is outl<strong>in</strong>ed below:-<br />
(a).<br />
(b).<br />
The successful bidder shall submit a Performance Guarantee (PG) <strong>in</strong><br />
the form of an irrevocable bank guarantee amount<strong>in</strong>g to 5% of the<br />
contract value.<br />
A Performance Guarantee shall be submitted by the successful bidder<br />
after the letter of acceptance has been issued, but before sign<strong>in</strong>g of the<br />
agreement. The agreement should normally be signed with<strong>in</strong> 15 days<br />
after the issue of LOA and Performance Guarantee shall also be<br />
submitted with<strong>in</strong> this time limit. This guarantee shall be <strong>in</strong>itially valid up to<br />
the stipulated date of completion plus 60 days beyond that. In case, the<br />
time for completion of work gets extended, the contractor shall get the<br />
validity of Performance Guarantee extended to cover such extended time<br />
for completion of work plus 60 days.<br />
(c ). The Performance Guarantee (PG) shall be released after the physical<br />
completion of the work based on the “Completion Certificate” issued by<br />
the competent authority stat<strong>in</strong>g that the contractor has completed the<br />
work <strong>in</strong> all respects satisfactorily . The security deposit, however, shall be<br />
released only after the expiry of the ma<strong>in</strong>tenance period and after pass<strong>in</strong>g<br />
the f<strong>in</strong>al bill based on “NO Claim Certificate.<br />
(d).<br />
(e).<br />
wherever the contracts is resc<strong>in</strong>ded, the security deposit shall be forfeited<br />
and Performance Guarantee shall be encashed and the balance work<br />
shall be got done <strong>in</strong>dependently without risk and cost of the failed<br />
contractor. The failed contractor shall be debarred from participat<strong>in</strong>g <strong>in</strong><br />
the tender for execut<strong>in</strong>g the balance work. If the failed contractor is a JV<br />
or a partnership firm, then every member/partner of such a firm shall be<br />
debarred from participat<strong>in</strong>g <strong>in</strong> the tender for the balance work either <strong>in</strong><br />
his/her <strong>in</strong>dividual capacity or as a partner of any other JV/partnership firm.<br />
The Eng<strong>in</strong>eer shall not make a claim under the Performance Guarantee<br />
except for amounts to which the President of India is entitled under the<br />
contract (not withstand<strong>in</strong>g and /or without prejudice to any other<br />
provisions <strong>in</strong> the contract agreement) <strong>in</strong> the event of:<br />
1. Failure by the contractor to extend the validity of the Performance<br />
Guarantee as described here<strong>in</strong> above, <strong>in</strong> which event the<br />
Eng<strong>in</strong>eer may claim the full amount of the Performance<br />
Guarantee.<br />
2. Failure by contractor to pay President of India any amount due,<br />
either as agreed by the contractor or determ<strong>in</strong>ed under any of the<br />
Clauses/Conditions of the agreement, with<strong>in</strong> 30 days of the<br />
service of notice to this effect by Eng<strong>in</strong>eer.<br />
3. The contract be<strong>in</strong>g determ<strong>in</strong>ed or resc<strong>in</strong>ded under provision of the<br />
GCC the Performance Guarantee shall be forfeited <strong>in</strong> full and shall<br />
be absolutely at the disposal of the President of India.<br />
4. CONTRACTOR'S OFFICE & STORES DEPOT<br />
48
The Contractor shall, with<strong>in</strong> a month of issue of letter of acceptance of tender,<br />
establish an office and store depot at a convenient place for receiv<strong>in</strong>g and stor<strong>in</strong>g<br />
equipments and materials and progress<strong>in</strong>g field work expeditiously <strong>in</strong><br />
consultation and with the approval of the purchaser. He shall <strong>in</strong>timate the<br />
purchaser and address there of to which all correspondence should be sent. Any<br />
communication sent to the contractor by post at his said address shall be deemed<br />
to have reached the contractor duly and <strong>in</strong> time. Important documents shall be<br />
sent by Registered post.<br />
5. USE OF RAILWAY LAND:<br />
Use of Railway land required by the Contractor for constructions of temporary<br />
offices, quarter(s), hutments etc. for the staff and for stor<strong>in</strong>g materials etc., will be<br />
permitted to him/them free by Railway, if available. The location of these offices,<br />
hutments, stores etc. will be subject to the approval of the Eng<strong>in</strong>eer or his<br />
representative. The land will be restored to Railways by the Contractor(s) <strong>in</strong> the<br />
same condition as when taken over or <strong>in</strong> vacant condition as desired by the<br />
Eng<strong>in</strong>eer, after completion of the work or at any earlier day, as specified by the<br />
Eng<strong>in</strong>eer. The failure to do so will make the Contractor(s) liable to pay the cost<br />
<strong>in</strong>curred by the Railway for gett<strong>in</strong>g possession of land.<br />
6. PROGRAMME OF WORK:<br />
6.1 The Contractor shall have necessary resources to execute the work so that the<br />
entire work is completed with<strong>in</strong> a period as mentioned <strong>in</strong> the preamble from<br />
the date of issue of Letter of Acceptance of the tender. He shall also have<br />
necessary resources to take up the work of <strong>in</strong>stallation commission<strong>in</strong>g etc.<br />
simultaneously at different sites.<br />
6.2 With<strong>in</strong> a period of 30 days beg<strong>in</strong>n<strong>in</strong>g from the date of issue of Letter of<br />
Acceptance of Tender, the Contractor shall submit the detailed time Schedule for<br />
the execution of work based on the conditions <strong>in</strong> consultation with the Railway<br />
to the authority mentioned <strong>in</strong> the Preamble and approved by the latter <strong>in</strong> writ<strong>in</strong>g<br />
before commencement of the work.<br />
6.3 The Contractor shall be held responsible for the execution of the work accord<strong>in</strong>g<br />
to the Programme given above for the execution of the work and also the various<br />
clauses of the technical supplement, Technical specifications, <strong>in</strong>structions and<br />
draw<strong>in</strong>gs available separately. Failure to comply with any of these will be dealt<br />
with as per provision laid down <strong>in</strong> General Conditions of Contract.<br />
6.4 The Contractor on his part will have to employ supervisors, technicians and<br />
labour <strong>in</strong> full strength commensurate with work<strong>in</strong>g area available. He will also<br />
arrange match<strong>in</strong>g materials and equipment to complete the job most<br />
expeditiously so as to ensure that the work is completed <strong>in</strong> phases with<strong>in</strong> the<br />
stipulated period.<br />
49
6.5 Inspection Register shall be ma<strong>in</strong>ta<strong>in</strong>ed at the site of work by the Railway<br />
where<strong>in</strong> <strong>in</strong>structions regard<strong>in</strong>g the work<strong>in</strong>g etc. shall be recorded by the<br />
Eng<strong>in</strong>eer or his executive subord<strong>in</strong>ates. It is expected of the Contractor or his<br />
representative at the site to note such <strong>in</strong>structions whenever asked upon to do so<br />
and take action accord<strong>in</strong>gly.<br />
6.6 No facility whatsoever, e.g. provisions of approach road and provision of<br />
temporary level cross<strong>in</strong>g etc. will be provided by Railway for cart<strong>in</strong>g materials.<br />
Approach roads with<strong>in</strong> the Railway limits can be used for cart<strong>in</strong>g materials.<br />
6.7 The contractor will programme his work <strong>in</strong> such a manner so as not to <strong>in</strong>terfere <strong>in</strong><br />
the work<strong>in</strong>g and movement of tra<strong>in</strong>s. No extra payment shall be allowed on this<br />
account and for tak<strong>in</strong>g any precautions or wastage of contractor's labour, time etc.<br />
due to tra<strong>in</strong> work<strong>in</strong>g.<br />
7 COMPETENT SUPERVISORS:<br />
7.1 The Contractor shall place and keep competent Representatives /<br />
Supervisors / Eng<strong>in</strong>eers, as his representative at the work sites who will be<br />
authorised to receive and acknowledge materials issued by the Railway and<br />
take all orders issued by the Railway. The said representatives shall be present<br />
at site dur<strong>in</strong>g work<strong>in</strong>g hours and any written orders or <strong>in</strong>structions which the<br />
purchaser's Eng<strong>in</strong>eer may give to the said representatives of the contractor shall<br />
be deemed to have been duly given or communicated to the contractor.<br />
7.2 The contractor or his representative will accompany the Purchaser's Eng<strong>in</strong>eer or<br />
Eng<strong>in</strong>eer on <strong>in</strong>spection or proceed to their offices whenever called upon to do<br />
so.<br />
8. SPECIFIED RAILWAY STORES:<br />
8.1 The contractor shall furnish a stand<strong>in</strong>g <strong>in</strong>demnity bond for the materials and<br />
equipments supplied to him by Railways <strong>in</strong> form No.6. (Chapter 3, Section II).<br />
8.2 The Contractor shall transport material supplied by Railways to the site of work<br />
as required and no cart<strong>in</strong>g charges shall be payable by Railways.<br />
8.3 RECONCILIATION OF MATERIALS SUPPLIED BY RAILWAYS:<br />
All the materials supplied by the Purchaser shall be correctly accounted for<br />
and the quantities reconciled on completion of the work by the contractor. On<br />
completion of the work all surplus materials supplied by the Purchaser together<br />
with the ones found defective or that have became defective or broken on<br />
account of defective materials and/or workmanship shall be returned to him by the<br />
contractor.<br />
If the contractor fails to return excess and unused materials supplied by the<br />
railway or if there are any shortages dur<strong>in</strong>g f<strong>in</strong>al reconciliation, their cost there<br />
50
of shall be recovered by the Purchaser from the Contractor at the books rate plus<br />
railway freight, handl<strong>in</strong>g, load<strong>in</strong>g, supervision and other <strong>in</strong>cidental charges at the<br />
rates fixed by the railway. To this will be added an <strong>in</strong>crease of 100%.<br />
8.5 CONSIGNEE:<br />
The contractor should consign, if need be, all the materials to 'self' to the nearest<br />
stations where materials can be booked for stack<strong>in</strong>g before erection. For such<br />
items, as admit part payment on receipt by the Railway, can be booked to store<br />
go-down of Sr Section Eng<strong>in</strong>eer/stores / Nangloi, where from the materials shall<br />
be handed over to the contractor for <strong>in</strong>stallation. However transportation<br />
charges to the site of work, taxes, octroi etc and all handl<strong>in</strong>g charges for each such<br />
item shall be borne by the contractor.<br />
8.6 Pack<strong>in</strong>g and forward<strong>in</strong>g<br />
The contractor shall pack at his own cost the stores sufficiently and properly for<br />
transit by rail/road, air and/or sea as provided <strong>in</strong> the contract so as to ensure their<br />
be<strong>in</strong>g free from loss or damage on arrival at their dest<strong>in</strong>ation.<br />
All conta<strong>in</strong>ers (<strong>in</strong>clud<strong>in</strong>g pack<strong>in</strong>g cases, boxes, t<strong>in</strong>s, drums and wrapp<strong>in</strong>gs) <strong>in</strong><br />
which the stores are supplied by the contractor shall be considered as nonreturnable<br />
and their cost as deemed to have been <strong>in</strong>cluded <strong>in</strong> the contract price.<br />
Each bale or package shall conta<strong>in</strong> note specify<strong>in</strong>g the name and address of the<br />
Contractor the number and date of the acceptance of tender and the designation of<br />
the Controll<strong>in</strong>g officer<br />
Each bale or package delivered under the contract shall be marked by the<br />
Contractor at his own expense. Such mark<strong>in</strong>g shall be dist<strong>in</strong>ct (all previous<br />
irrelevant mark<strong>in</strong>g be<strong>in</strong>g carefully obliterated) and shall clearly <strong>in</strong>dicate the<br />
description and quantity of the stores, the name and address of the consignee, the<br />
gross weight of the package and the name of the contractor with a dist<strong>in</strong>ctive<br />
number of mark sufficient for the purpose of identification. All mark<strong>in</strong>gs shall be<br />
carried out with such material as may be found satisfactory by the <strong>in</strong>spect<strong>in</strong>g<br />
officer as regard quickness of dry<strong>in</strong>g, fastness and <strong>in</strong>delibility. Materials and<br />
Equipment meant for each station shall be packed <strong>in</strong> separate boxes and marked<br />
with the name of station, consignee and railway.<br />
The <strong>in</strong>spect<strong>in</strong>g officer may reject the stores if the stores are not packed and/or<br />
marked as aforesaid and <strong>in</strong> case where the pack<strong>in</strong>g materials are separately<br />
prescribed, if such materials are not <strong>in</strong> accordance with the terms of the contract.<br />
Such rejection of the stores by the Inspect<strong>in</strong>g Officer shall be b<strong>in</strong>d<strong>in</strong>g on the<br />
Contractor.<br />
8.7 Consignee’s right of rejection:<br />
Notwithstand<strong>in</strong>g any approval which the Inspect<strong>in</strong>g officer may have given <strong>in</strong><br />
respect of any materials or other particulars or the work or workmanship <strong>in</strong>volved<br />
51
<strong>in</strong> the performance of the contract (whether with or without any test carried out by<br />
the Contractor or the <strong>in</strong>spect<strong>in</strong>g officer or under the direction of the Inspect<strong>in</strong>g<br />
officer) and notwithstand<strong>in</strong>g delivery of the materials where so provided to the<br />
<strong>in</strong>terim consignee, it shall be lawful for the consignee, on behalf of the Railway,<br />
to reject the materials or any part, portion or consignment thereof with<strong>in</strong> a<br />
reasonable time after actual delivery thereof to him at the place or dest<strong>in</strong>ation<br />
specified <strong>in</strong> the contract if such materials or part, portion or consignment thereof<br />
is not <strong>in</strong> all respects <strong>in</strong> conformity with the terms and conditions of the contract<br />
whether on account of any loss, deterioration or damage before despatch or<br />
delivery or dur<strong>in</strong>g transit or otherwise howsoever.<br />
8.8 Security of materials:-<br />
Security of all materials <strong>in</strong> the section where the work is <strong>in</strong> progress shall be the<br />
contractor’s responsibility and he shall arrange to guard the same from theft. In<br />
the event of any loss the contractor shall be responsible to that effect and shall<br />
execute an <strong>in</strong>demnity bond for the materials that will rema<strong>in</strong> <strong>in</strong> his custody, which<br />
has been supplied by the Railway.<br />
9. OTHER RAILWAY STORES:<br />
9.1 If any material other than those specified <strong>in</strong> para 8 above is supplied by the<br />
Railways either at the Contractor's request or suo motto <strong>in</strong> order to prevent any<br />
possible delay <strong>in</strong> the execution of the works likely to occur due to the<br />
Contractor's <strong>in</strong>ability to make adequate arrangements for supply thereof or<br />
otherwise, recovery will be made from Contractor's bill at 1.5 times the cost of<br />
procurement which is <strong>in</strong>clusive of freight or rate given <strong>in</strong> schedule whichever is<br />
higher. Freight between the Railway sources of supply and Railway<br />
Stores/depot shall be to the Contractor's account.<br />
9.2 If however, the material required by the Contractor is not available <strong>in</strong> Railways<br />
stock or the Railways decide not to supply the same, be that for whatever<br />
reasons, the Railway will not be bound to arrange for the supply at the cost<br />
quoted above or at any other cost nor will this fact be accepted as an excuse for<br />
delay <strong>in</strong> execution of works.<br />
10. TESTING & MEASURING INSTRUMENTS, SPECIAL TOOLS AND<br />
INSTALLATION MATERIAL<br />
10.1 Special tools and <strong>in</strong>struments required for <strong>in</strong>stallation and ma<strong>in</strong>tenance of all the<br />
equipment shall be arranged by the tenderer <strong>in</strong> adequate quantities. All<br />
<strong>in</strong>stallation material for complete commission<strong>in</strong>g of the system shall be provided<br />
by the tenderer. Details of special tools, their quantities and unit prices shall be<br />
<strong>in</strong>dicated.<br />
10.2 All tests and measur<strong>in</strong>g <strong>in</strong>struments and other arrangements required for all the<br />
acceptance tests shall be provided by the contractor free of cost.<br />
52
11. STORES TO BE SUPPLIED BY CONTRACTOR:<br />
11.1 All materials required for the execution of the contract other than those<br />
specifically shown as be<strong>in</strong>g supplied by the Railways <strong>in</strong> this document shall be<br />
arranged and supplied by the contractor as detailed <strong>in</strong> the scope so as to realise<br />
the end objective. The materials supplied and used by the contractor shall be of<br />
best quality available.<br />
11.2. The approximate quantities of equipment and material to be supplied by<br />
contractor are <strong>in</strong>dicated <strong>in</strong> Schedule A & B of SoR. The supply of equipment and<br />
materials shall also <strong>in</strong>clude required <strong>in</strong>stallation and other materials and<br />
documents etc., which may not be specifically mentioned here<strong>in</strong>, but which are<br />
usually necessary for complet<strong>in</strong>g the work <strong>in</strong> all respects. The materials supplied<br />
and used by the contractor shall be of best quality available.<br />
12. SUPPLY OF TECHNICAL LITERATURES, DOCUMENTATION,<br />
DRAWINGS & COMPLETION PLANS ETC.<br />
12.1 The supply of equipment and materials shall <strong>in</strong>clude supply of two sets of pr<strong>in</strong>ted<br />
documents from the orig<strong>in</strong>al equipment manufacturers with each equipment. The<br />
documents should <strong>in</strong>clude:-<br />
(i)<br />
(ii)<br />
(iii)<br />
(iv)<br />
(v)<br />
(vi)<br />
All software documentation required for the equipment / system design.<br />
Design approach of the system.<br />
Functions achieved <strong>in</strong> hardware and software.<br />
Mode of <strong>in</strong>teraction between hardware and software<br />
The follow<strong>in</strong>g certifications from the approved validation agency (<strong>in</strong>dependent<br />
safety auditor).<br />
Correctness and safety of the software<br />
Expected MTBF and availability of the system<br />
Name of manufacturer, place of manufacture and <strong>in</strong>spection. A list of spare parts<br />
as recommended by the manufacturer shall be enclosed.<br />
A list of Test equipment and other special tools as required for data <strong>in</strong>put,<br />
simulation test<strong>in</strong>g, <strong>in</strong>stallation and ma<strong>in</strong>tenance etc. of the system and a detailed<br />
write-up about the procedure to be adopted for use of the same.<br />
Quality assurance & software validation:<br />
The tenderer shall submit along with the tender the quality assurance control, and<br />
<strong>in</strong>spection plan <strong>in</strong>clud<strong>in</strong>g full details of <strong>in</strong>-house quality assurance organization,<br />
procedure and documentation. The tenderer shall submit along with this tender the<br />
details of software validation done by an Accredited Agency of International<br />
repute and standard. Further, all the details of test, certification and validation<br />
done to ensure full safety of the system for use at stations for operation of<br />
53
passenger tra<strong>in</strong> services, as per the Technical Specification, shall be submitted by<br />
the tenderer<br />
12.2 Except where pr<strong>in</strong>ted documents are supplied with each equipment by orig<strong>in</strong>al<br />
equipment manufacturer, all other documentation and <strong>in</strong>formation shall be<br />
prepared us<strong>in</strong>g CAD. All the documentation and draw<strong>in</strong>gs etc. shall be supplied <strong>in</strong><br />
two sets of CD’s. The draw<strong>in</strong>gs etc. shall also be supplied <strong>in</strong> duplicate on J.K.<br />
Copier/map litho white paper to facilitate tak<strong>in</strong>g out copies on pla<strong>in</strong> paper copier.<br />
In addition, four complete sets of such documents shall also be supplied for ready<br />
use duly bounded <strong>in</strong> good plastic folders.<br />
12.3 The supply of equipment and materials shall also <strong>in</strong>clude necessary<br />
documentation related to tra<strong>in</strong><strong>in</strong>g on the ma<strong>in</strong>tenance of equipment <strong>in</strong> sufficient<br />
number of copies and two video-CDs<br />
13. SPARES:<br />
13.1 The tenderer shall <strong>in</strong>clude <strong>in</strong> his tender the details of essential spares, their<br />
quantity and unit prices as per schedule of requirements. Details are to be given to<br />
confirm that quantity of spares quoted is as per requirement of this clause. The<br />
tenderer shall give a detailed list of circuit packs, modules, panels, plug <strong>in</strong> units,<br />
crystals, couplers, connectors, fuses of each type which may be lowest level field<br />
replaceable units for each location. The total cost of essential spares based on the<br />
unit price quoted by the tenderer shall be <strong>in</strong>cluded <strong>in</strong> the tender evaluation.<br />
13.2 Railway shall consider the follow<strong>in</strong>g essential spares at 5% of the quantities used<br />
<strong>in</strong> the equipment subject to a m<strong>in</strong>imum of one. The fraction shall be rounded off<br />
on higher side.<br />
a) All units which may <strong>in</strong>clude but not limited to circuit packs, modules, plug <strong>in</strong><br />
units, ancillary equipment connectors, couplers of each type, which may be lowest<br />
level field replaceable assembly/device.<br />
b) Surge and lightn<strong>in</strong>g protection arrangement.<br />
c) Power supply equipment.<br />
d) Connectors and couplers of each type with cables, crystals, MCBs switches.<br />
In addition follow<strong>in</strong>g are to be supplied as spares :<br />
i) Software back up <strong>in</strong> two sets of CD’s.<br />
ii)<br />
Three times the quantity of fuses used <strong>in</strong> the equipment for each type.<br />
Spares which are considered essential by the Railways but not quoted by the<br />
tenderer shall be assumed by the Railways, based on the highest price quoted by<br />
any other tenderer for the similar spares only for the purpose of evaluation. The<br />
54
spares for which no rates are available <strong>in</strong> the tender offer shall be required to be<br />
supplied free of cost.<br />
Optional Spares:<br />
In addition to the essential spares, tenderer shall <strong>in</strong>dicate additional<br />
recommended quantities of spares for efficient ma<strong>in</strong>tenance of the equipment<br />
and the systems which is considered necessary by the tenderer for a period of 8<br />
years after warranty period of one year. The details, unit price and the total cost of<br />
recommended spares shall be <strong>in</strong>cluded <strong>in</strong> the tender as an option. However, the<br />
cost of such recommended spares shall not be considered for tender evaluation.<br />
14. LONG TERM AVAILABILITY OF SPARES AND SYSTEM SUPPORT:<br />
14.1 The tenderer shall undertake to supply on payment all ma<strong>in</strong>tenance spares<br />
and tools required for the equipment dur<strong>in</strong>g life time. He shall also undertake<br />
to supply additional equipment required for replacement or expansion of the<br />
network, that may become necessary due to additional traffic requirements. The<br />
price variation formula adopted <strong>in</strong> pric<strong>in</strong>g such ma<strong>in</strong>tenance spares and additional<br />
supply that may be ordered <strong>in</strong> future shall be provided by mutual discussions.<br />
14.2 The manufacturer shall guarantee that spare parts for the system shall be<br />
available for a m<strong>in</strong>imum of eight years after expiry of the warranty period and<br />
thereafter at least two years notice shall be given to the Railways before any<br />
equipment or components are discont<strong>in</strong>ued or phased out from the<br />
manufactur<strong>in</strong>g plans. This will enable the Railways to assess the life time<br />
requirement of spares needed and order <strong>in</strong> sufficient quantity prior to stoppage<br />
of the manufacture.<br />
14.3 That the successful tenderer shall further guarantee that if he goes out of<br />
production of spare parts he shall supply the specifications of materials at no<br />
cost to the purchaser, if and when required <strong>in</strong> connection with the equipment to<br />
enable the purchaser to fabricate or procure from other sources.<br />
14.4 The supplier shall recommend and provide, prior to the system acceptance,<br />
calibration procedures. The recommendation shall <strong>in</strong>clude a list of the various<br />
calibration <strong>in</strong>struments, recalibration periods and extent of preventive<br />
ma<strong>in</strong>tenance for each test <strong>in</strong>strument.<br />
15. QUALITY ASSURANCE:<br />
15.1 The tenderer shall submit along with the tender the quality control plan <strong>in</strong>clud<strong>in</strong>g<br />
full details of <strong>in</strong>-house quality assurance organisation, procedures and<br />
documentation. Dur<strong>in</strong>g the manufactur<strong>in</strong>g process, proper record shall be<br />
ma<strong>in</strong>ta<strong>in</strong>ed for the <strong>in</strong>spection and test carried out accord<strong>in</strong>g to this plan.<br />
15.2 In the event of Railways waiv<strong>in</strong>g off the <strong>in</strong>spection, all tests provided <strong>in</strong> the test<br />
schedules approved by Railways shall be carried out by the quality assurance<br />
55
organisation and proper record of all such tests and results thereof shall be<br />
ma<strong>in</strong>ta<strong>in</strong>ed and supplied to Railways on demand.<br />
16. EQUIPMENT EVALUATION AND APPROVAL:<br />
16.1 The equipment shall be supplied by the contractor after the prototype is approved<br />
by the <strong>in</strong>spect<strong>in</strong>g agency.<br />
16.2 The procedure proposed to be adopted for the prototype approval of the<br />
equipment shall be as under:-<br />
(i)<br />
(ii)<br />
(iii)<br />
(iv)<br />
(v)<br />
(vi)<br />
The test procedure shall be based on the system design. The methodologies to be<br />
adopted for various tests shall be decided tak<strong>in</strong>g <strong>in</strong>to account the system<br />
design/configuration and shall be approved by IR.<br />
Manufacturer shall carry out acceptance tests on equipment to be <strong>in</strong>stalled for<br />
functional acceptance test. These will be subjected to rout<strong>in</strong>e tests and<br />
environmental tests as laid down <strong>in</strong> the Technical Specifications of the Tender<br />
Document. These will be shipped to the consignee only after the <strong>in</strong>spect<strong>in</strong>g<br />
official issues a clear and unequivocal <strong>in</strong>spection certificate.<br />
Functional Acceptance Tests: The Functional Acceptance Tests shall sequence<br />
through all required operations to prove that the System performs <strong>in</strong> accordance<br />
with the Specification and that the local configuration data is acceptable.<br />
After completion of the survey and functional acceptance test, clearance will be<br />
given by the Railway to the Contractor for undertak<strong>in</strong>g manufacture of the total<br />
quantity of equipment to be supplied under this tender.<br />
Rout<strong>in</strong>e Test: The manufacture shall carryout the rout<strong>in</strong>e tests as per Technical<br />
specifications of the tender document on each equipment and the tests results shall<br />
be submitted to the <strong>in</strong>spection authority before call<strong>in</strong>g him for the acceptance<br />
tests.<br />
Acceptance Test: The <strong>in</strong>spect<strong>in</strong>g official shall undertake the Acceptance test on<br />
all the equipments as per technical specification of tender document at the<br />
manufacturer's premises. The material will be shipped only after an issue of<br />
'Inspection Certificate' by the <strong>in</strong>spect<strong>in</strong>g official.<br />
(vii) The Inspect<strong>in</strong>g Officer shall be nom<strong>in</strong>ated by the CAO/IRPMU. Notice /<br />
Intimation shall be sent <strong>in</strong> writ<strong>in</strong>g at least One month <strong>in</strong> advance by the<br />
Contractor to the Inspect<strong>in</strong>g officer when the stores or material to be supplied are<br />
ready for <strong>in</strong>spection and test and no materials shall be delivered or dispatched<br />
until the Inspect<strong>in</strong>g Officer has certified <strong>in</strong> writ<strong>in</strong>g that such stores have been<br />
<strong>in</strong>spected and approved for dispatch.<br />
(viii) Test Procedure: The contractor shall submit detailed Test Procedure for each<br />
equipment, sub-system and system as a whole to the Railway. The Railway shall<br />
56
discuss with the contractor and modify the same as may be required to ensure that<br />
the requirements of Tender Specifications are complied. The f<strong>in</strong>alised Acceptance<br />
Test Procedure/Schedule shall, only, act as broad guidel<strong>in</strong>e and Railway shall be<br />
free to carry out any other test that may be considered essential. The Test<br />
Procedure shall give details of all equipment, test and measur<strong>in</strong>g <strong>in</strong>struments<br />
required to perform the test.<br />
(ix)<br />
(x)<br />
(xi)<br />
Facilities for Test and Exam<strong>in</strong>ation: The contractor shall, at his own cost afford<br />
to the <strong>in</strong>spect<strong>in</strong>g officer all reasonable facilities <strong>in</strong>clud<strong>in</strong>g Office/Lab<br />
accommodation as may be necessary for satisfy<strong>in</strong>g himself, that the materials are<br />
be<strong>in</strong>g and/or have been manufactured <strong>in</strong> accordance with the Specification and<br />
conditions laid down. Contractor shall provide the facilities of <strong>in</strong>spection and<br />
test<strong>in</strong>g at the f<strong>in</strong>al stage of production, assembly and test<strong>in</strong>g <strong>in</strong> the<br />
manufacturer's/supplier's premises.<br />
Cost of Test: The Contractor shall provide, at his cost, all materials, tools, labour<br />
and assistance of every k<strong>in</strong>d, which the Inspect<strong>in</strong>g officer may demand of him for<br />
any test and exam<strong>in</strong>ation, which he shall require to be made on the Contractor's<br />
premises. If the Contractor fails to meet with the conditions aforesaid, the<br />
<strong>in</strong>spect<strong>in</strong>g officer shall, <strong>in</strong> his sole judgement, be entitled to remove for test and<br />
exam<strong>in</strong>ation, all or any of the stores manufactured by the Contractor to any<br />
premises other than that of the Contractor, and <strong>in</strong> all such cases the Contractor<br />
shall bear the cost of transport and/or carry<strong>in</strong>g out such test elsewhere. A<br />
certificate <strong>in</strong> writ<strong>in</strong>g by the Inspect<strong>in</strong>g officer that the Contractor has failed to<br />
provide the facilities and the means for test exam<strong>in</strong>ation shall be f<strong>in</strong>al. The<br />
contractor shall not be entitled to object on any ground whatsoever to the method<br />
of test<strong>in</strong>g adopted by the Inspect<strong>in</strong>g officer.<br />
Delivery of Materials for Test: The Contractor shall also provide and deliver for<br />
test, at his cost, at such place other than his premises as the Inspect<strong>in</strong>g officer may<br />
specify such material or stores, he may require. The premises for test<strong>in</strong>g other<br />
than manufacturer's premises shall be mutually decided by Railway and the<br />
Contractor.<br />
17. INSPECTION OF MATERIALS:<br />
17.1 All equipment, materials, fitt<strong>in</strong>gs and components will be subject to <strong>in</strong>spection by<br />
the purchaser or his representative at the manufacturer's premises before dispatch<br />
and no materials shall be dispatched from the manufacturer's premises until these<br />
are <strong>in</strong>spected and /or approved. The materials may also be <strong>in</strong>spected by the<br />
purchaser or his representative at the contractor's depot at the purchaser’s<br />
discretion. The purchaser or his representative shall have the right to be present<br />
dur<strong>in</strong>g all stages of manufacture, and shall be afforded, free of charge all<br />
reasonable facilities for <strong>in</strong>spection and test<strong>in</strong>g so as to satisfy himself that the<br />
materials are <strong>in</strong> accordance with specifications, approved draw<strong>in</strong>g and<br />
designs.<br />
57
17.2 Materials to IRS/RDSO design or specification and ITD/TEC specification shall<br />
be <strong>in</strong>spected by RDSO before they are f<strong>in</strong>ally used <strong>in</strong> works. Materials other than<br />
this should be <strong>in</strong>spected by purchaser Eng<strong>in</strong>eer or his representative at<br />
factory/site.<br />
17.3 All materials that are not covered under the specification, designs and draw<strong>in</strong>gs of<br />
RDSO/TEC etc. shall be procured from the reputed manufacturers or their<br />
authorised dealers. Such materials are to be approved by the purchaser’s<br />
Eng<strong>in</strong>eer. The Contractor may be required to produce test certificate from the<br />
manufacturer wherever called for by the Eng<strong>in</strong>eer.<br />
17.4 Dur<strong>in</strong>g the execution of the contract, samples may be taken from all the<br />
materials employed for the purpose of test and/or analysis under the conditions<br />
laid down <strong>in</strong> specification; such samples to be prepared for test<strong>in</strong>g and<br />
forwarded to the test<strong>in</strong>g entity shall be free of all costs to the Railway.<br />
17.5 The decision of the purchaser or his successor shall be f<strong>in</strong>al <strong>in</strong> respect of<br />
acceptability or otherwise of any material, equipment etc. required for the work.<br />
17.6 The cost of <strong>in</strong>spection of equipment and materials, all tests and/or analysis<br />
performed shall be borne by the Contractor.<br />
17.7 All expenses of the purchasers representative shall be borne by the purchaser<br />
whether the <strong>in</strong>spected materials is utilised <strong>in</strong> the work or not.<br />
17.8 In case any material is found not accord<strong>in</strong>g to the standard specifications after<br />
delivery at site, the contractor shall immediately remove such materials with<strong>in</strong> 48<br />
hours from Railway premises at his own cost.<br />
18. INSPECTION OF WORKS:<br />
18.1 The Eng<strong>in</strong>eer or his representative may <strong>in</strong>spect and test the various portions of<br />
the work at all stages and shall have full power to reject all or any portion of<br />
the work that he may consider to be defective or <strong>in</strong>ferior <strong>in</strong> quality of<br />
materials workmanship of design <strong>in</strong> comparison to what is called for <strong>in</strong> the<br />
specification. In the event of rejection of any work already executed and not<br />
<strong>in</strong> accordance with specification as <strong>in</strong> this tender and/or as determ<strong>in</strong>ed by the<br />
Eng<strong>in</strong>eer or which the Contractor has been apprised, the Contractor shall<br />
carry out alterations/replacements to such works to the satisfaction of the<br />
Eng<strong>in</strong>eer for which no additional expenses will be Borne by the Railway.<br />
18.2 The contractor shall submit detailed test procedure for each equipment, subsystem<br />
and system as a whole to the Railways. The Railways shall discuss with<br />
the contractor and modify the test procedure as may be required to ensure that<br />
the requirement of tender specifications are complied. The f<strong>in</strong>alised test<br />
procedure shall, only, act as a broad guidel<strong>in</strong>e and Railway shall be free to carry<br />
out any other tests that may be considered essential. The test procedure shall<br />
58
give details of all equipment, test and measur<strong>in</strong>g <strong>in</strong>struments required to perform<br />
the tests which shall be provided by the contractor free of cost.<br />
19. QUANTUM OF WORK AND VARIATION IN QUANTITIES:<br />
19.1 The quantities of various items given <strong>in</strong> the schedules for the works to be<br />
executed are only approximate and are only for the guidance of the contractor. As<br />
far as possible, they have been assessed correctly but are likely to vary dur<strong>in</strong>g the<br />
execution of the work.<br />
19.2 For <strong>in</strong>crease upto 25% of the quantities <strong>in</strong>dicated <strong>in</strong> schedule, the contractor shall<br />
not be entitled for compensation and will be paid for such <strong>in</strong>crease <strong>in</strong> the<br />
quantities at the agreement rate.<br />
19.3 In the event of reduction <strong>in</strong> the quantities to be executed for any reason<br />
whatsoever, the contractor shall not be entitled for any compensation but shall be<br />
paid only for the actual quantity of work done, at the agreement rates.<br />
19.4 When the gross value of the work to be executed is likely to <strong>in</strong>crease <strong>in</strong> excess of<br />
25% of the orig<strong>in</strong>al value of the agreement, the contractor should notify the<br />
Eng<strong>in</strong>eer <strong>in</strong> –charge at least THIRTY DAYS before such necessity arises.<br />
19.5 When the operation of the quantities results <strong>in</strong> the agreement value exceed<strong>in</strong>g by<br />
25% to 50%, for the first 15% <strong>in</strong>crease, the payment will be reduced straightaway<br />
by 2% <strong>in</strong> the <strong>in</strong>cremental value of the agreement and for the next 10% <strong>in</strong>crease <strong>in</strong><br />
the value, the payment will be reduced straightaway by an additional reduction of<br />
2% <strong>in</strong> the further <strong>in</strong>cremental value of the agreement.<br />
19.6 Notwithstand<strong>in</strong>g the above adhoc reduction, Railway reserves the right to refix<br />
the rates, by mutual consent, of those items <strong>in</strong> the schedule, where the quantities<br />
have exceeded by 25% of the agreemental quantities.<br />
19.7 Execution of quantities beyond +50% of overall value shall not be generally<br />
permitted. The rate for quantities <strong>in</strong> excess of 50% of the items shall be decided<br />
between the Railway and the contractor <strong>in</strong> advance of execution of the quantities<br />
<strong>in</strong>volved if <strong>in</strong> the op<strong>in</strong>ion of the Railway, such quantities are also to be executed<br />
by the same contractor. In the event of mutually agreed rate not be<strong>in</strong>g arrived at,<br />
the Railway shall be entitled to execute the excess work by other means and the<br />
contractor shall have no claims on this account.<br />
19.8 An undertak<strong>in</strong>g shall be given to the effect that additional quantities up to 25% of<br />
the contract value at the same unit rates shall be supplied by the tenderer <strong>in</strong> case<br />
order for the additional quantity is placed with<strong>in</strong> the currency period of contract.<br />
It should be noted that this excludes additional quantities that may be required as<br />
warranty or replacement due to defective design and manufacture etc. On this<br />
account, the responsibility of the tenderer under the warranty clause will not be<br />
diluted <strong>in</strong> any way.<br />
59
20. RIGHT OF RAILWAY TO KEEP BACK FROM THE CONTRACT ANY<br />
PORTION OF WORK:<br />
The successful tenderer will however, have no claim or right <strong>in</strong> the execution of<br />
work which <strong>in</strong> the op<strong>in</strong>ion of the Eng<strong>in</strong>eer should be carried out departmentally<br />
or otherwise and the Railway Reserves the right any time after the acceptance of<br />
the tender to keep back from the contract and carry out the work or any portion of<br />
work through any other agent it may th<strong>in</strong>k without assign<strong>in</strong>g any reason. No<br />
claim for compensation/loss or whatsoever on this account will be enterta<strong>in</strong>ed by<br />
the Railway.<br />
21. SUBLETTING AND ASSIGNMENT:<br />
21.1 The contractor may sublet a part of the works under this contract and enter <strong>in</strong>to<br />
contract with suppliers for supply of materials only with the approval of the<br />
Railway adm<strong>in</strong>istration.<br />
21.2 The names of all sub contractors proposed to be employed for execution of work<br />
or any part thereof <strong>in</strong>clud<strong>in</strong>g manufactur<strong>in</strong>g of equipment and other materials<br />
shall be submitted by the contractor to the purchaser and got approved by him<br />
before the contractor enter <strong>in</strong>to a agreement with the sub contractor for the<br />
purpose.<br />
21.3 The contractor shall arrange for effective supervision of sub contractor's work and<br />
rema<strong>in</strong> solely responsible for materials supplied and for works carried out on his<br />
behalf by the sub contractor.<br />
21.4 The contractor shall not, save with the previous consent <strong>in</strong> writ<strong>in</strong>g of the<br />
Purchaser, sublet, transfer or assign the contract or any part thereof or <strong>in</strong>terest<br />
there<strong>in</strong> or benefit or advantage thereof any manner whatsoever.<br />
21.5 In the event of the Contractor's sublett<strong>in</strong>g or assign<strong>in</strong>g this contract or any part<br />
thereof without such permission, the purchaser shall be entitled to cancel the<br />
contract and to purchase the stores elsewhere on the contractor's account and risk<br />
and the contractor shall be liable for any loss or damage which the purchaser<br />
may susta<strong>in</strong> <strong>in</strong> consequence or aris<strong>in</strong>g out of such purpose.<br />
22.1. EXECUTION OF WORK :<br />
All the work shall be executed <strong>in</strong> strict conformity to the provisions of the<br />
contract document and accord<strong>in</strong>g to detailed draw<strong>in</strong>gs, specifications and<br />
<strong>in</strong>structions as may be approved from time to time by Railway based on<br />
detailed design and eng<strong>in</strong>eer<strong>in</strong>g carried out by contractor <strong>in</strong> l<strong>in</strong>e with<br />
requirements as per contract document. The contractor shall be responsible for<br />
ensur<strong>in</strong>g that the work throughout are executed <strong>in</strong> the most substantial, proper<br />
and workman like manner with the quality of material and workmanship <strong>in</strong><br />
strict accordance with the specifications and as per sound <strong>in</strong>dustrial practices and<br />
to the entire satisfaction of the Railway. In case of any doubts regard<strong>in</strong>g any<br />
60
particulars of construction and any ambiguities <strong>in</strong> the plans, the decision of the<br />
purchaser’s eng<strong>in</strong>eer shall be f<strong>in</strong>al and b<strong>in</strong>d<strong>in</strong>g on the contractor.<br />
22.2 Safety of Work, Tra<strong>in</strong>s & Personnel :-<br />
(i)<br />
(ii)<br />
(iii)<br />
(iv)<br />
(v)<br />
The contractor should abide by all the Railway regulations and also ensure that<br />
the same are followed by his representatives, agents, servants or workmen. He<br />
is therefore, bound under these clauses to give notice to them about the<br />
provisions of this clause and the consequent liability of the contractor under the<br />
agreement.<br />
No petroleum spirit with<strong>in</strong> the mean<strong>in</strong>g of the Indian Petroleum Act shall be<br />
stored at site or adjacent land until the approval of the Railway and necessary<br />
license under the Act has been obta<strong>in</strong>ed by the contractor.<br />
The contractor's employees and workers shall not for any reason operate any<br />
appliances or <strong>in</strong>stallations of the Railway concern<strong>in</strong>g the safety of tra<strong>in</strong><br />
movements, but they should whenever necessary notify the qualified Railway<br />
staff who will then take necessary steps. The contractor shall also be responsible<br />
for any damage that the may cause due to the carelessness of his workmen and<br />
will bear the consequences <strong>in</strong> this regard.<br />
The works must be carried out most carefully <strong>in</strong> such a way that they do not<br />
h<strong>in</strong>der the Railway operation except as agreed to by the Railway. The<br />
Contractor shall do no work that may <strong>in</strong>terfere with traffic until protection has<br />
been provided by the Railway and under the supervision of Railway's<br />
representative. When the work is required to be carried out on the track itself or<br />
as close to the track as may pose a hazard to rail traffic, the work shall be<br />
carried out under the supervision of an authorized Railway representative Junior<br />
Eng<strong>in</strong>eer/Senior Eng<strong>in</strong>eer/ Senior Section Eng<strong>in</strong>eer (JE/SE/SSE). Whenever<br />
track side works are undertaken by the contractors, areas for unload<strong>in</strong>g of bulk<br />
materials should be clearly demarcated and barricades provided if necessary<br />
with the consent of the Junior Eng<strong>in</strong>eer/Senior Eng<strong>in</strong>eer (JE/SE)<br />
Signal/Telecom, <strong>in</strong>-charge of the work. Suitable steps shall also be taken to<br />
prevent transport vehicles and such other mach<strong>in</strong>ery ga<strong>in</strong><strong>in</strong>g access so near the<br />
track as to threaten the safety of runn<strong>in</strong>g tra<strong>in</strong>s. That, whenever it becomes<br />
<strong>in</strong>escapable to allow transport vehicles or mobile mach<strong>in</strong>ery to operate <strong>in</strong> close<br />
proximity to the runn<strong>in</strong>g l<strong>in</strong>es the maximum mov<strong>in</strong>g dimensions for the said<br />
l<strong>in</strong>es shall be adequately protected by fenc<strong>in</strong>g or such other suitable measures.<br />
No vehicle will normally be permitted to ply adjacent to the runn<strong>in</strong>g l<strong>in</strong>es. The<br />
contractor will be responsible for the safety of hired trucks and men etc.<br />
work<strong>in</strong>g at the site. He will also be responsible for any damage caused to the<br />
Railway property, staff and passengers travell<strong>in</strong>g on the l<strong>in</strong>e on account of his<br />
truck/vehicles hav<strong>in</strong>g been allowed to ply on the bank.<br />
The contractor shall take all precautionary measures <strong>in</strong> order to ensure<br />
protection of his own personnel mov<strong>in</strong>g about or work<strong>in</strong>g on the Railway<br />
premises and shall have to conform to the Rules and Regulations of the<br />
Railway. If and when, while the work under the contract is <strong>in</strong> progress, there is<br />
likely to be any danger to the persons employed by the contractor due to runn<strong>in</strong>g<br />
of traffic or while work<strong>in</strong>g on the Railway premises, the contractor shall apply<br />
61
(vi)<br />
(vii)<br />
(viii)<br />
(ix)<br />
<strong>in</strong> writ<strong>in</strong>g to the Railway to provide flagmen or lookout men for protection. The<br />
Railway will, however, decide as to whether it is necessary to post such flagmen<br />
and lookout men for various types of works and also the number of such men<br />
required to protect the contractor's staff work<strong>in</strong>g at site. The flagmen and<br />
lookout men will be Railway Servants and no expenses on this account will be<br />
recovered from the contractor. In spite of these precautions, if any unforeseen<br />
accident or <strong>in</strong>jury happens, the contractor will be solely responsible for the<br />
same.<br />
Suitable ladders for climb<strong>in</strong>g the posts and sl<strong>in</strong>gs for support<strong>in</strong>g men on the post<br />
shall be used. Ropes as required shall be used for erection of the poles. The<br />
size of the rope shall be adequate. The contractor shall take necessary<br />
precautions for work<strong>in</strong>g near the power l<strong>in</strong>es. If at any time the Railway f<strong>in</strong>ds<br />
the safety arrangements are <strong>in</strong>adequate or <strong>in</strong>sufficient, the contractor shall take<br />
immediate corrective action as directed by the Railway's representative at site.<br />
However, it is not obligatory on the part of the Railway to give such directions.<br />
The issue or non-issue of any direction <strong>in</strong> the matter by the Railway shall <strong>in</strong> no<br />
way absolve the contractor of his sole responsibility to adopt safe work<strong>in</strong>g<br />
methods. The stone-breakers, if employed shall be provided with protective<br />
goggles and protective cloth<strong>in</strong>g and seated at sufficiently safe <strong>in</strong>tervals.<br />
Necessary personal safety equipment as considered adequate by the Eng<strong>in</strong>eer<strong>in</strong>-Charge<br />
should be kept available by the contractor for the use of the persons<br />
employed on the site and ma<strong>in</strong>ta<strong>in</strong>ed <strong>in</strong> a condition suitable for immediate use<br />
and the contractor should take adequate steps to ensure proper use of equipment<br />
by these concerned. When not <strong>in</strong> use, electrical apparatus shall be switched off.<br />
No pa<strong>in</strong>t conta<strong>in</strong><strong>in</strong>g lead or lead products shall be used except <strong>in</strong> the form of<br />
paste or ready mixed pa<strong>in</strong>ts. Suitable face masks should be supplied by the<br />
contractor for use by the workers when pa<strong>in</strong>t is applied <strong>in</strong> the form of spray.<br />
With<strong>in</strong> the station premises and specially on passenger platforms, the contractor<br />
shall ensure sufficient free space for movement of passenger traffic. He must<br />
cover and protect the excavations carried out <strong>in</strong> such areas with a view to avoid<br />
any accidents.<br />
In case of an accident of any nature, the contractor will <strong>in</strong>demnify the Railway<br />
for any losses caused by him as a result of the accident.<br />
The contractor will not be entitled to any compensation for any damage or loss<br />
susta<strong>in</strong>ed by him dur<strong>in</strong>g execution of the work, for any idle labour or transport<br />
or any loss or deterioration of the material or tools.<br />
22.3 Supervision & Labour:-<br />
(i)<br />
Dur<strong>in</strong>g the execution of the works the contractor or his representative shall not<br />
leave the site where the works are be<strong>in</strong>g carried out. At the site of work, the<br />
contractor shall always make available one representative who shall be approved<br />
by the Railway Adm<strong>in</strong>istration and who shall be <strong>in</strong>vested with adequate powers<br />
by the Contractor so that orders or <strong>in</strong>structions given to the said representative<br />
by the Railway Adm<strong>in</strong>istration <strong>in</strong> writ<strong>in</strong>g could be considered as duly given or<br />
conveyed to the Contractor himself. Representative of the Railway will check up<br />
the work from time to time. Supervision and Erection of <strong>in</strong>door work will be<br />
done by the contractors with their own labour, till completion and test<strong>in</strong>g of the<br />
62
(ii)<br />
(iii)<br />
work.<br />
The field supervisor shall receive <strong>in</strong>structions, <strong>in</strong> the absence of the contractor<br />
from the Eng<strong>in</strong>eer-<strong>in</strong>-charge of the work or his representative at site and comply<br />
with the <strong>in</strong>structions. The contractor shall be responsible for the compliance of<br />
such <strong>in</strong>structions.<br />
If the supervisor act<strong>in</strong>g on behalf of the contractor disobeys or does not regard<br />
the <strong>in</strong>structions of the Railway's supervisor/representative and does not execute<br />
the work to the satisfaction of this Railway supervisor, it shall be b<strong>in</strong>d<strong>in</strong>g on the<br />
contractor to replace his supervisor.<br />
23. PROGRESS REPORTING:<br />
23.1 The contractor shall submit to Railways at his own cost periodic progress<br />
reports at regular <strong>in</strong>tervals regard<strong>in</strong>g the state and progress of work. The<br />
details and pro-forma of the report will mutually be agreed after award of the<br />
Contract. Such reports shall be for daily man power, equipment and plant<br />
development, weekly work progress and monthly progress review reports. All<br />
actions as directed by Railway pursuant to such reports shall be promptly attended<br />
to by Contractor.<br />
23.2 The purchaser’s eng<strong>in</strong>eer shall also conduct monthly meet<strong>in</strong>gs with the<br />
contractor to assess and review the programme of works. The action proposed to<br />
progress the work as planned, difficulties, assistance required etc. shall be<br />
clearly brought out and remedial action taken. The m<strong>in</strong>utes of these meet<strong>in</strong>gs<br />
shall be jo<strong>in</strong>tly signed by Railways and contractor.<br />
24. MAINTENANCE OF WORKS :<br />
24.1 The contractor shall at all times dur<strong>in</strong>g the progress and cont<strong>in</strong>uance of the works<br />
and also for the period of ma<strong>in</strong>tenance specified <strong>in</strong> the tender form and after the<br />
date of pass<strong>in</strong>g of the certificate of completion by the Railway's representative or<br />
any other earlier date subsequent to the completion of the works that may be<br />
fixed by Railway's representative be responsible for and effectively ma<strong>in</strong>ta<strong>in</strong> and<br />
uphold <strong>in</strong> good, substantial, sound and perfect condition all and every part of the<br />
works and shall make good from time to time and at all times, as often as<br />
the Railway's representative shall require, any damage or defect that may dur<strong>in</strong>g<br />
the above period arise <strong>in</strong> or be discovered or be <strong>in</strong> any way connected with the<br />
works, provided that such damage or defect is not directly caused by errors<br />
<strong>in</strong> the contract documents, act of providence or <strong>in</strong>struction or civil riot, and the<br />
contractor shall be liable for and shall pay and make good to the Railways or<br />
other persons legally entitled thereto whenever required by the Railway's<br />
representative so to do, all losses, damages, costs and expenses they or any of<br />
them may <strong>in</strong>cur or be put or be liable to, by reason or <strong>in</strong> consequence of the<br />
operations of the contractor or his failure <strong>in</strong> any respect.<br />
25 CLEARANCE OF SITE:<br />
63
25.1 Contractor at his own expenses clean the site, set out all works and provide all<br />
necessary labours, pegs, str<strong>in</strong>g, steel to enable the purchaser or any of his<br />
representatives to check all sett<strong>in</strong>g out and the contractor will correct all errors at<br />
his own expenses.<br />
25.2 At the end of the work <strong>in</strong> each section the contractor shall as a part of his<br />
contractual obligation leave the area completely cleared of rubbish and<br />
obstructions of all k<strong>in</strong>ds accord<strong>in</strong>g to the <strong>in</strong>structions of the Railway's<br />
representatives. If with<strong>in</strong> fortnight of completion of the particular item of site<br />
work, the refuge is not cleared, the Railway will arrange to get them removed at<br />
the cost of the Contractor. However, before the Railway actually gets the site<br />
cleared, <strong>in</strong>timation <strong>in</strong> writ<strong>in</strong>g shall be sent to the Contractor.<br />
26. PROVISIONAL ACCEPTANCE:<br />
26.1 Immediately after the completion of the work at each station or after<br />
completion of work <strong>in</strong> a block section here<strong>in</strong> after referred as sub-section, the<br />
contractor shall certify and advise the purchaser <strong>in</strong> writ<strong>in</strong>g that the <strong>in</strong>stallation<br />
is (i) complete, (ii) ready for satisfactory service and (iii) ready to be handed<br />
over. He will also place at the disposal of the purchaser the required staff for<br />
<strong>in</strong>spection, test<strong>in</strong>g and putt<strong>in</strong>g it <strong>in</strong>to operation.<br />
26.2 The test or tests specified <strong>in</strong> Technical specification will be conducted jo<strong>in</strong>tly by<br />
the purchaser and contractor as soon as possible after receipt of advice of<br />
completion of one sub-section by the purchaser from the contractor. The<br />
test schedule shall be furnished by the tenderer which will be modified by<br />
mutual discussion between the contractor and Railway before f<strong>in</strong>alisation.<br />
Any component, modules, sub-assemblies or equipment fail<strong>in</strong>g dur<strong>in</strong>g the<br />
commission<strong>in</strong>g test shall be replaced/repaired free of cost by the tenderer.<br />
26.3 Purchaser's Eng<strong>in</strong>eer shall issue a Provisional Acceptance certificate for<br />
successful commission<strong>in</strong>g of whole system cover<strong>in</strong>g all materials and services<br />
<strong>in</strong>cluded <strong>in</strong> the Schedule of works, after the f<strong>in</strong>al acceptance test as per the<br />
approved test procedure have been completed and the performance has been<br />
found to meet the specifications. Railways decision <strong>in</strong> this respect shall be f<strong>in</strong>al.<br />
The Provisional acceptance certificate shall be signed by both the parties. The<br />
period of ma<strong>in</strong>tenance of works shall commence from the date of such certificate.<br />
26.4 The Purchaser's Eng<strong>in</strong>eer may issue such a certificate with respect to any part of<br />
the works before the completion of the whole of the works or with respect to any<br />
substantial part of the works which has been both completed to the satisfaction<br />
of the Purchaser's Eng<strong>in</strong>eer and occupied or used by the Railway and when any<br />
such certificate is given <strong>in</strong> respect of a part of the works, such part shall be<br />
considered as completed and the period of ma<strong>in</strong>tenance of such part shall<br />
commence from the date of such certificate.<br />
26.5 Should the result/s of <strong>in</strong>spection and test be not satisfactory, an extension of<br />
one month will be granted to the contractor to make good the defects and<br />
64
deficiencies po<strong>in</strong>ted out by the purchaser. Fresh <strong>in</strong>spection and test will then<br />
be carried out after the contractor has attended to the defects and<br />
deficiencies. If these tests are also not satisfactory the purchaser may proceed<br />
at the contractor's expense by all means deemed expedient, to have the<br />
<strong>in</strong>stallation made satisfactory until they comply with the specifications, and<br />
approved draw<strong>in</strong>gs and designs.<br />
26.6 In such a case or <strong>in</strong> the case of delay <strong>in</strong> complet<strong>in</strong>g the work under this contract<br />
with<strong>in</strong> the time limit the purchaser reserves the right, if he deems it possible<br />
to use <strong>in</strong> a reasonable manner any part of the <strong>in</strong>stallation even if some<br />
<strong>in</strong>stallations are not completely erected. The purchaser will give to the contractor<br />
for this purpose 7 days previous notice. The contractor shall then take at his own<br />
expense all necessary steps to complete the work <strong>in</strong> accordance with the<br />
provisions of the contract. In case it becomes impossible to proceed with the<br />
above mentioned tak<strong>in</strong>g over tests or reasons other than for which the contractor<br />
is responsible, the Provisional Acceptance Certificate shall be issued at or with<strong>in</strong><br />
a mutually agreed reasonable period not exceed<strong>in</strong>g six months after completion of<br />
<strong>in</strong>stallation.<br />
26.7 The issue of provisional acceptance will not be withheld for rectification or<br />
m<strong>in</strong>or defects as dist<strong>in</strong>ct from rejected equipment, which may not be<br />
essential for commission<strong>in</strong>g and operation of the <strong>in</strong>stallation. In such cases,<br />
only the value of the materials and cost of the rectification of the m<strong>in</strong>or defects<br />
shall be withheld from the payments on provisional acceptance until rectification<br />
is completed.<br />
27. PLACING IN SERVICE & MAINTENANCE SUPERVISION:<br />
27.1 After the equipment has been commissioned & placed <strong>in</strong> service and<br />
Provisional Acceptance certificate issued by Purchaser's Eng<strong>in</strong>eer, the<br />
contractor shall be responsible for proper ma<strong>in</strong>tenance supervision of the<br />
equipment for a period of 12 months from the date of commission<strong>in</strong>g. For this<br />
purpose he shall prepare a ma<strong>in</strong>tenance plan and make available the services<br />
of qualified ma<strong>in</strong>tenance eng<strong>in</strong>eer stationed at the location approved by<br />
Purchaser's Eng<strong>in</strong>eer who will guide and supervise the work of Railways<br />
ma<strong>in</strong>tenance staff. The ma<strong>in</strong>tenance eng<strong>in</strong>eer of the tenderer will visit each<br />
location at least once <strong>in</strong> a month and attend to any fault on the systems.<br />
27.2 Dur<strong>in</strong>g this period of ma<strong>in</strong>tenance supervision if any lacuna is noticed <strong>in</strong> the<br />
function<strong>in</strong>g as a result of any defect <strong>in</strong> design or manufacture, the same will be<br />
rectified by the contractor free of cost. Dur<strong>in</strong>g such rectification if any faulty<br />
equipment/modules need replacement or repair, they shall be provided by the<br />
contractor from the set of equipment or modules that the contractor should br<strong>in</strong>g<br />
to the site of <strong>in</strong>stallation <strong>in</strong> addition to all the materials to be supplied aga<strong>in</strong>st<br />
this contract. Use of spare modules covered under the Schedule of material of<br />
this tender shall not be permitted to be used dur<strong>in</strong>g <strong>in</strong>stallation, commission<strong>in</strong>g<br />
and ma<strong>in</strong>tenance supervision period without personal approval of Chief<br />
65
Adm<strong>in</strong>istrative Office /IRPMU Spares, so issued under unusual circumstances,<br />
should be replaced by the firm with<strong>in</strong> seven days of the issue of spares.<br />
28. FINAL ACCEPTANCE:<br />
28.1 The f<strong>in</strong>al acceptance of the entire equipment <strong>in</strong>stalled <strong>in</strong> the section shall take<br />
effect from the date of expiry of the period of ma<strong>in</strong>tenance supervision as def<strong>in</strong>ed<br />
<strong>in</strong> para- 27 or the expiry of the last of the respective period of Ma<strong>in</strong>tenance<br />
Supervision of various sections for which Provisional Acceptance Certificates<br />
are issued or brought <strong>in</strong>to full fledged operation, provided that the contractor<br />
has complied fully with his obligations under clause 27 <strong>in</strong> respect of each<br />
section under the contract.<br />
28.2 If on the other hand the contractor has not so complied with his obligation under<br />
para 27 <strong>in</strong> respect of any site the purchaser may either extend the period of<br />
ma<strong>in</strong>tenance supervision <strong>in</strong> respect of that section until the necessary works are<br />
carried out by the contractor or carry out those works suo moto on behalf of the<br />
contractor at the contractor's expenses. After expiry of the period of<br />
ma<strong>in</strong>tenance supervision for each section, a certificate of F<strong>in</strong>al Acceptance for<br />
the section shall be issued by the purchaser and the last of such certificate will be<br />
called the Last and F<strong>in</strong>al Acceptance Certificate. The contract shall not be<br />
considered as completed until the issue of F<strong>in</strong>al Acceptance Certificate by<br />
the purchaser.<br />
28.3 The purchaser shall not be liable to the contractor for any dispute aris<strong>in</strong>g out of<br />
or <strong>in</strong> connection with the contract or execution of the work unless the contractor<br />
have made a claim <strong>in</strong> writ<strong>in</strong>g <strong>in</strong> respect thereof before the issue of F<strong>in</strong>al<br />
Acceptance Certificate under this clause. The contractor shall be debarred from<br />
disput<strong>in</strong>g the correctness of the items caused by the no claim certificate or<br />
demand<strong>in</strong>g a reference to Arbitration <strong>in</strong> respect thereof.<br />
28.4 Notwithstand<strong>in</strong>g the issue of F<strong>in</strong>al Acceptance Certificate, the contractor and the<br />
purchaser (subject to Sub Clause as above) shall rema<strong>in</strong> liable for fulfilment of<br />
any obligation <strong>in</strong>curred under the provision of the contract prior to the issue of<br />
F<strong>in</strong>al Acceptance Certificate which rema<strong>in</strong>s unperformed at the time such<br />
certificate is issued and for determ<strong>in</strong><strong>in</strong>g the nature and extent of such<br />
obligation, the contract shall be deemed to rema<strong>in</strong> <strong>in</strong> force between the parties<br />
hereto.<br />
29. WARRANTY:<br />
29.1 All equipment and system supplied by the Contractor shall be guaranteed aga<strong>in</strong>st<br />
the defects for a period of 12 (twelve) months from the date of commission<strong>in</strong>g of<br />
work and plac<strong>in</strong>g <strong>in</strong> service. The date of the commission<strong>in</strong>g of the work will be<br />
after the sign<strong>in</strong>g of the provisional acceptance certificate by both the parties as per<br />
details at clause 26(26.3) above.<br />
66
29.2 Dur<strong>in</strong>g the period of warranty, the contractor shall rema<strong>in</strong> responsible to arrange<br />
replacement and for sett<strong>in</strong>g right at his own cost any equipment <strong>in</strong>stalled by him<br />
which is of defective manufacture or design or becomes unworkable due to any<br />
cause whatsoever. The decision of the Railway's representative <strong>in</strong> this regard to<br />
direct the contractor to attend to any damage or defect <strong>in</strong> work shall be f<strong>in</strong>al and<br />
b<strong>in</strong>d<strong>in</strong>g on the Contractor.<br />
29.3 Dur<strong>in</strong>g the period of warranty, the contractor shall be responsible to the extent<br />
expressed <strong>in</strong> this clause for any defects that may develop under the conditions<br />
provided for by the contract and under proper use, aris<strong>in</strong>g from faulty materials,<br />
design of workmanship <strong>in</strong> the plant, or from faulty execution of the plant by the<br />
contractor but not otherwise and shall remedy such defects at his own cost<br />
when called upon to do so by the Purchaser who shall state <strong>in</strong> writ<strong>in</strong>g <strong>in</strong> what<br />
respect the portion is faulty.<br />
29.4 If it becomes necessary for the contractor to replace or renew any defective<br />
portions of the system under this clause the provisions of this clause shall apply<br />
to the portions of the plant to be replaced or renewed until the expiration of<br />
six months from the date of such replacement or renewal or until the end of the<br />
warranty period whichever may be later. If any defect is not remedied with<strong>in</strong><br />
reasonable time, the purchaser may proceed to do the work at contractor's risk<br />
and expense, but without prejudice to any other rights which the purchaser<br />
may have aga<strong>in</strong>st the contractor <strong>in</strong> respect of such defects.<br />
29.5 If the replacement or renewal are of such a character as may affect the efficiency<br />
of the system the purchaser shall have the right to give to the contractor with<strong>in</strong><br />
one month from such replacement or renewal notice <strong>in</strong> writ<strong>in</strong>g for the tests to<br />
be carried out. The cost of all such tests shall be borne by the contractor.<br />
29.6 All <strong>in</strong>spections, adjustments, replacements or renewals carried out by the<br />
contractor dur<strong>in</strong>g the supervised ma<strong>in</strong>tenance period shall be <strong>gov</strong>erned by the<br />
special conditions of this contract.<br />
29.7 Until the f<strong>in</strong>al certificate shall have been issued, the contractor shall have the right<br />
of entry, at his own risk and expense, by himself or his duly authorised<br />
representatives, whose names shall have previously been communicated <strong>in</strong><br />
writ<strong>in</strong>g to the purchaser at all reasonable work<strong>in</strong>g hours upon all necessary<br />
parts of the works for the purpose of <strong>in</strong>spect<strong>in</strong>g the work<strong>in</strong>g and the records of<br />
the system and tak<strong>in</strong>g notes there from and, if he desires at his own risk and<br />
expense, mak<strong>in</strong>g any tests subject to the approval of the purchaser which shall<br />
not be unreasonably withheld.<br />
30. TRAINING:<br />
30.1 The tenderer shall undertake to tra<strong>in</strong> Railway eng<strong>in</strong>eers and other staff<br />
nom<strong>in</strong>ated by the Railways <strong>in</strong> different aspects of equipments function<strong>in</strong>g, field<br />
<strong>in</strong>stallation, test<strong>in</strong>g, commission<strong>in</strong>g, operation, ma<strong>in</strong>tenance and repair,<br />
cover<strong>in</strong>g both hardware and software. The tra<strong>in</strong><strong>in</strong>g should be comprehensive for<br />
67
transfer of complete know-how so as to impart full knowledge and competent to<br />
<strong>in</strong>dependently and successfully execute the <strong>in</strong>stallation, operation, ma<strong>in</strong>tenance<br />
and repair of all equipment. The tra<strong>in</strong><strong>in</strong>g courses should, apart from formal<br />
class room tra<strong>in</strong><strong>in</strong>g, <strong>in</strong>clude hand on practical experience and visits to work<strong>in</strong>g<br />
<strong>in</strong>stallation.<br />
30.2 The contractor shall at every stage of <strong>in</strong>stallation; test<strong>in</strong>g and commission<strong>in</strong>g shall<br />
provide all facilities for adequate tra<strong>in</strong><strong>in</strong>g of Railway personnel who may be<br />
deputed to work on the project.<br />
30.3 The requirement of tra<strong>in</strong><strong>in</strong>g <strong>in</strong> man-weeks has been <strong>in</strong>dicated <strong>in</strong> the schedule of<br />
requirements. The tenderer shall quote for the man week rates and Railways<br />
shall have the right to vary the tra<strong>in</strong><strong>in</strong>g period <strong>in</strong>dicated <strong>in</strong> the schedule.<br />
30.4 In the event of any equipment/sub-system be<strong>in</strong>g manufactured/assembled <strong>in</strong> India<br />
<strong>in</strong> technical collaboration with foreign firm by the tenderer or any of its subcontractor,<br />
approximately half of the tra<strong>in</strong><strong>in</strong>g provided <strong>in</strong> the schedule shall be<br />
arranged at the collaborator's premises/tra<strong>in</strong><strong>in</strong>g centre and the rema<strong>in</strong><strong>in</strong>g portion<br />
at the work<strong>in</strong>g <strong>in</strong>stallations. Details of tra<strong>in</strong><strong>in</strong>g proposal shall be submitted by<br />
the tenderer.<br />
30.5 Set of documents related to tra<strong>in</strong><strong>in</strong>g <strong>in</strong> adequate quantity shall be provided.<br />
30.6 All expenses for travel to and from the place of tra<strong>in</strong><strong>in</strong>g, board<strong>in</strong>g and lodg<strong>in</strong>g of<br />
the tra<strong>in</strong>ees shall be borne by the Railways.<br />
31. INFRINGEMENT OF PATENTS:<br />
(a)<br />
(b)<br />
The Contractor is forbidden to use any patents or registered draw<strong>in</strong>gs, processes<br />
or patterns <strong>in</strong> fulfill<strong>in</strong>g his contract without the previous consent <strong>in</strong> writ<strong>in</strong>g of the<br />
owner of such patents, draw<strong>in</strong>gs, patterns or trade marks, except where these<br />
are specified by the purchaser himself. Royalties where payable for the use of<br />
such patented processes, registered draw<strong>in</strong>gs or patterns shall be borne<br />
exclusively by the Contractor. The Contractor shall advise the purchaser of any<br />
proprietary rights that may exist on such processes, draw<strong>in</strong>gs or patterns which<br />
he may use of his own accord.<br />
In the case of patents taken out by the Contractor of the draw<strong>in</strong>gs or patterns<br />
registered by him, or of those patents, draw<strong>in</strong>gs or patterns for which he holds<br />
a license, the sign<strong>in</strong>g of the contract automatically gives the Purchaser the<br />
right to repair by himself the purchased articles covered by the patent or by<br />
any person or body chosen by him and to obta<strong>in</strong> from any sources he desires the<br />
component parts required by him for carry<strong>in</strong>g out the repair work. In the<br />
event of <strong>in</strong>fr<strong>in</strong>gement of any patent rights due to above action of the purchaser,<br />
he shall be entitled to claim damages from the contractor on the grounds of any<br />
loss of any nature which he may suffer.<br />
32. LICENSE AS PER GOVT. OF INDIA CONTRACT LABOUR ACT:<br />
68
32.1 The contractors are required to produce license as enjo<strong>in</strong>ed <strong>in</strong> the Government of<br />
India Contract Labour (Regulation and Abolition) Act (1978). They shall not be<br />
allowed to undertake or execute any work through contract labour except under<br />
and <strong>in</strong> accordance with a license issued under the said Act <strong>in</strong> that behalf by<br />
the authorised licens<strong>in</strong>g Officer.<br />
33. DEFAULT & DELAYS:<br />
The Contractor shall execute the work with due diligence and expedition, keep<strong>in</strong>g<br />
to the approved Time schedule. Should he refuse or neglect to comply with any<br />
reasonable orders given to him <strong>in</strong> writ<strong>in</strong>g by the Purchaser's Eng<strong>in</strong>eers <strong>in</strong><br />
connection with the work or contravene the provision of the contract or the<br />
progress of work lags persistently beh<strong>in</strong>d the time schedule due to his neglect,<br />
the Purchaser shall be at liberty to give seven days notice <strong>in</strong> writ<strong>in</strong>g to the<br />
Contractor requir<strong>in</strong>g him to make good the neglect or contravention compla<strong>in</strong>ed<br />
of and should the contractor fail to comply with the requisitions made <strong>in</strong> the<br />
notice with<strong>in</strong> seven days from the receipt thereof, it shall be lawful for the<br />
purchaser to take the work wholly or <strong>in</strong> part out of the Contractor's hands<br />
without any further reference and get the work or any part thereof, as the case<br />
may be, completed by other agencies at the expense of the contractor without<br />
prejudice to any other right or remedy of the Purchaser.<br />
34. LOSS SUSTAINED DUE TO DEFAULT AND DELAY:<br />
In the event of any loss to the purchaser on account of execution and/or<br />
completion of the work or any part thereof by agencies other than the<br />
contractor, the contractor shall be liable to reimburse the loss to purchaser<br />
without prejudice to the other rights and remedies of the purchaser, and<br />
the reimbursement <strong>in</strong> full or <strong>in</strong> part as the case may be, shall be met, at the<br />
option of the purchaser from out of all or any of the follow<strong>in</strong>g sources viz :<br />
i) Any amount due and payable to the contractor by the purchaser on any<br />
account whatsoever;<br />
ii) The Contractor's security deposit <strong>in</strong> hands of the purchaser as far as available,<br />
and any other assets whatsoever of the contractor;<br />
In the event of re-imbursement from out of sources (i) and/or (ii) above<br />
mentioned, the purchaser shall have the right of appropriation sue motto.<br />
35. PENALTY FOR DELAY IN COMPLETION:<br />
a) If the contractor fails to execute and complete the work with<strong>in</strong> the time<br />
specified <strong>in</strong> the Agreement or with<strong>in</strong> the period of extension granted under para<br />
36 except <strong>in</strong> so far as the delay is on the purchaser's account, the contractor shall<br />
be levied Liquidated Damages @ 1/2% per week or part thereof of the entire<br />
contract value of the work awarded to the contractor for delays <strong>in</strong><br />
supply/execution of the work as per General Condition of contract.<br />
69
) For the purpose of this clause, the contract value of the works shall be taken as<br />
value of work as per contract agreement <strong>in</strong>clud<strong>in</strong>g any supplementary work<br />
order/contract agreement issued Provided also, that the total amount of liquidated<br />
damages under this condition shall not exceed the under noted percentage value<br />
or of the total value of the item or groups of items of work for which a separate<br />
dist<strong>in</strong>ct completion period is specified <strong>in</strong> the contract.<br />
(i) For contract value up to Rs. 2 Lakhs -- 10% of the total value of the<br />
contract.<br />
(ii) For contracts valued above Rs. 2 Lakhs -- 10% for the first Rs.2 Lakhs and<br />
the 5% of the balance.<br />
Provided further, that if the Railway is not satisfied that the works can be<br />
completed by the Contractor and <strong>in</strong> the event of failure on the part of the<br />
contractor to complete the work with<strong>in</strong> further extension of time allowed as<br />
aforesaid, the Railway shall be entitled, without prejudice to any other right or<br />
remedy available <strong>in</strong> that behalf, to appropriate the contractor’s security deposit<br />
and resc<strong>in</strong>d the contract under clause 62 of these conditions, whether or not actual<br />
damage is caused by such default.<br />
36. EXTENSION OF TIME:<br />
If such a failure as aforesaid shall have arisen from any cause which the<br />
Purchaser may agree as be<strong>in</strong>g a reasonable ground for extension of time, the<br />
Chief Adm<strong>in</strong>istrative Officer / IRPMU or his successor(s) may allow such<br />
additional time as he may <strong>in</strong> his absolute discretion consider to be reasonably<br />
justified by the circumstances of the case, such extensions shall be granted with<br />
liquidated damages <strong>in</strong> the Form No.11. The Contractor will apply for extension<br />
at least two months before the expiry of the period of completion. Form No.12<br />
will be applicable <strong>in</strong> case extension is on purchaser’s account and also <strong>in</strong> case<br />
extension is on contractor's account but the purchaser is reasonably satisfied that<br />
contractor cannot be penalised for such delay. The terms and conditions of the<br />
orig<strong>in</strong>al contract will rema<strong>in</strong> operative dur<strong>in</strong>g the extended period and noth<strong>in</strong>g<br />
will be allowed on this account.<br />
37. CONTRATOR'S LIABILITIES FOR COSTS AND DAMAGES:<br />
37.1 WITHHOLDING AND LIEN IN RESPECT OF SUMS CLAIMED:<br />
a) Whenever any claim or claims for payment of a sum of money arises out of<br />
under the contract aga<strong>in</strong>st the contractor, the Purchaser shall be entitled to<br />
withhold and also have lien to reta<strong>in</strong> such sum or sums <strong>in</strong> whole or <strong>in</strong> part from<br />
the security, if any, deposited by the contractor and for the purpose aforesaid the<br />
purchaser shall be entitled to withhold the said cash security deposit or the<br />
security, if any, furnished as the case may be and also have lien over the sum<br />
pend<strong>in</strong>g f<strong>in</strong>alisation or adjudication of any such claim.<br />
70
) In the event of the security be<strong>in</strong>g <strong>in</strong>sufficient to cover the claimed amount or<br />
amounts or if no security has been taken from the Contractor, the purchaser shall<br />
be entitled to withhold and have lien to reta<strong>in</strong> to the extent of such claim amount<br />
or amounts referred to spura, from any sum or sums found payable or which at<br />
any time thereafter may become payable to the Contractor under the same<br />
contract or any other department of the Central Government pend<strong>in</strong>g<br />
f<strong>in</strong>alisation or adjudication of any such claims.<br />
c) It is an agreed term of the contract that the sum of money or moneys so withheld<br />
or reta<strong>in</strong>ed under the lien referred to by the purchaser till the claim aris<strong>in</strong>g out of<br />
or under the contract is determ<strong>in</strong>ed by the Arbitrator. (If the contract is <strong>gov</strong>erned<br />
by the Arbitration clause) or by the competent court as the case may be and that<br />
the contractor will have no claim for <strong>in</strong>terest of damages whatsoever on any<br />
account <strong>in</strong> respect of such withhold<strong>in</strong>g or retention under the lien referred to<br />
spura and duly notified as such to the Contractor.<br />
d) For the purpose of this clause, where contractor is a partnership firm or a<br />
limited company, the purchaser shall be entitled to withhold and also have a lien<br />
to reta<strong>in</strong> towards such claimed amount or amounts <strong>in</strong> whole or <strong>in</strong> part from any<br />
sum found payable to any partner/limited company, as the case may be,<br />
whether <strong>in</strong> his <strong>in</strong>dividual company or otherwise.<br />
37.2 LIEN IN RESPECT OF OTHER CONTRACTS:<br />
a) Any sum or sums of money due and payable to the Contractor (<strong>in</strong>clud<strong>in</strong>g the<br />
security deposit returnable to him under the contract) may be withheld or<br />
reta<strong>in</strong>ed by way of lien by the Purchaser aga<strong>in</strong>st any claim of this Railway or<br />
any other Railways or any other Departments of the Central Government <strong>in</strong><br />
respect of payment of a sum of money aris<strong>in</strong>g out of or under any other<br />
contract made by the Contractor with this or any other Railway or any other<br />
department of the Central Government.<br />
b) It is an agreed term of the contract that the sum of money so withheld or reta<strong>in</strong>ed<br />
under this clause by the purchaser will be kept withheld or reta<strong>in</strong>ed as such by<br />
the purchaser till the claim aris<strong>in</strong>g out of or under any other contract is<br />
either mutually settled or determ<strong>in</strong>ed by the Arbitrator if the other contract is<br />
<strong>gov</strong>erned by the Arbitration clause or by the competent court as the case may<br />
be, and that the contractor shall have no claim for <strong>in</strong>terest or damages <strong>in</strong> respect<br />
of any sum of money withheld or reta<strong>in</strong>ed under this clause and duly notified to<br />
the contractor.<br />
38. UNIT PRICES:<br />
38.1 The prices quoted by the Tenderer shall <strong>in</strong>clude the prices of materials <strong>in</strong>clud<strong>in</strong>g<br />
all <strong>in</strong>cidental charges for transport, load<strong>in</strong>g/unload<strong>in</strong>g and handl<strong>in</strong>g of<br />
materials, commission for arrang<strong>in</strong>g despatch by rail / road direct from<br />
manufacturer's factory and complet<strong>in</strong>g all necessary formalities <strong>in</strong> this respect,<br />
such as submission of forward<strong>in</strong>g notes, arrang<strong>in</strong>g placement of Wagon,<br />
71
collection of banker's charges for Bank guarantee, Indemnity Bonds, <strong>in</strong>clusive<br />
of cost of Stamp etc. as also sid<strong>in</strong>g or shunt<strong>in</strong>g charges, if any, levied by the<br />
Railway. The break up of the basic cost and other taxes and duties shall be<br />
positively submitted.<br />
38.2 The prices shall <strong>in</strong>clude all taxes, duties, Royalty and levies (<strong>in</strong>clud<strong>in</strong>g Octroi<br />
etc.) applicable on this Works Contract. Therefore, they should quote their prices<br />
tak<strong>in</strong>g <strong>in</strong>to account the rate of sales tax as leviable <strong>in</strong> the event of sale to the<br />
Central Government Organisation etc. It is clarified that required form applicable<br />
for this purpose will be supplied to the contractor, as applicable <strong>in</strong> the state where<br />
the contract is be<strong>in</strong>g executed. The prices shall also <strong>in</strong>clude provision for losses<br />
and wastage <strong>in</strong> transit and <strong>in</strong>stallation and commission<strong>in</strong>g.<br />
38.3 The prices quoted by the tenderer shall <strong>in</strong>clude cost of commission<strong>in</strong>g and<br />
test<strong>in</strong>g and all costs of Adm<strong>in</strong>istration of Contract, Insurance Premium,<br />
Banker's charges for guarantees, cost of storage, load<strong>in</strong>g-unload<strong>in</strong>g and handl<strong>in</strong>g<br />
of materials and for any road transport which the contractor may use for carriage<br />
of materials to his depot and the site of work. The prices shall <strong>in</strong>clude the cost of<br />
works and adjustments necessary to be done by the contractor dur<strong>in</strong>g or after tests<br />
carried out by the purchaser.<br />
38.4 The price to be quoted by the tenderer's should take <strong>in</strong>to account the credit availed<br />
on <strong>in</strong>puts under the MODVAT scheme <strong>in</strong>troduced w.e.f. 1st March 1986. The<br />
tenderers should give a declaration that any let offs <strong>in</strong> respect of duties on <strong>in</strong>puts<br />
as admissible under law is be<strong>in</strong>g totally and unconditionally passed on to the<br />
purchaser <strong>in</strong> the price quoted by him (see para 43).<br />
38.5 While the price quoted <strong>in</strong> the contract are <strong>in</strong>clusive of all taxes i.e. custom duty,<br />
excise duty, octroi, local levies, Sales tax levied by any statutory authority, the<br />
purchaser shall make any deduction toward sales tax on works contract if<br />
statutorily required to do so. The deducted sales tax on works contract shall be<br />
remitted to the concerned sales tax authority and the purchaser shall <strong>in</strong> no way be<br />
responsible for any disputes between the sales tax authorities and the contractor <strong>in</strong><br />
this regard.<br />
38.6 All taxes, duties and levies (Includ<strong>in</strong>g octroi etc.) aris<strong>in</strong>g out of the transaction<br />
between the contractor and his sub contractor/supplier for this work will be<br />
<strong>in</strong>cluded <strong>in</strong> the rates quoted by the contractor <strong>in</strong> the relevant schedule.<br />
38.7 Arrangement of permits/license for materials will not be made by the Railway<br />
or any assistance given. The Contractor will have to make his own<br />
arrangement. Also no import license shall be arranged by the Railway for this<br />
work.<br />
38.8 The Unit prices offered aga<strong>in</strong>st the various items <strong>in</strong> schedules will <strong>in</strong>clude beside<br />
labour the follow<strong>in</strong>g elements of cost :-<br />
72
(i) Cost of all materials required for prepar<strong>in</strong>g the cable routes, lay<strong>in</strong>g the cables and<br />
all other <strong>in</strong>cidentals connected therewith exclud<strong>in</strong>g the materials supplied by the<br />
Railways.<br />
(ii) Special tools & <strong>in</strong>stallation materials for IPDSLAM, racks, wir<strong>in</strong>g etc. (see para<br />
10).<br />
(iii) Cost of transportation of material, supplied by the Railway from place of<br />
delivery to the site of work.<br />
(iv) Return of released materials, left over cables and other materials from the site of<br />
work and hand<strong>in</strong>g over to the Eng<strong>in</strong>eer at specified locations or stores depot.<br />
(v) Cost of preparation of detailed documentation completion plans/draw<strong>in</strong>gs (see<br />
para 12).<br />
(vi) All other miscellaneous expenses necessary for the execution of the work and<br />
fulfilment of contractual obligation.<br />
39. MEASUREMENT OF WORKS:<br />
39.1 Payments for the works shall be made <strong>in</strong> accordance with approved designs &<br />
draw<strong>in</strong>gs and measured <strong>in</strong> relevant units except where provided or otherwise.<br />
The measurements will be made generally <strong>in</strong> accordance with standard<br />
eng<strong>in</strong>eer<strong>in</strong>g practice & <strong>in</strong> conformity with the General conditions of Contract.<br />
39.2 Figures, Dimensions and Draw<strong>in</strong>gs shall supersede measurement by scale and<br />
draw<strong>in</strong>gs to a larger scale shall take precedence over those to a smaller scale.<br />
Special dimensions or directions <strong>in</strong> the specification shall supersede all else.<br />
39.3 MEANING AND INTERPRETATION BY RAILWAY TO BE FINAL :<br />
All measurement, method of measurement, mean<strong>in</strong>g and <strong>in</strong>tent of specifications<br />
and <strong>in</strong>terpretation of Special Conditions of Contract, given and made by the<br />
Purchaser or by the Purchaser’s Eng<strong>in</strong>eer shall be f<strong>in</strong>al and b<strong>in</strong>d<strong>in</strong>g and shall<br />
be considered "excepted matters" <strong>in</strong> terms of conditions laid down <strong>in</strong> the<br />
General Conditions of Contract.<br />
40. TERMS OF PAYMENT:<br />
40.1 Payment to contractor will be made through EFT/ECS. All bills shall be submitted to<br />
the authority mentioned <strong>in</strong> Preamble or as nom<strong>in</strong>ated by CAO/IRPMU from time<br />
to time.<br />
40.2 Subject to any deductions or recovery which the Railway may be entitled to<br />
make under contract, the Contractor will be entitled to be paid from time to<br />
73
time by way of `on account payment' for supply of goods and `progress<br />
payment' for works as <strong>in</strong> the op<strong>in</strong>ion of the Eng<strong>in</strong>eer he has executed <strong>in</strong> terms<br />
of Contract.<br />
40.3 ON ACCOUNT PAYMENT:<br />
"On Account Payment" will be made for supply of equipment, materials <strong>in</strong>dicated<br />
<strong>in</strong> the supply schedule on receipt of materials <strong>in</strong> good condition at the<br />
site as certified by Eng<strong>in</strong>eers representative. On Account payments made will<br />
subsequently be adjusted aga<strong>in</strong>st payments due on Provisional Acceptance or<br />
F<strong>in</strong>al Acceptance. 75% (Seventy five percent) of the value of each consignment<br />
shall be paid on production of the follow<strong>in</strong>g documents :<br />
a) Store receipt certificate issued by Railway official/Representative as per<br />
Form-14.<br />
b) Orig<strong>in</strong>al Inspection certificate issued by Inspect<strong>in</strong>g Officer viz.<br />
RDSO/RITES/Railway Representative or Inspection Waiver Certificate issued by<br />
competent authority..<br />
c) Manufacturer's certificate for IP DSLAM equipments and associated equipment<br />
that the materials are <strong>in</strong> accordance with the specifications of the contract.<br />
d) Challan / Invoice <strong>in</strong> duplicate. No 3 rd party <strong>in</strong>voice generated <strong>in</strong> the name of<br />
Railway shall be accepted.<br />
e) A certificate that the materials supplied are as per the contract and the amount<br />
claimed <strong>in</strong> the <strong>in</strong>voice is correct as per terms of the contract.<br />
(i) Current Income Tax Clearance Certificate.<br />
(ii)<br />
Current Sale Tax Clearance Certificate. (Form No.58)<br />
40.4 All on account payments shall be covered by a stand<strong>in</strong>g <strong>in</strong>demnity bond <strong>in</strong> the<br />
approved form (see form No.6).<br />
40.5 15% (Fifteen percent) value of the goods supplied shall be paid after the<br />
successful completion of <strong>in</strong>stallation & commission<strong>in</strong>g of a location.<br />
40.6 15% payment aga<strong>in</strong>st supply of spares ( Para 13 of SCC) and of goods supplied<br />
but not <strong>in</strong>stalled / not required to be <strong>in</strong>stalled, shall be paid after issue of<br />
provisional acceptance certificate.<br />
40.7 90% (N<strong>in</strong>ety percent) of the <strong>in</strong>stallation rate quoted <strong>in</strong> rate schedule shall be paid<br />
to the contractor as on account bills only on production of certificate by the site<br />
eng<strong>in</strong>eer that relevant portion of <strong>in</strong>stallation has been completed.<br />
41. FINAL PAYMENT:<br />
74
F<strong>in</strong>al payment of 10% (Ten percent) of contract value shall be made after<br />
satisfactory operation and ma<strong>in</strong>tenance of the equipment under the supervision of<br />
the contractor for a period of one year after commission<strong>in</strong>g and issue of F<strong>in</strong>al<br />
Acceptance Certificate. On the basis of F<strong>in</strong>al Acceptance Certificate from the<br />
Purchaser's Eng<strong>in</strong>eer for all the works <strong>in</strong> all the sections covered <strong>in</strong> this<br />
contract, and reconciliation of materials issued, the f<strong>in</strong>al bill for the balance<br />
payment for each item of work shall be submitted by the Contractor along with<br />
a clear `No Claim Certificate'. The F<strong>in</strong>al Acceptance Certificate shall be issued by<br />
the Purchaser's Eng<strong>in</strong>eer only when he has accepted the work wholly after<br />
conduct<strong>in</strong>g the acceptance tests as per the details given <strong>in</strong> the technical<br />
specification and supplement.<br />
42. FINAL SETTLEMENT:<br />
On expiry of the warranty period and issue of the certificate of f<strong>in</strong>al<br />
acceptance of the entire <strong>in</strong>stallations the security deposit will be refunded or<br />
Bank Guarantee released to the Contractor after adjustment of any dues<br />
payable by the contractor.<br />
Railways shall release performance guarantee after satisfactory completion of<br />
warranty period, issue of certificate of proper function<strong>in</strong>g and ma<strong>in</strong>tenance of<br />
system by Eng<strong>in</strong>eer <strong>in</strong> charge of work, on sign<strong>in</strong>g of AMC Contract with Railway<br />
if so decided by Railway, submission of any security or bank guarantee required<br />
for AMC, compliance of any other relevant applicable clause and after recover<strong>in</strong>g<br />
any dues payable by contractor.<br />
43. CERTIFICATE FOR MODVAT BENEFITS ON BILLS:<br />
a) The Contractor should submit the follow<strong>in</strong>g certificate along with the bills :-<br />
"We certify that no additional duty set off on the Goods supplied by us have<br />
accrued under the MODVAT Scheme <strong>in</strong> force on the date of supply after we<br />
submitted our quotations and submitted the present bill."<br />
b) In the event of MODVAT credit be<strong>in</strong>g extended by the Government of India<br />
to more items than that already covered, the firm should advise the purchaser<br />
about the additional benefits accrued through a letter conta<strong>in</strong><strong>in</strong>g the follow<strong>in</strong>g<br />
certificate or any variation thereof as may be considered necessary by<br />
<strong>in</strong>dividual Railway adm<strong>in</strong>istration :-<br />
“We hereby declare that we can avail additional duty set off as per latest<br />
MODVAT scheme <strong>in</strong> force now and we hereby give a reduction of<br />
(___________) per unit and agree to revise the prices <strong>in</strong>dicated <strong>in</strong> the order. The<br />
current E.D. of (_________) is payable on this reduced price. Therefore, we<br />
request you to amend the order accord<strong>in</strong>gly."<br />
44. DEDUCTION FROM ON ACCOUNT PAYMENT BILLS:<br />
75
(i) All costs, damages or expenses, which Railways may have paid or <strong>in</strong>curred,<br />
which under the provisions of contract are Contractor's obligations will be<br />
deducted by Railways from progress payment Bills/Invoice of contractor, as<br />
and when it is understood that such an expenses has been <strong>in</strong>curred or paid for.<br />
(ii)<br />
All such claims of Railways shall, however, be duly supported by appropriate and<br />
certified vouchers, receipts or explanations as are available to enable the<br />
contractor to identify such claims.<br />
45. TAXES:<br />
45.1 The Contractor and all personnel employed by him shall pay such taxes like<br />
Income Tax as are payable under statutory laws of India and the Purchaser<br />
WILL NOT ACCEPT any liability for the same.<br />
45.2 Deduction of Income Tax at source as per provisions of F<strong>in</strong>ance Act and<br />
Income Tax Act <strong>in</strong> force shall be made from the Contractor/Sub-Contractor and<br />
the amount so deducted may be credited to the Central Government.<br />
45.3 Wherever the law makes it statutory for the Purchaser to deduct any amount<br />
towards Sales Tax on Works Contract, the same will be deducted and remitted to<br />
the concerned authority.<br />
46. MOBILIZATION ADVANCE (Not applicable <strong>in</strong> Present tender)<br />
(a)<br />
If required by the Contractor, mobilisation advance limited to 10% of contract<br />
value shall be payable on submission of irrevocable Bank Guarantee from a<br />
Nationalised Bank <strong>in</strong> India or the State Bank of India <strong>in</strong> a form acceptable to the<br />
Railway (Form No.8). This advance shall be payable <strong>in</strong> two stages as under :-<br />
Stage : 1.<br />
5% of the contract value on sign<strong>in</strong>g the contract.<br />
2. 5% of the contract value on mobilisation of establishment etc., i.e.<br />
sett<strong>in</strong>g up of project office and commencement of telecom. Works.<br />
Interest: - The mobilisation advance shall carry on <strong>in</strong>terest at the rate of<br />
18% per annum and recovery of the mobilisation advance along with its<br />
<strong>in</strong>terest shall be made from `On account and progress bills <strong>in</strong>clud<strong>in</strong>g design<br />
payment and advance payments for the work on pro-rata basis. The <strong>in</strong>terest<br />
will be charged on balance outstand<strong>in</strong>g on the first day of each month.<br />
The recovery of the advance shall be commenc<strong>in</strong>g when the work to an extent of<br />
15% of the provisional value of the contract is completed. The recovery of<br />
pr<strong>in</strong>cipal and <strong>in</strong>terest shall be made at the rate of 15% of on account and/or<br />
progress payment such that the entire amount is recovered before total<br />
payment reach 85% of the value of the contract.<br />
76
(b)<br />
(c)<br />
(d)<br />
(e)<br />
(f)<br />
In case pr<strong>in</strong>cipal and <strong>in</strong>terest could not be deducted progressively from<br />
progress/on account bills dur<strong>in</strong>g the course of the year, the <strong>in</strong>terest <strong>in</strong> mobilisation<br />
advance as accrued <strong>in</strong> the end of an year will be recovered with<strong>in</strong> the first 30<br />
days of the next year from the progress/on account bills or any other bills which<br />
may be made by the Railways to the Contractor. If, for the reason whatever,<br />
progress/on account bill or any other amount is paid to the Contractor, he will<br />
still pay to the Railways the accrued <strong>in</strong>terest <strong>in</strong> full with<strong>in</strong> the said 30 days of<br />
the next year. Otherwise, the unpaid <strong>in</strong>terest will be added on to the Pr<strong>in</strong>cipal<br />
and <strong>in</strong>terest for the next year will be charged on the balance compris<strong>in</strong>g Pr<strong>in</strong>cipal<br />
as well as unpaid <strong>in</strong>terest.<br />
In case of extension of the date of completion due to any reason whatsoever the<br />
<strong>in</strong>terest on the mobilisation advance outstand<strong>in</strong>g would cont<strong>in</strong>ue to accrue as<br />
specified earlier and the contractor/firm would make the payment aga<strong>in</strong>st the<br />
advance <strong>in</strong> the same manner as specified <strong>in</strong> Para (b) above.<br />
No advance/extra payment other than stated above shall be payable aga<strong>in</strong>st the<br />
works.<br />
The Tenderers shall specifically <strong>in</strong>dicate <strong>in</strong> their offer whether mobilisation<br />
advance is required by them. In case no specific demand has been made <strong>in</strong> the<br />
offer, grant of mobilisation advance will not be considered subsequently.<br />
No mobilisation advance would be considered for Contract with a value less<br />
than Rs.1 (one) crore.<br />
47. INSURANCE:<br />
47.1 The Contractor shall take out and keep <strong>in</strong> force a policy or policies of <strong>in</strong>surance<br />
aga<strong>in</strong>st all liabilities of the Contractor or the Purchaser at common law or under<br />
any statute <strong>in</strong> respect of accidents to persons who shall be employed by the<br />
contractor <strong>in</strong> or about the site for the purpose of carry<strong>in</strong>g out the works on the<br />
site. The Contractor shall also take out and keep <strong>in</strong> force a policy or policies of<br />
Insurance aga<strong>in</strong>st all recognised risks to their offices and depots. Such <strong>in</strong>surance<br />
shall <strong>in</strong> all respects be to the approval of the Purchaser and if he so requires <strong>in</strong><br />
his name.<br />
47.2 INSURANCE OF MATERIALS & INSTALLATIONS:<br />
The Contractor shall take out and keep <strong>in</strong> force a policy or policies of Insurance<br />
for all materials <strong>in</strong>clud<strong>in</strong>g Railway supply materials equipment irrespective of<br />
whether used up <strong>in</strong> the portion of work already done or kept for the use <strong>in</strong> the<br />
balance portion of the work until such works are provisionally handed over to<br />
the Railways. For this purpose the works are deemed to have been provisionally<br />
handed over when Provisional acceptance certificate is issued for the Subsection<br />
as per para 26 of SCC.<br />
77
47.3 The Contractor shall not be liable for losses/damages to the materials either used<br />
up <strong>in</strong> the portion of work done or his material kept for use at site, <strong>in</strong><br />
consequence of mut<strong>in</strong>y, or other similar causes over which the Contractor has no<br />
control and which cannot be <strong>in</strong>sured. Such losses or damages shall be the liability<br />
of the Purchaser and if required by the Purchaser, be made good by the<br />
contractor, at the cost of the Purchaser.<br />
47.4 The Contractor should, however, <strong>in</strong>sure the stores brought to site, aga<strong>in</strong>st risks<br />
<strong>in</strong> consequence of war and <strong>in</strong>vasion, as required under the Emergency Risk<br />
(Goods) Insurance Act <strong>in</strong> force from time to time.<br />
47.5 It may be noted that the beneficiary of the <strong>in</strong>surance policy should be Railways<br />
or the policies should be pledged <strong>in</strong> favour of Railway. The contractor shall keep<br />
the policy/policies current till the <strong>in</strong>stallations are provisionally handed over to<br />
the Purchaser. It may also be noted that <strong>in</strong> the event of contractor's failure<br />
to keep the policy current and alive, renewal of the policy will be done by the<br />
purchaser for which the cost of the premium plus 20% of premium shall be<br />
recovered from the contractor.<br />
47.6 For purpose of enabl<strong>in</strong>g the contractor to take the <strong>in</strong>surance cover <strong>in</strong><br />
connection with this contract, the purchaser's eng<strong>in</strong>eer will advise the<br />
approximate price of all the Railway supply materials to the contractor.<br />
47.7 The Contractor shall take out all Insurance covers <strong>in</strong> connection with this<br />
contract with General Insurance Corporation of India only.<br />
48. FORCE MAJEURE CLAUSE :<br />
If at any time, dur<strong>in</strong>g the cont<strong>in</strong>uance of this contract, the performance, <strong>in</strong> whole<br />
or part, by either party, of any obligation under this contract shall be prevented or<br />
delayed by reason of any war, hostility, act of the public enemy, Civil<br />
Commotion, Sabotage, Fires, Floods, Earth quakes, explosions, strikes,<br />
epidemics, quarant<strong>in</strong>e, restrictions lockouts, any statute, statutory rules,<br />
regulations, order of requisitions issued by any Government Department or<br />
Competent Authority or acts of God (here-<strong>in</strong> after referred to as event) then<br />
provided notice of the happen<strong>in</strong>g of any such, event is given by either party to<br />
the other with<strong>in</strong> twenty one days from the date of occurrence thereof neither<br />
party shall by reason of such event be entitled to term<strong>in</strong>ate this Contract nor<br />
shall either party have any claim for damage aga<strong>in</strong>st the other <strong>in</strong> respect of such<br />
non-performance or delay <strong>in</strong> performance, and the obligations under the<br />
Contract shall be resumed as soon as practicable after such event has come to an<br />
end or ceased to exist, provided further that if the performance <strong>in</strong> whole or<br />
part of any obligation under this contract is prevented or delayed by reason of<br />
any such event beyond a period as mutually agreed to by the Railways and the<br />
Contractor after any event or 60 days <strong>in</strong> the absence of such an agreement<br />
whichever is more, either party may at its option term<strong>in</strong>ate the Contract<br />
provided also that if the contract is so term<strong>in</strong>ated under this clause the Railways<br />
78
may at the time of such term<strong>in</strong>ation take over from the Contractor at prices as<br />
provided for <strong>in</strong> the contract, all works executed or works under execution.<br />
49. SETTLEMENT OF DISPUTE AND ARBITRATION:<br />
49.1 MATTERS FINALLY DETERMINED BY THE RAILWAY:<br />
All disputes or differences of any k<strong>in</strong>d whatsoever aris<strong>in</strong>g out of or <strong>in</strong> connection<br />
with the contract, whether dur<strong>in</strong>g the progress of the work or after its completion<br />
and whether before or after the determ<strong>in</strong>ation of the contract shall be referred<br />
by the contractor to the Railway and the Railway shall with<strong>in</strong> 120 days after<br />
receipt of the contractor's representation make and notify decisions on all matters<br />
referred to by the contractor <strong>in</strong> writ<strong>in</strong>g provided that matters for which<br />
provision has been made <strong>in</strong> clauses 8(a), 18, 22(5), 39, 43(2), 45(a) 55, 55-<br />
A(5), 57, 57A, 61(1), 61(2) and 62(i)(b) of General Conditions of Contract or <strong>in</strong><br />
any clause of the Special Conditions of the Contract shall be deemed as<br />
'excepted matters' and decision of the Railway authority, thereon shall be<br />
f<strong>in</strong>al and b<strong>in</strong>d<strong>in</strong>g on the contractor provided further that 'excepted matters' shall<br />
stand specifically excluded from the purview of the arbitration clause and not<br />
be referred to arbitration.<br />
50. DEMAND FOR ARBITRATION:<br />
50.1 (i) In the event of any dispute or difference between the parties hereto as<br />
to the construction or operation of this contract, or the respective rights and<br />
liabilities of the parties on any matter <strong>in</strong> question, dispute or difference on any<br />
account or as to the withhold<strong>in</strong>g by the Railway of any certificate to which the<br />
contractor may claim to be entitled to, or if the Railway fails to make a decision<br />
with<strong>in</strong> 120 days, then and <strong>in</strong> any such case, but except <strong>in</strong> any of the 'excepted<br />
matters' referred to <strong>in</strong> clause 49.1 of these conditions, the contractor, after 120<br />
days but with<strong>in</strong> 180 days of his present<strong>in</strong>g his f<strong>in</strong>al claim on disputed matters<br />
shall demand <strong>in</strong> writ<strong>in</strong>g that the dispute or difference be referred to Arbitration.<br />
(ii)<br />
(a)<br />
(b)<br />
The demand for arbitration shall specify the matters which are <strong>in</strong> question or<br />
subject of the dispute or difference as also the amounts of claim item-wise.<br />
Only such dispute(s) or difference(s) <strong>in</strong> respect of which the demand has<br />
been made, together with counter claims or set off shall be referred to<br />
arbitration and other matters shall not be <strong>in</strong>cluded <strong>in</strong> the reference.<br />
The Arbitration preceed<strong>in</strong>gs shall be assumed to have commenced from the<br />
day, a written and valid demand for arbitration is received by the Railway.<br />
The claimant shall submit his claim stat<strong>in</strong>g the facts support<strong>in</strong>g the claims along<br />
with all relevant documents and the relief or remedy sought aga<strong>in</strong>st each claim<br />
with<strong>in</strong> a period of 30 days from the date of appo<strong>in</strong>tment of the Arbitral Tribunal.<br />
79
(c)<br />
(iii)<br />
The Railway shall submit its defence statement and counter claims, if any<br />
with<strong>in</strong> a period of 60 days of receipt of copy of claims from Tribunal thereafter,<br />
unless otherwise extension has been granted by Tribunal.<br />
No new claim shall be added dur<strong>in</strong>g proceed<strong>in</strong>gs by either party. However<br />
party may amend or supplement the orig<strong>in</strong>al claim or defence thereof dur<strong>in</strong>g<br />
the course of arbitration proceed<strong>in</strong>gs subject to acceptance by Tribunal hav<strong>in</strong>g<br />
due regard to the delay <strong>in</strong> mak<strong>in</strong>g it.<br />
(iv)<br />
If the contractor(s) does/do not prefer his/their specific and f<strong>in</strong>al claims <strong>in</strong><br />
writ<strong>in</strong>g, with<strong>in</strong> a period of 90 days of receiv<strong>in</strong>g the <strong>in</strong>timation from the<br />
Railways that the f<strong>in</strong>al bill is ready for payment, he/they will be deemed to<br />
have waived his/their claim(s) and the Railway shall be discharged and<br />
released of all liabilities under the contract <strong>in</strong> respect of these claims.<br />
50.2 OBLIGATIONS DURING PENDENCY OF ARBITRATION:<br />
Work under the contract shall, unless otherwise directed by the Eng<strong>in</strong>eer,<br />
cont<strong>in</strong>ue dur<strong>in</strong>g the arbitration proceed<strong>in</strong>gs, and no payment due or payable by<br />
the Railway shall be withheld on account of such proceed<strong>in</strong>gs, provided,<br />
however, it shall be open for Arbitral Tribunal to consider and decide whether<br />
or not such work should cont<strong>in</strong>ue dur<strong>in</strong>g arbitration proceed<strong>in</strong>gs.<br />
50.3 (a)<br />
(i) In cases where the total value of all claims <strong>in</strong> question added together does<br />
not exceed Rs.10,00,000/- (Rupees Ten Lakhs only), the Arbitral Tribunal<br />
consist of a sole arbitrator who shall be either the General Manager or a<br />
gazetted officer of Rail not below the grade of JA Grade nom<strong>in</strong>ated by the<br />
General Manager <strong>in</strong> that behalf. The sole arbitrator shall be appo<strong>in</strong>ted with<strong>in</strong><br />
60 days from the day when a written and valid demand for arbitration is received<br />
by Railway.<br />
(ii) In cases not covered by clause 50.3(a)(i), the Arbitral Tribunal shall<br />
consist of a panel of three Gazetted Railway Officers not below JA Grade, as<br />
the arbitrators. For this purpose, the Railway will send a panel of more than 3<br />
names of Gazetted Railway Officers of one or more departments, of the<br />
Railway to the contractor who will be asked to suggest to General Manager upto<br />
2 names out of the panel for appo<strong>in</strong>tments as contractor's nom<strong>in</strong>ee. The<br />
General Manager shall appo<strong>in</strong>t at least one out of them as the contractor's<br />
nom<strong>in</strong>ee and will, also simultaneously appo<strong>in</strong>t the balance number of<br />
arbitrators either from the panel or from outside the panel, duly <strong>in</strong>dicat<strong>in</strong>g the<br />
'Presid<strong>in</strong>g arbitrator from amongst the 3 arbitrators so appo<strong>in</strong>ted. While<br />
nom<strong>in</strong>at<strong>in</strong>g the arbitrators it will be necessary to ensure that one of them is from<br />
the Accounts department. An officer of Selection Grade of the Accounts<br />
department shall be considered of equal status to the officers <strong>in</strong> SA grade of<br />
other departments of the Railways for the purpose of appo<strong>in</strong>tment of arbitrators.<br />
80
iii) If one or more of the arbitrators appo<strong>in</strong>ted as above refuses to act as<br />
arbitrator, withdraws from his office as arbitrator, or vacates his/their<br />
office/offices or is/are unable or unwill<strong>in</strong>g to perform his functions as<br />
arbitrator for any reason whatsoever or dies or <strong>in</strong> the op<strong>in</strong>ion of the General<br />
Manager fails to act without undue delay, General Manager shall appo<strong>in</strong>t new<br />
arbitrator/arbitrators to act <strong>in</strong> his/their place <strong>in</strong> the same manner <strong>in</strong> which the<br />
earlier arbitrator/arbitrators had been appo<strong>in</strong>ted. Such re-constituted Tribunal<br />
may at its discretion, proceed with the reference from the stage at which it was<br />
left by the previous arbitrator(s).<br />
iv) The arbitral Tribunal shall have power to call for such evidence by way of<br />
affidavits or otherwise as the arbitral Tribunal shall th<strong>in</strong>k proper, and it shall be<br />
the duty of the parties hereto to do or cause to be done all such th<strong>in</strong>gs as may<br />
be necessary to enable the Arbitral Tribunal to make the award without any<br />
delay.<br />
v) While appo<strong>in</strong>t<strong>in</strong>g arbitrator(s) under Sub-clause (i), (ii) and (iii) above, due<br />
care shall be taken that he/they is/are not the one/those who had an opportunity<br />
to deal with the matters to which the contract relates or who <strong>in</strong> the course of<br />
his/their duties as Railway servant(s) expressed views on all or any of the matters<br />
under dispute or differences. The proceed<strong>in</strong>gs of the Arbitral Tribunal or the<br />
award made by such Tribunal will, however, not be <strong>in</strong>valid merely for the reason<br />
that one or more arbitrator had, <strong>in</strong> the course of his service, opportunity to deal<br />
with the matters to which the contract relates or who <strong>in</strong> the course of his/their<br />
duties expressed views on all or any of the matters under dispute.<br />
(b)<br />
(i) The arbitral award shall state <strong>in</strong> item-wise, the sum and reasons upon which it<br />
is based.<br />
(ii) A party may apply for corrections of any computational errors, any<br />
typographical or clerical errors or any other error of similar nature occur<strong>in</strong>g <strong>in</strong><br />
the award and <strong>in</strong>terpretation of a specific po<strong>in</strong>t of award to tribunal with<strong>in</strong> 30<br />
days of receipt of the award.<br />
(iii) A party may apply to tribunal with<strong>in</strong> 30 days of receipt of award to<br />
make on additional award as to claims presented <strong>in</strong> the arbitral proceed<strong>in</strong>gs<br />
but omitted from the arbitral award.<br />
50.4 In case of the Tribunal, compris<strong>in</strong>g of three Members, any rul<strong>in</strong>g or award shall<br />
be made by a majority of Members of Tribunal. In the absence of such a<br />
majority the views of the Presid<strong>in</strong>g Arbitrator shall prevail.<br />
50.5 Where the arbitral award is for the payment of money, no <strong>in</strong>terest shall be payable<br />
on whole or any part of the money for any period till the date on which the award<br />
<strong>in</strong> made.<br />
81
50.6 The cost of arbitration shall be Borne by the respective parties. The cost<br />
shall <strong>in</strong>ter-alia <strong>in</strong>clude fees of the arbitrator(s) as per the rates fixed by the<br />
Railway Adm<strong>in</strong>istration from time to time.<br />
50.7 Subject to the provisions of the aforesaid Arbitration and conciliation Act 1996<br />
and the rules there under and any statutory modification thereof shall apply to<br />
the arbitration proceed<strong>in</strong>gs under this clause.<br />
*****<br />
82
Section – II<br />
Chapter – 3<br />
Forms of Tenders etc.<br />
83
SECTION - II<br />
CHAPTER - 3<br />
FORMS OF TENDERS ETC.<br />
FORM NO. 1 : Offer letter.<br />
FORM NO. 2 : Not Applicable.<br />
FORM NO. 3 : Agreement.<br />
FORM NO. 4 : Guarantee Bond for Security Deposit.<br />
FORM NO. 5 : Statement of Deviations.<br />
FORM NO. 6 : Stand<strong>in</strong>g Indemnity Bond for on account<br />
Payments and Stores supplied by Rly.<br />
FORM NO. 7 : System Performance Guarantee.<br />
FORM NO. 8 : Bank Guarantee for Mobilisation Advance.<br />
FORM NO. 9 : Not Applicable<br />
FORM NO. 10 : Acknowledgement for receiv<strong>in</strong>g<br />
materials and Cable from Railways.<br />
FORM NO. 11 : Extension of period of completion on<br />
account of contractor.<br />
FORM NO. 12 : Extension of period of completion of<br />
work.<br />
FORM NO. 13 : Qualification Experience.<br />
FORM NO. 14 : Store Receipt Certificate.<br />
84
FORM-I<br />
Para-6.8 Chapter-I<br />
OFFER LETTER<br />
To<br />
The President of India,<br />
Act<strong>in</strong>g through Chief Adm<strong>in</strong>istrative Officer/IRPMU<br />
(or his successor),N C Railway,<br />
Shivaji Bridge(IRCOT Complex), New Delhi<br />
I/We ........................................................................ have read the various<br />
conditions to tender attached here to and hereby agree to abide by the said conditions.<br />
I/We also agree to keep this tender open for acceptance for a period of 180 days from the<br />
date fixed for open<strong>in</strong>g the same and <strong>in</strong> default thereof, I/We will be liable for forfeiture of<br />
my/our Earnest Money. I/We offer to do the work of Design, Supply, Installation and<br />
commission<strong>in</strong>g of IP DSLAM at various locations over Northern & North Central<br />
Railways and Central Organization of Railway Electrification at the rates quoted by<br />
me/us <strong>in</strong> the attached schedules and hereby b<strong>in</strong>d myself/ourselves to complete the work<br />
with<strong>in</strong> (-------- -------) months from the date `of issue of Letter of Acceptance of the<br />
tender. I/We also hereby agree to abide by the General and Special conditions of Contract<br />
and to carry out the work accord<strong>in</strong>g to the Specifications for materials and works laid<br />
down by the Railways for the present contract.<br />
A sum of Rs.________ herewith forwarded as “Earnest Money”. The full<br />
value of Earnest Money shall stand forfeited without prejudice to any other rights or<br />
remedies if,<br />
(a) I/We do not execute the contract documents with<strong>in</strong> 30 days after receipt of notice<br />
issued by the Railway that such documents are ready or,<br />
(b) I/We do not commence the work with<strong>in</strong> 10 days after receipt or orders to that<br />
effect.<br />
3. Until a formal agreement is prepared and executed the acceptance of this tender<br />
shall constitute a b<strong>in</strong>d<strong>in</strong>g contract between us subject to modifications, as may be<br />
mutually agreed to between us and <strong>in</strong>dicated <strong>in</strong> the “Letter of Acceptance” of my/our<br />
offer for this work.<br />
SIGNATURE OF CONTRACTOR(S)<br />
DATE :<br />
SIGNATURE OF WITNESS : CONTRACTOR(S) ADDRESS :<br />
1.............................................. .......................................................<br />
2.............................................. .......................................................<br />
85
FORM - 3<br />
Para-2/ Chapter-II<br />
AGREEMENT<br />
AN AGREEMENT made this ........................................................... day of<br />
....................................... Two Thousand .......................... between the President of India,<br />
act<strong>in</strong>g <strong>in</strong> the premises through the Chief Project Manager/IRPMU, North Central Railway<br />
or his successor ......................................... of the M<strong>in</strong>istry of Railways, Railway Board<br />
(here<strong>in</strong> after referred to as “the Railway”) of one part and Messers<br />
.................................................. (here<strong>in</strong> after referred to as “Contractor”) of the other part,<br />
a .......................... Firm (Status of the firm) be<strong>in</strong>g represented by .....................................<br />
(Name & Designation of the proprietor <strong>in</strong> case of sole proprietorship bus<strong>in</strong>ess or all the<br />
names and particulars <strong>in</strong> case of partnership firm etc.)<br />
Whereas <strong>in</strong> response to a call for Design, Supply, Installation and commission<strong>in</strong>g of<br />
IP DSLAM at various locations over Northern & North Central Railways and Central<br />
Organization of Railway Electrification as per tender papers at Annexure-A hereto the<br />
Contractor has submitted a tender as per Annexure-B hereto and whereas the said Tender<br />
of the Contractor has been accepted for .................. as per copy of Letter of Acceptance<br />
of Tender No..................................... dated ................... complete with enclosures at the<br />
accepted rates and agreed deviations from Tender Papers<br />
..................................................... as per Annexure-C hereto and at an estimated contract<br />
value of Rs...................... (Rupees ............................................................ only).<br />
Now this agreement witnesses that <strong>in</strong> consideration of the premises and the<br />
payment to be made by the purchaser to the contractor provided for here<strong>in</strong> below the<br />
Contractor shall supply all equipment and materials and execute and perform all works<br />
for which the said Tender of the Contractor has been accepted strictly accord<strong>in</strong>g to the<br />
various provisions <strong>in</strong> Annexure-B and C hereto and upon such supply, execute and<br />
perform to the satisfaction of the purchaser and the purchaser shall pay to the Contractor<br />
at the rates accepted as per the said Annexure-C and <strong>in</strong> terms of provisions there<strong>in</strong>. In<br />
case if the Contractor is not a company <strong>in</strong>corporated under the Companies Act, 1956, the<br />
expression “Contractor” shall unless otherwise excluded by or repugnant to the subject or<br />
context mean and <strong>in</strong>clude each of the successors- <strong>in</strong>- <strong>in</strong>terest, agents, nom<strong>in</strong>ees, servants,<br />
beneficiaries etc. If it is a Sole Proprietorship bus<strong>in</strong>ess, <strong>in</strong> addition to this, such<br />
expression Contractor will also <strong>in</strong>clude, each of his heirs, executors, and legal<br />
representatives.<br />
In the witness where of the parties have hereunto set and subscribed their<br />
respective hands and/or seals day and year respectively mentioned aga<strong>in</strong>st their<br />
respective signature.<br />
Signed and delivered at .................................................................... by Shri<br />
..................................................... for and on behalf of Messers<br />
....................................................................... the Contractor with<strong>in</strong> named <strong>in</strong> the presence<br />
of :-<br />
1. Signature :<br />
86
Date :<br />
Name <strong>in</strong> block Capitals :<br />
Address :<br />
2. Signature :<br />
Date :<br />
Name <strong>in</strong> block Capitals :<br />
Address :<br />
Signed and delivered at ............................................... for and on behalf of the<br />
President of India by Shri .......................................................... (General Manager or his<br />
successor) .............................................. Railway .................................. M<strong>in</strong>istry of<br />
Railways (Railway Board) <strong>in</strong> the presence of :-<br />
1. Signature :<br />
Date :<br />
Name <strong>in</strong> block Capitals :<br />
Address :<br />
2. Signature :<br />
Date :<br />
Name <strong>in</strong> block Capitals :<br />
Address :<br />
Annexure -A<br />
Annexure -B<br />
Annexure -C<br />
: Tender Paper No.<br />
: Firm’s Tender No.<br />
: Letter of Acceptance of Tender<br />
Complete with enclosures.<br />
_________________________<br />
(Signature)<br />
Dated:<br />
87
GUARANTEE BOND FOR SECURITY DEPOSIT<br />
(On Stamp Paper of Appropriate value)<br />
(To be used by approved Scheduled Banks)<br />
FORM-4<br />
Para-1/Chapter-II<br />
In consideration of the President of India (here<strong>in</strong>after called “the Government”) hav<strong>in</strong>g<br />
agreed to exempt .................................................... (here<strong>in</strong>after called “The said<br />
contractor(s)”) from the demand, under the terms and conditions of an agreement<br />
No........................................... dated .................... made between .............................. and<br />
.................... for ............................................................. (here<strong>in</strong> after called “the said<br />
agreement”) of Security Deposit for the due fulfillment by the said contractor(s) of the<br />
terms and conditions conta<strong>in</strong>ed <strong>in</strong> the said Agreement, or production of a Bank Guarantee<br />
for Rs............. (Rupees ....................................... only), we<br />
...............................................................<br />
(<strong>in</strong>dicate the name of Bank) (here<strong>in</strong>after referred to as<br />
‘the Bank”) at the request of ................................. Contractor(s) do hereby undertake to<br />
pay to the Government an amount not exceed<strong>in</strong>g Rs............................ aga<strong>in</strong>st any loss or<br />
damage caused to or suffered or would be caused to or suffered by the Government by<br />
reason of any breach by the said Contractor(s) of any of the terms or conditions conta<strong>in</strong>ed<br />
<strong>in</strong> the said Agreement.<br />
2. We ...................................................................... Bank do hereby undertake to pay<br />
the amounts due and payable under this Guarantee without any demur, merely on demand<br />
from the Government stat<strong>in</strong>g the amount is claimed is due by way of loss or damage<br />
caused to or would be caused to or suffered by the Government by reason of breach by<br />
the said Contractor(s) of any of terms or conditions conta<strong>in</strong>ed <strong>in</strong> the said Agreement or<br />
by reason of the Contractor(s) failure to perform the said Agreement. Any such demand<br />
made on the Bank shall be conclusive as regards the amount due and payable by the Bank<br />
under this guarantee. However, our liability under this guarantee shall be restricted to an<br />
amount not exceed<strong>in</strong>g Rs...............................<br />
3. We .................................................................... bank undertake to pay to the<br />
Government any money so demanded notwithstand<strong>in</strong>g any dispute or disputes raised by<br />
the Contractor(s)/Supplier(s) <strong>in</strong> any suit or proceed<strong>in</strong>gs pend<strong>in</strong>g before any court or<br />
Tribunal relat<strong>in</strong>g thereto our liability under this present be<strong>in</strong>g absolute and unequivocal.<br />
The payment so made by us under this Bond shall be a valid discharge of our<br />
liability for payment there under and the Contractor(s)/ Supplier(s) shall have no claim<br />
aga<strong>in</strong>st us for mak<strong>in</strong>g such payment.<br />
4. We ........................................................... Bank further agree that the Guarantee<br />
here<strong>in</strong> conta<strong>in</strong>ed shall rema<strong>in</strong> <strong>in</strong> full force and effect dur<strong>in</strong>g the period that would<br />
be taken for the performance of the said Agreement and that it shall cont<strong>in</strong>ue to be<br />
enforceable till all the dues of the Government under or by virtue of the said<br />
88
agreement have been fully paid and its claims satisfied or discharged or till<br />
.................... office/ department) M<strong>in</strong>istry of<br />
........................... certifies that the terms and conditions of the said agreement have<br />
been fully and properly carried out by the said contractor(s) and accord<strong>in</strong>gly<br />
discharges this Guarantee. Unless a demand or claim under the Guarantee is made<br />
on us <strong>in</strong> writ<strong>in</strong>g on or before the ................................. we shall be discharged from<br />
all liability under this Guarantee thereafter.<br />
5. We ................................................................................ further agree with<br />
(Indicate the name of bank)<br />
the Government that the Government shall have the fullest liberty without affect<strong>in</strong>g <strong>in</strong><br />
any manner our obligations hereunder to vary any of the terms and conditions of the<br />
Agreement or to extend time of performance by the said Contractor(s) from time to time<br />
or to postpone for any time or from time to time any of the powers exercisable by the<br />
Government aga<strong>in</strong>st the said Contractor(s) and to forebear or enforce any other terms and<br />
conditions relat<strong>in</strong>g to the said Agreement and we shall not be relieved from our liability<br />
by reason of any such variation, or extension to the said Contractor(s) or for any<br />
forbearance, act or omission on the part of Government or any <strong>in</strong>dulgence by the<br />
Government to the said Contractor(s) or by any such matter or th<strong>in</strong>g whatsoever which<br />
under the law relat<strong>in</strong>g to sureties would but for this provision, have no effect of so<br />
reliev<strong>in</strong>g us. We, further agree to acknowledge Governments right to extend time of<br />
performance of the Contractor from time to time and <strong>in</strong> case the guarantee extends<br />
beyond the period as <strong>in</strong>dicated here<strong>in</strong>, the Government shall have the right to a fresh<br />
guarantee bond for the extended period.<br />
6. This Guarantee will not be discharged due to the change <strong>in</strong> the Constitution of the<br />
Bank or the Contractor(s)/Supplier(s).<br />
7. We ...................................................... lastly undertake not to revoke this<br />
(Indicate the name of bank)<br />
Guarantee dur<strong>in</strong>g its currency except with the previous consent of the Government <strong>in</strong><br />
writ<strong>in</strong>g.<br />
Dated the .......................... day of ..................200 for<br />
......................................................................................<br />
(Indicate the name of the bank)<br />
89
FORM-5<br />
Para-6.8/Chapter-I<br />
STATEMENT OF DEVIATIONS<br />
PROFORMA FOR STATEMENT OF DEVIATIONS<br />
1. The follow<strong>in</strong>g are the particulars of deviations from requirement of the<br />
<strong>in</strong>structions to Tenderers, General Conditions of contract.<br />
1.1 Instructions to Tenderers & Condition of Tender<strong>in</strong>g<br />
CLAUSE DEVIATION REMARKS<br />
(INCLUDING JUSTIFICATION)<br />
1.2 General Conditions of Contract<br />
CLAUSE DEVIATION REMARKS<br />
(INCLUDING JUSTIFICATION)<br />
1.3 Special Conditions of Contract<br />
CLAUSE DEVIATION REMARKS<br />
(INCLUDING JUSTIFICATION)<br />
2. The follow<strong>in</strong>g are the particulars of deviations from requirement of the technical<br />
specifications :<br />
( Separate Statement for each specification)<br />
CLAUSE DEVIATION REMARKS<br />
(INCLUDING JUSTIFICATION)<br />
Note : Where there is no deviation, the statement should be returned duly<br />
signed with an endorsement <strong>in</strong>dicat<strong>in</strong>g no deviations.<br />
90
FORM-6<br />
Para-8.2/Chapter-II<br />
STANDING INDEMNITY BOND<br />
(FOR ON ACCOUNT PAYMENTS & STORES SUPPLIED BY<br />
RLYS.)<br />
(On Stamp paper of Requisite Value)<br />
We, M/s............................................................. hereby undertake that we hold at<br />
our stores Depot/s at ................................................ for and on behalf of the President of<br />
India <strong>in</strong> the premises through the General Manager or his successor, North Central<br />
Railway (here<strong>in</strong> after referred to as “the Purchaser”) all materials for which “On<br />
Account” payments have been made to us aga<strong>in</strong>st the contract for Design, Supply,<br />
Installation and commission<strong>in</strong>g of IP DSLAM at various locations over Northern & North Central<br />
Railways and Central Organization of Railway Electrification vide letter of Acceptance of<br />
Tender No....................................... dated ................ and the materials handed over to us<br />
by the purchaser for the purpose of execution of the said Contract, until such time the<br />
materials are duly erected or otherwise handed over to him.<br />
We shall be entirely responsible for the site custody and protection of the said<br />
materials aga<strong>in</strong>st all risk till they are duly delivered as erected equipment to the purchaser<br />
or as he may direct otherwise and shall <strong>in</strong>demnify the Purchaser aga<strong>in</strong>st any loss, damage<br />
or deterioration what so ever <strong>in</strong> respect of the said materials while <strong>in</strong> our possession and<br />
aga<strong>in</strong>st disposal of surplus materials. The said materials shall at all times be open to<br />
<strong>in</strong>spection by any Officer authorized by the Chief Adm<strong>in</strong>istrative Officer/IRPMU, N C<br />
Railway, Shivaji Bridge, NewDelhi.<br />
Should any loss, damage or deterioration of materials occur or surplus materials<br />
disposed off and refund becomes due, the purchaser shall be entitled to recover from us<br />
the full cost as per prices <strong>in</strong>cluded <strong>in</strong> the Contract (as applicable) and also<br />
compensation for such loss or damage if any along with<br />
the amount to be refunded without prejudice to any other remedies available to him by<br />
deduction from any sum due or any sum which at any time hereafter becomes due to us<br />
under the said or any other Contract.<br />
Dated this ...................... day of ........................, 200<br />
Signature of Witness :<br />
Name of Witness <strong>in</strong> block letters :<br />
Address :<br />
for and on behalf of<br />
Messers ........................................ (Contractor)<br />
91
FORM-7<br />
Para-22.2/Chapter-I<br />
SYSTEM PERFORMANCE GUARANTEE<br />
PROFORMA FOR THE SYSTEM PERFORMANCE GUARANTEE<br />
To<br />
The President of India,<br />
I/We........................................................................................ hereby<br />
guarantee that the design on the basis of which we have submitted our<br />
Tender No................................................. has been carefully made to<br />
conform to the end objectives <strong>in</strong> the tender documents and to technical<br />
specification there<strong>in</strong>. We further guarantee that <strong>in</strong> the event of the<br />
performance of the system, when <strong>in</strong>stalled, not comply<strong>in</strong>g with the end<br />
objectives or with the specifications conta<strong>in</strong>ed <strong>in</strong> the tender documents, we<br />
shall provide further <strong>in</strong>puts to enable the Railways to realise the end<br />
objectives conta<strong>in</strong>ed <strong>in</strong> these documents without any additional payment for<br />
any additional equipment which may be required <strong>in</strong> this regard. We further<br />
guarantee that all the expenses <strong>in</strong>clud<strong>in</strong>g the expenses <strong>in</strong>curred <strong>in</strong> India for<br />
provid<strong>in</strong>g the additional <strong>in</strong>puts under the System guarantee will be borne by<br />
us. We further guarantee that these additional <strong>in</strong>puts will be provided by us<br />
to make the system workable with<strong>in</strong> 8 months from the date on which this<br />
guarantee is <strong>in</strong>voked by the Purchaser.<br />
Seal :<br />
( Signature of firm’s authorised Officer)<br />
Signature of Witness :<br />
1..................................................<br />
2.................................................<br />
92
FORM-8<br />
Para-46/Chapter-II<br />
PROFORMA OF BANK GUARANTEE FOR MOBILISATION<br />
ADVANCE<br />
(On Stamp Paper of requisite value)<br />
(To be used by approved Scheduled Banks)<br />
1. In consideration of the President of India (here<strong>in</strong>after called “the Government”)<br />
hav<strong>in</strong>g agreed to exempt ...................................................... {here<strong>in</strong>after called “the said<br />
Contractor(s)”} from the demand, under the terms and conditions of an Agreement<br />
No.......................................... dated ............... made between ........................................<br />
and ......................................... for ......................................................... (here<strong>in</strong>after called<br />
“the said Agreement”) of Mobilisation advance payment for the due fulfillment by the<br />
said Contractor(s) of the terms and conditions conta<strong>in</strong>ed <strong>in</strong> the said Agreement, or<br />
production of a Bank Guarantee for Rs..................... (Rupees............................. only).<br />
We, ...................................................................................... here<strong>in</strong>after<br />
(<strong>in</strong>dicate the name of the Bank)<br />
referred to as “the Bank”) at the request of ........................................ Contractor(s) do<br />
hereby undertake to pay Rs................................. aga<strong>in</strong>st any loss or damage caused to or<br />
suffered or would be caused to or suffered by the Government by reason of any breach by<br />
the said Contractor(s) of any of the terms or conditions conta<strong>in</strong>ed <strong>in</strong> the said Agreement.<br />
2. We, ...................................................................... Bank do hereby undertake to pay<br />
the amounts due and payable under this Guarantee without any demur, merely on demand<br />
from the Government stat<strong>in</strong>g that the amount is claimed is due by way of loss or damage<br />
caused to or would be caused to or suffered by the Government by reason of breach by<br />
the said Contractor(s) of any of terms or conditions conta<strong>in</strong>ed <strong>in</strong> the said Agreement or<br />
by reason of the Contractor(s) failure to perform the said Agreement. Any such demand<br />
made on the Bank shall be conclusive as regards the amount due and payable by the Bank<br />
shall be conclusive as regards the amount due and payable by the Bank under this<br />
guarantee. However, our liability under this guarantee shall be restricted to an amount<br />
not exceed<strong>in</strong>g Rs...................................<br />
3. We, .......................................................... bank undertake to pay to the<br />
Government any money so demanded not withstand<strong>in</strong>g any dispute or disputes raised by<br />
the Contractor(s)/Supplier(s) <strong>in</strong> any suit or proceed<strong>in</strong>gs pend<strong>in</strong>g before any Court or<br />
Tribunal relat<strong>in</strong>g thereto our liability under this present be<strong>in</strong>g, absolute and unequivocal.<br />
The payment so made by us under this Bond shall be a valid discharge of our liability for<br />
payment there under and the Contractor(s)/Supplier(s) shall have no claim aga<strong>in</strong>st us for<br />
mak<strong>in</strong>g such payment.<br />
93
4. We, ............................................................. Bank further agree that the Guarantee<br />
here<strong>in</strong> conta<strong>in</strong>ed shall rema<strong>in</strong> <strong>in</strong> full force and effect dur<strong>in</strong>g the period that would<br />
be taken for the performance of the said Agreement and that it shall cont<strong>in</strong>ue to be<br />
enforceable till all the dues of the Government under or by virtue of the said<br />
Agreement have been fully paid and its claims satisfied or discharged or till<br />
....................... office/Department) M<strong>in</strong>istry of ......................... certifies that the<br />
terms and conditions of the said Agreement have been fully and properly carried<br />
out by the said Contractor(s) and accord<strong>in</strong>gly discharges this Guarantee. Unless a<br />
demand or claim under the Guarantee is made on us <strong>in</strong> writ<strong>in</strong>g on or before the<br />
.............. (1) ................................. we shall be discharged from all liability under<br />
this Guarantee thereafter.<br />
5. We, ............................................................................ further agree with<br />
(<strong>in</strong>dicate the name of Bank)<br />
the Government that the Government shall have the fullest liberty without our consent<br />
and without affect<strong>in</strong>g <strong>in</strong> any manner our obligations hereunder to vary any of the terms<br />
and conditions of the Agreement or to extend time of performance by the said<br />
Contractor(s) from time to time or to postpone for any time or from time to time any of<br />
the powers exercisable by the Government aga<strong>in</strong>st the said Contractor(s) and to forbear<br />
or enforce any of the terms and conditions relat<strong>in</strong>g to the said Agreement and we shall<br />
not be relieved from our liability by reason of any such variation, or extension to the said<br />
Contractor(s) or for any forbearance, act or omission on the part of Government or any<br />
<strong>in</strong>dulgence by the Government to the said Contractor(s) or by any such matter or th<strong>in</strong>g<br />
whatsoever which under the law relat<strong>in</strong>g to sureties would, but for this provision, have<br />
affect of so reliev<strong>in</strong>g us.<br />
6. This Guarantee will not be discharged due to the change <strong>in</strong> the Constitution of the<br />
Bank or the Contractor(s)/Supplier(s).<br />
7. We, .......................................................... lastly undertake not to revoke<br />
(<strong>in</strong>dicate the name of Bank)<br />
this Guarantee dur<strong>in</strong>g its currency except with the previous consent of the Government <strong>in</strong><br />
writ<strong>in</strong>g.<br />
Dated the ......................... day of .................. 200<br />
for ..................................................................<br />
(<strong>in</strong>dicate the name of the Bank)<br />
Witness<br />
1 Signature ...........................................<br />
Name ...........................................<br />
2 Signature ...........................................<br />
Name ...........................................<br />
NOTE : (1) The guarantee shall be valid for a period of two months after<br />
the expiry of the currency of the contract.<br />
94
FORM-10<br />
Para-8.3/Chapter-II<br />
ACKNOWLEDGEMENT<br />
FOR RECEIVING MATERIALS FROM RAILWAY<br />
STATION :<br />
DATE :<br />
Sub: - Receipt of Materials from Railway.<br />
It is hereby acknowledged that the follow<strong>in</strong>g material as detailed have<br />
been received <strong>in</strong> full and good condition by me on .............<br />
........................... at ........................ for the work com<strong>in</strong>g under the<br />
Agreement No.............................. dated ................<br />
----------------------------------------------------------------------------------------<br />
Sl.No. Description of Material Quantity Remarks<br />
if any<br />
----------------------------------------------------------------------------------------<br />
----------------------------------------------------------------------------------------<br />
Witnessed by: -<br />
-------------------------------- ------------------------------------<br />
(Signature of Purchaser’s<br />
(Signature of Contractor or<br />
Representative with<br />
Contractor’s Representative)<br />
Designation )<br />
95
EXTENSION OF PERIOD OF COMPLETION OF WORK<br />
ON CONTRACTOR’S ACCOUNT<br />
FORM-11<br />
Para-35/Chapter-II<br />
No. Date :<br />
(Regd. With A/D)<br />
To<br />
.............................................<br />
.............................................<br />
Sub : (i) ................................................. (Name of Work)<br />
(ii)Acceptance Letter No. ....................................................<br />
(iii) Undertak<strong>in</strong>g /Agreement No. .......................................<br />
Ref : ......................... (Quote specific application of the Contractor for extension to<br />
date, if received).<br />
Dear Sir,<br />
The stipulated date for completion of the work mentioned above is/was ............... .<br />
However, the work is/was not completed on this date.<br />
Expect<strong>in</strong>g that you may be able to complete the work if some time is given and <strong>in</strong><br />
consideration of your Letter No.............................., the General Manager (or his successor) on<br />
behalf of the president of India, although not bound to do so, hereby extends the time for<br />
completion from ............. to ..............<br />
Please note that liquidated damages @1/2% per week or part thereof of the entire contract<br />
value will be recovered for delay <strong>in</strong> the completion of the work after the expiry of (1)<br />
....................... from you as mentioned <strong>in</strong> para 35 of the Special Conditions of Contract for the<br />
extended period.<br />
The above extension of the completion date will also be subject to the further condition<br />
that no <strong>in</strong>crease <strong>in</strong> rates on any account will be payable to you.<br />
Please note that <strong>in</strong> the event of decl<strong>in</strong><strong>in</strong>g to accept the extension on the above said<br />
conditions or <strong>in</strong> the event of your failure after accept<strong>in</strong>g or act<strong>in</strong>g up to this extension to complete<br />
the work by (2)....................... (here mention the extended date), further action will be taken <strong>in</strong><br />
terms of relevant para of Conditions of Contract.<br />
Your’s faithfully,<br />
for & on behalf of President of India.<br />
Note :-<br />
1. Give here the stipulated date for completion without any penalty fixed earlier.<br />
2. Here mention the extended date.<br />
96
EXTENSION OF PERIOD OF COMPLETION OF WORK<br />
No. Date :<br />
To<br />
..................................<br />
..................................<br />
..................................<br />
Dear Sirs,<br />
Sub : (i) ............................................ (Name of work)<br />
(ii) Acceptance Letter No.........................................<br />
(iii) Undertak<strong>in</strong>g/Agreement No...............................<br />
Ref : .......................... (quote specific application of the<br />
Contractor for extension to the date, if received) .<br />
FORM-12<br />
Para-36/Chapter-II<br />
The stipulated date for completion of subject work under the above contract was<br />
............................ In consideration of the Contractor’s Letter No..............................., The<br />
General Manager (or his successor) behalf of the President of India, is pleased to grant<br />
extension of the time for completion of works without liquidated damages under para 36<br />
of Chapter II , Section II of the contract as mentioned below :<br />
“...................................................................................”<br />
It may be noted that unless repugnant to the context, all the terms and<br />
conditions of the Contract will rema<strong>in</strong> unaltered dur<strong>in</strong>g the extended period from<br />
...................... to ...................... also, and further no <strong>in</strong>creased additional rates and claims<br />
of recoveries which have not been already envisaged <strong>in</strong> terms of the conditions of the<br />
Contract will be leviable either by you or by the purchaser <strong>in</strong> respect of this extended<br />
period.<br />
Your’s faithfully,<br />
( )<br />
for and on behalf of President of India<br />
97
FORM-13<br />
QUALIFICATION EXPERIENCE<br />
List of Works completed<br />
Description<br />
of Work<br />
Organisation<br />
for whom<br />
executed<br />
Approx.<br />
value of<br />
contract<br />
at the<br />
time of<br />
award<br />
Date<br />
of<br />
award<br />
Date of<br />
scheduled<br />
completion<br />
of work<br />
Date of actual<br />
Start<br />
Completion<br />
F<strong>in</strong>al<br />
value of<br />
contract<br />
List of Works <strong>in</strong> Hand<br />
Description<br />
of work<br />
Contract<br />
Value<br />
Approx. value of balance<br />
work yet to be done<br />
Date of award<br />
98
FORM-14<br />
RECEIPT CERTIFICATE (FOR SUPPLY ONLY)<br />
From: Sr.Section Eng<strong>in</strong>eer/Section Eng<strong>in</strong>eer(Signal/Telecom)/<br />
North Central Railway,<br />
No. Date :<br />
1 Contract No<br />
2 Name of Work<br />
3 Item No. As <strong>in</strong> Rate Schedule<br />
4 Description of Item.<br />
5 Material <strong>in</strong>spected by :<br />
6 Despatch particular & date<br />
7 Qty as per despatch particular<br />
8 Qty received<br />
9 Qty short received<br />
10 Condition of Stores Received<br />
11 Name of Firm & Address<br />
12 Place of receipt<br />
13 Date of receipt<br />
14 Ledger No.<br />
15 Name & designation of Stores<br />
In-charge<br />
--------------------------------------<br />
Signature of Stores-<strong>in</strong>-Charge<br />
99
Section – III<br />
Technical Specification<br />
100
Section – III<br />
TECHNICAL SPECIFICATION<br />
INDEX<br />
Chapter – 1<br />
Chapter – 2<br />
Chapter – 3<br />
Chapter – 4<br />
Chapter – 5<br />
Chapter – 6<br />
Chapter – 7<br />
Chapter – 8<br />
Chapter – 9<br />
Technical Overview<br />
Equipment Requirement & Configuration<br />
Technical Specifications of IP DSLAM<br />
Technical Specifications of NMS / EMS<br />
IP DSLAM Equipment Characteristics<br />
Technical Specifications of ADSL Modem<br />
Technical Specifications of Router<br />
Technical Specifications of Layer – 3 Switch<br />
Technical Specifications of ADSL L<strong>in</strong>e Tester<br />
101
Section – III<br />
Chapter – 1<br />
Technical Overview<br />
102
IP-Based Digital Subscriber L<strong>in</strong>e Access Multiplexer (IP-DSLAM)<br />
1. Introduction<br />
This specification covers the requirements of IP-DSLAM Equipment to be<br />
supplied to Railways for provid<strong>in</strong>g data and voice services to their employees<br />
across Country.<br />
The IP Digital Subscriber L<strong>in</strong>e Access Multiplexer Equipment here<strong>in</strong> after<br />
referred to as “IP-DSLAM” shall comply with the technical specification set forth<br />
here<strong>in</strong> and shall comply with the latest relevant ITU-T and other recognized<br />
standards.<br />
The equipment shall be of modern design, proven capability, high-demonstrated<br />
reliability and low power consumption. All the equipment offered shall be those<br />
which adopt the latest and highest grade technique and be stable <strong>in</strong> operation for a<br />
long cont<strong>in</strong>uous period of time.<br />
The detailed <strong>in</strong>formation of the requirement is provided <strong>in</strong> this technical<br />
Requirement document.<br />
103
Section – III<br />
Chapter – 2<br />
Equipment Requirement &<br />
Configuration<br />
104
Equipment Requirement and Configuration<br />
2. Equipment Requirement and Configuration<br />
A Typical environment of the network is depicted below keep<strong>in</strong>g today’s and<br />
future growth <strong>in</strong> m<strong>in</strong>d.<br />
Proposed equipments (IP DSLAM) must support real time application like video services, video<br />
on demand, video conferenc<strong>in</strong>g, VoIP etc through guaranteed end to end QoS.<br />
2.1 Configuration of IP-DSLAM<br />
2.1.1 Type 1 Configuration: 528 ports of ADSL 2+<br />
The equipment proposed has to have m<strong>in</strong>imum 528 ports of ADSL 2+ expandable<br />
upto 640 ports, currently equipped with 528 ports <strong>in</strong> a s<strong>in</strong>gle chassis<br />
configuration. The equipment must comply to the specifications detailed <strong>in</strong> the<br />
specifications chapter.<br />
2.1.2 Type 2 Configuration: 192 ports of ADSL 2+<br />
The equipment proposed has to have m<strong>in</strong>imum 192 ports of ADSL2+ <strong>in</strong> a s<strong>in</strong>gle<br />
chassis expandable upto 256 ports <strong>in</strong> a s<strong>in</strong>gle system configuration, currently<br />
equipped with 192 ports. The equipment must comply to the specifications<br />
detailed <strong>in</strong> the specifications chapter.<br />
105
Section – III<br />
Chapter – 3<br />
Technical Specifications of<br />
IP DSLAM<br />
106
Technical Specification of IP-DSLAM<br />
3.1 DSLAM Specification<br />
IP-DSLAM with m<strong>in</strong>imum 2 slots for management and switch cards, One Alarm Panel,<br />
Two slots for DC power <strong>in</strong>put and filter (Hot-swappable), or distributed power supply,<br />
One slot for fan and dust filter module, sensors for voltage, temperature and FAN speed,<br />
thermal cutoff protection mechanism (If temperature is over the threshold), MSC with<br />
redundancy feature (failover switch time less than 1 second). Proposed IP DSLAM must<br />
have m<strong>in</strong>imum 10G backplane capacity. The DSLAM should have multiservice access<br />
capability so that any future services can be planned by Railways from time to time,<br />
without chang<strong>in</strong>g the equipment configuration. The services can be of Voice, Video or<br />
data like VoIP, IP-TV etc. The equipment proposed should be of Indoor and outdoor type<br />
as well. The equipment with smaller footpr<strong>in</strong>t and compact <strong>in</strong> size will be preferred.<br />
3.1.1 The proposed IP-DSLAM shall have the capability to provide, at least, the<br />
follow<strong>in</strong>g Subscriber <strong>in</strong>terfaces for;<br />
3.1.1.1 Pla<strong>in</strong> Old Telephone Services (POTS)<br />
3.1.1.2 ISDN BRI, ISDNoIP<br />
3.1.1.3 ADSL/ADSL2/ADSL2+: G.992.1 Annex A, G.992.3 Annex A, G.992.5<br />
Annex A<br />
3.1.1.4 SHDSL (2 wire/4 wire): G.991.2, G.991.2.bis<br />
3.1.1.5 Fast Ethernet Ports<br />
3.1.1.6 Gigabit Upl<strong>in</strong>k Ports (Optical 10Km. / Electrical)<br />
This is keep<strong>in</strong>g <strong>in</strong> m<strong>in</strong>d future technology up-gradation requirement, if required <strong>in</strong> the IP<br />
DSLAM without any additional hardware cost other then module.<br />
107
3.1.2 The proposed IP-DSLAM shall be able to adapt to the chang<strong>in</strong>g requirements of<br />
an <strong>in</strong>dividual user <strong>in</strong> term of capacity, flexibility, and types of service offered<br />
without any additional requirements or equipment.<br />
3.1.3 The proposed IP DSLAM provided with Equipment protection and<br />
redundancy feature<br />
3.1.3.1 Common control unit (Redundant 1+1)<br />
3.1.3.2 Network <strong>in</strong>terface unit (HOT Swappable)<br />
3.1.3.3 VoIP Protocol Process Unit (Redundant 1+1)<br />
3.1.3.4 Power supply unit (Redundant 1+1 or Distributed power supply)<br />
3.1.3.5 The protection cards for the above units shall be hot swappable.<br />
3.1.3.6 In case where ventilat<strong>in</strong>g system of heat of the proposed equipment is fan<br />
type, the equipment shall support redundancy system, pluggable for<br />
ma<strong>in</strong>tenance and repair with temperature control and alarm functions.<br />
3.1.4 The proposed IP-DSLAM shall support at least po<strong>in</strong>t to po<strong>in</strong>t, cha<strong>in</strong>, r<strong>in</strong>g<br />
topologies and mixed topology. In case where r<strong>in</strong>g topology is used, IP-<br />
DSLAM must have r<strong>in</strong>g protection mechanisms that can switchover. The<br />
R<strong>in</strong>g topology is used to guarantee the network be<strong>in</strong>g normal even if one<br />
l<strong>in</strong>k between two devices is broken. So, <strong>in</strong> the r<strong>in</strong>g topology, the network<br />
will work well if one l<strong>in</strong>k is broken. In the R<strong>in</strong>g Topology, DSLAM<br />
should support RSTP.<br />
3.1.5 ISDN Interface- Basic rate and Primary rate ISDN shall comply with<br />
relevant ITU-T Standard.<br />
3.1.6 The IP-DSLAM shall support at least the follow<strong>in</strong>g VoIP features:<br />
3.1.6.1 Voice Activity Detection<br />
3.1.6.2 Comfort Noise Generation<br />
3.1.6.3 Call Progress Tone Generation<br />
3.1.6.4 V.21 Fax Tone Detection<br />
3.1.6.5 V.23 FSK Caller ID Generation3.1.6.6 Bellcore FSK Caller ID<br />
3.1.6.7 DTMF Detection and Relay<br />
3.1.6.8 T.38 Fax Relay<br />
3.1.6.9 Jitter Elim<strong>in</strong>ation<br />
3.1.6.10 RTP Encapsulation<br />
3.1.6.11 Voice Codec – G.711U, G.711A, G.723, G.729<br />
3.1.6.12 H.248 and MGCP protocol<br />
3.1.6.13 ISDN over IP protocol accord<strong>in</strong>g to IUA protocol stack<br />
108
3.1.7 The proposed IP-DSLAM shall be capable of demonstrate of<br />
follow<strong>in</strong>g L2 (Bridg<strong>in</strong>g) Functionalities. It shall support follow<strong>in</strong>g<br />
protocols.<br />
3.1.7.1 LLC & VC MUX bridg<strong>in</strong>g (RFC2684) support<strong>in</strong>g bridg<strong>in</strong>g and rout<strong>in</strong>g<br />
mode (Static IP & DHCP)<br />
3.1.7.2 Max. MAC address per system: 8 K (NT’s MAC address table)<br />
3.1.7.3. Max. 128 MAC address per port support (LT bridge port limitation)<br />
3.1.7.4 802.1D transparent bridg<strong>in</strong>g<br />
3.1.7.5 802.1Q tag based VLAN<br />
3.1.7.6 802.1w rapid spann<strong>in</strong>g tree protocol for network <strong>in</strong>terface ports<br />
3.1.7.7 Auto MAC address learn<strong>in</strong>g<br />
3.1.7.8 MAC ag<strong>in</strong>g-out time<br />
3.1.7.9 SVL-like bridg<strong>in</strong>g<br />
3.1.7.10 Limit<strong>in</strong>g number of MAC per port (MAC count filter)<br />
3.1.7.11 Static MAC address filter<strong>in</strong>g (MAC address filter, both deny and accept)<br />
3.1.7.12 Static MAC-OUI filter<strong>in</strong>g (MAC OUI filter, both deny and accept)<br />
3.1.7.13 Port Isolation<br />
3.1.7.14 Port-based VLAN tagg<strong>in</strong>g on subtend<strong>in</strong>g network <strong>in</strong>terface port<br />
3.1.7.15 Broadcast storm control<br />
3.1.7.16 Protocol-based VLAN<br />
3.1.7.17 LACP<br />
3.1.8 ATM QoS allows regulat<strong>in</strong>g the average rate and fluctuations of data<br />
transmission. This helps to elim<strong>in</strong>ate congestion <strong>in</strong> order to allow<br />
transmission of real time data (such as audio and video). The proposed IP-<br />
DSLAM to be provided with QoS/ ATM Traffic Management<br />
functionalities. However these features related to ATM are desirable.<br />
3.1.8.1 4-level 802.1p priority queue to guarantee the m<strong>in</strong>imum bandwidth for<br />
each queue<br />
3.1.8.2 8 PVC per DSL port<br />
3.1.8.3 TM 4.0 peak cell rate traffic parameter<br />
3.1.8.4 Downstream traffic shap<strong>in</strong>g function per ATM PVC<br />
3.1.8.5 Support ATM F5 OAM cells for End-to-End Loop back test (ITU-T Rec.<br />
I.610)<br />
3.1.9 VLAN allows a physical network to be partitioned <strong>in</strong>to multiple logical<br />
networks. Stations on a logical network belong to one group called VLAN<br />
group. A station can belong to more than one group. The stations on the<br />
same VLAN group can communicate with each other. With VLAN, a<br />
station cannot directly talk to or hear from stations that are not <strong>in</strong> the same<br />
VLAN groups. The proposed IP-DSLAM shall support at least follow<strong>in</strong>g<br />
VLAN features.<br />
3.1.9.1 4094 IEEE 802.1Q compliant VLAN tagg<strong>in</strong>g<br />
3.1.9.2 VLAN stack<strong>in</strong>g (Q-<strong>in</strong>-Q)<br />
3.1.9.3 VLAN Bridge Function (multiple PVCs to one VLAN)(N:1)<br />
3.1.9.4 PVC and VLAN one to one mapp<strong>in</strong>g (1:1)<br />
109
3.1.9.5 VLAN Trunk<strong>in</strong>g (S<strong>in</strong>gle PVC jo<strong>in</strong> Multiple VLAN) (1: N)<br />
3.1.10 The proposed IP-DSLAM shall support at least follow<strong>in</strong>g Security<br />
3.1.10.1 Per Port (MAC address based security level to deny/ access to the Internet)<br />
and Per VLAN isolation.<br />
3.1.10.2 IEEE 802.1x port-based authentication is desired to prevent the<br />
unauthorized ports (clients) from ga<strong>in</strong><strong>in</strong>g access to the network.<br />
3.1.10.3 Rule-based packet filter<strong>in</strong>g (L2 ~ L4 ACL)<br />
3.1.10.4 DSLAM should have MAC count limit<strong>in</strong>g feature for the number of<br />
dynamic learned MAC addresses <strong>in</strong> the MAC table per port.<br />
3.1.10.5 DHCP broadcast filter<strong>in</strong>g<br />
3.1.10.6 VLAN aware DHCP snoop<strong>in</strong>g features required to adds VLAN<br />
<strong>in</strong>formation <strong>in</strong>to DHCP snoop<strong>in</strong>g table.<br />
3.1.10.7 ACL filter<strong>in</strong>g feature—Net BiOS should be supported by the DSLAM.<br />
3.1.10.8 IGMP filter<strong>in</strong>g<br />
3.1.10.9 Anti IP/MAC address spoof<strong>in</strong>g<br />
3.1.11 Follow<strong>in</strong>g Network Management method/ features should be<br />
supported by the IPDSLAM for end to end management.<br />
3.1.11.1 Local management through a craft term<strong>in</strong>al<br />
3.1.11.2 Web-based /GUI based Management Interface<br />
3.1.11.3 Cluster Management (Up to 8 cluster members) required for manag<strong>in</strong>g<br />
multiple DSLAM adm<strong>in</strong>istration with s<strong>in</strong>gle/master IP address.<br />
3.1.11.4 View-based Network Management<br />
3.1.11.5 In-band and out-of-band IP <strong>in</strong>terface for management<br />
3.1.11.6 SNMPv1/v2c agent/traps<br />
3.1.11.7 Standard MIBs report should be view for different l<strong>in</strong>e card<br />
3.1.11.7.1 2RFC 1213 MIB II<br />
3.1.11.7.2 ADSL L<strong>in</strong>e MIB (RFC2662)/Extension L<strong>in</strong>e MIB (RFC 3440)<br />
3.1.11.7.3 SHDSL L<strong>in</strong>e MIB (RFC 3276)<br />
3.1.11.7.4 VDSL l<strong>in</strong>e MIB (RF3728)<br />
3.1.11.7.5 Bridge MIB/Extension MIB<br />
3.1.11.7.6 RMON MIB (RFC 1757)<br />
3.1.11.7.7 Vendor specific MIBs, e.g.,Chassis Management MIB (Fan Speed,<br />
Voltage, Temperature) or its management through EMS<br />
3.1.12 The proposed IP-DSLAM shall have built-<strong>in</strong> Remote Subscriber L<strong>in</strong>e<br />
Test<strong>in</strong>g Function which is used to test subscriber l<strong>in</strong>es. This function shall<br />
be performed by the Network Management System/ EMS.<br />
At least the follow<strong>in</strong>g parameters for ADSL2+:<br />
3.1.12.1 Max Down speed<br />
3.1.12.2 Upstream possible on each DSL standard<br />
3.1.12.3 Copper Loop length (m)<br />
3.1.12.4 Loop Attenuation (dB)<br />
3.1.12.5 Mean noise level (dBm/Hz)<br />
110
3.1.13 Various methods/ options required <strong>in</strong> the proposed IP DSLAM for<br />
Management purpose<br />
3.1.13.1 Local console port<br />
3.1.13.2 Web-based/ GUI based configuration<br />
3.1.13.3 Telnet (share 4 Session)<br />
3.1.13.4 SNMP v1/v2 based EMS<br />
3.1.13.5 Should allow multiple adm<strong>in</strong>istrative accounts and 3 levels of access<br />
privileges (Low: read only/ Middle: read / write/ High: read / write / user<br />
management)<br />
3.1.14 The proposed IP DSLAM should have follow<strong>in</strong>g Management<br />
Function<br />
3.1.14.1 Alarm and Status Surveillance<br />
3.1.14.2 Fault management<br />
3.1.14.3 Configuration management<br />
3.1.14.4 Performance management<br />
3.1.15 Management Switch<strong>in</strong>g Card shall support the follow<strong>in</strong>g local<br />
management features<br />
3.1.15.1 General management function<br />
3.1.15.1.1 Handle def<strong>in</strong>ed alarm <strong>in</strong>put/output<br />
3.1.15.1.2 FAN module speed detection and alarm issue if necessary<br />
3.1.15.1.3 DC power <strong>in</strong>put A, B status detection and alarm issue if necessary<br />
subscriber l<strong>in</strong>e card plugg<strong>in</strong>g events detection<br />
3.1.15.1.4 Chassis type & ID detection<br />
3.1.15.2 FW features supported by the MSC <strong>in</strong> the proposed IP DSLAM<br />
3.1.15.2.1 MAC address mgmt<br />
3.1.15.2.2 CoS for backplane <strong>in</strong>terfaces and upl<strong>in</strong>k as well as subtend<strong>in</strong>g ports (SPQ<br />
& WRR support)<br />
3.1.15.2.3 IEEE 802.3x flow control<br />
3.1.15.2.4 Storm Control<br />
3.1.15.2.5 IEEEE 802.1s, IEEE 802.1d, IEEE 802.1w<br />
3.1.15.2.6 Support IEEE 802.1Q/1P<br />
3.1.15.2.7 Support untag and tag frames<br />
3.1.15.2.8 VLAN GVRP support<br />
3.1.15.2.9 IP multicast<strong>in</strong>g<br />
3.1.15.2.10 Port Trunk<strong>in</strong>g<br />
3.1.15.2.11 Port Security<br />
3.1.15.2.12 Packet Filter<strong>in</strong>g<br />
3.1.15.2.13 Traffic shap<strong>in</strong>g on subscriber port<br />
3.1.15.2.14 Redundant MSC mechanism<br />
3.1.15.2.15 LACP<br />
3.1.15.2.16 DiffServ Code Po<strong>in</strong>t (DSCP) to 802.1p priority mapp<strong>in</strong>g<br />
3.1.16 OAM&P features <strong>in</strong> the proposed IP DSLAM<br />
111
3.1.16.1 Firmware upgrade through FTP and serial console port should be<br />
supported <strong>in</strong> the IPDSLAM<br />
3.1.16.2 MAC entry displayed with VLAN ID <strong>in</strong>formation should be viewed<br />
3.1.16.3 CPU utilization status and alarm report for report generation<br />
3.1.16.4 Per-VLAN primary and secondary DHCP server sett<strong>in</strong>g<br />
3.1.16.5 Profile server<br />
3.1.16.6 Alarm severity assignment table should be viewed<br />
3.1.16.7 M<strong>in</strong>imum Profile Management required<br />
3.1.16.7.1 ADSL profile management<br />
3.1.16.7.2 ATM traffic profile management<br />
3.1.16.7.3I GMP filter<strong>in</strong>g profile management<br />
3.1.16.7.4 Alarm profile management with Threshold Cross<strong>in</strong>g Alarm management<br />
and alarm severity assignment and sett<strong>in</strong>g<br />
3.1.17 ALC/Filter<strong>in</strong>g features <strong>in</strong> the proposed IP DSLAM<br />
3.1.17.1 Frame filter<strong>in</strong>g, such as based on source MAC address, port etc.<br />
3.1.17.2 PPPoE filter<strong>in</strong>g<br />
3.1.17.3 Layer 3 filter<strong>in</strong>g based on IP header: source addresses, dest<strong>in</strong>ation<br />
addresses<br />
3.1.17.4 ARP broadcast filter<strong>in</strong>g<br />
3.1.17.5 ACL filter<strong>in</strong>g feature--NetBiOS should be supported by the DSLAM.<br />
3.1.17.6 DHCP broadcast filter<strong>in</strong>g<br />
3.1.17.7 IGMP filter<strong>in</strong>g<br />
3.1.17.8 MAC OUI Filter<strong>in</strong>g<br />
3.1.17.9 Advanced upstream ACL<br />
3.1.17.10 Rate limit<strong>in</strong>g features<br />
3.1.17.10.1 Rate limit<strong>in</strong>g per XDSL port<br />
3.1.17.10.2 Rate limit<strong>in</strong>g per XDSL VCRate limit<strong>in</strong>g per Ethernet port (MSC<br />
subtend<strong>in</strong>g port.<br />
3.1.17.10.3 Per-PVC upstream rate limit<strong>in</strong>g<br />
3.1.17.10.4 Block user’s multicast packets from subscribed user ports<br />
3.1.18 Multicast<strong>in</strong>g features <strong>in</strong> the proposed IP DSLAM<br />
3.1.18.1 IP multicast forward<strong>in</strong>g<br />
3.1.18.2 IGMPv1/v2 Proxy/snoop<strong>in</strong>g<br />
3.1.18.3 IGMP filter<strong>in</strong>g profile<br />
3.1.18.4 IGMP multicast channel limit<strong>in</strong>g (by count and bandwidth usage)<br />
3.1.18.5 Static multicast forward<strong>in</strong>g, All video group address are configured <strong>in</strong> the<br />
box.<br />
3.1.18.6 Number of zap / second per system > 30 zaps/s<br />
3.1.18.7 Expedite Leave (channel zapp<strong>in</strong>g time less than 250ms-target)<br />
3.1.18.8 At least 256 multicast group<br />
3.1.18.9 Multicast membership reports<br />
3.1.18.10 Discard unknown multicast traffic<br />
3.1.18.11 Track<strong>in</strong>g MAC address with IGMP<br />
3.1.18.12 Multicast VLAN (16 VLANs)<br />
3.1.18.13 Static Multicast Bandwidth Control<br />
112
3.1.18.14 Multicast VLAN<br />
3.1.19 Environmental Specifications<br />
3.1.19.1 Operat<strong>in</strong>g Temp 0 deg C to 50 deg C<br />
3.1.19.2 Storage Temp -40 deg C to 70 deg C<br />
3.1.19.3 Operat<strong>in</strong>g Humility 10 ~ 90% (non-condens<strong>in</strong>g)<br />
3.1.19.4 Storage Humility 10 ~ 95% (non-condens<strong>in</strong>g)<br />
3.1.19.5 Power Supply: -48V DC<br />
3.1.20 Certification<br />
3.1.20.1 K.20<br />
3.1.20.2 Safety Certificate<br />
3.1.20.2.1 EN60950-1<br />
3.1.20.2.2 CSA60950-1<br />
3.1.20.2.3 UL60950-1<br />
3.1.20.2.4 IEC60950-1<br />
3.1.20.3 EMC<br />
3.1.20.3.1 FCC Part 15 Class A<br />
3.1.20.3.2 EN55022 Class A<br />
3.1.20.3.3 EN55024 Class A<br />
3.1.20.3.4 ETSI 300 386<br />
3.2 Management / LINE CARD SPECIFICATIONS<br />
The proposed IP DSLAM should support different l<strong>in</strong>e card (ADSL2+,<br />
G.SHDSL, G.SHDSL.bis. VDSL, VOIP). Current requirement is for<br />
ADSL 2+ l<strong>in</strong>e card. Below are the specifications that the proposed IP<br />
DSLAM should support<br />
3.2.1 Hot swappable Management Switch Cards (MSC)/Failover-enabled<br />
Network Term<strong>in</strong>ation Card..<br />
DESCRIPTION:<br />
Fully Gigabit non-block<strong>in</strong>g backplane design for each slot, at least one<br />
Gigabit to each traffic slot. to solve traffic congestion problem, Supported<br />
by total four gigabit upl<strong>in</strong>k and subtend<strong>in</strong>g with port trunk<strong>in</strong>g features for<br />
friendly deployment <strong>in</strong> r<strong>in</strong>g or tree topology and Fully VLAN functions to<br />
segment the class of service, easy to manage with web, CLI, SNMP, and<br />
EMS, Hot swappable fan module with filter, two power modules for<br />
redundancy,<br />
3.2.2 Standard compliant<br />
3.2.2.1 IEEE 802.1p, 802.1Q<br />
3.2.2.2 IEEE 802.3u/3z/3x/3ab<br />
3.2.2.3 SFF committee INF-8074i Specification<br />
3.2.2.4 SFP (Small Form factor Pluggable) transceiver rev.1.0<br />
3.2.3 Switch Fabric<br />
3.2.3.1 Switch<strong>in</strong>g fabric capability: 20Gbps, non-block<strong>in</strong>g full duplex<br />
3.2.3.2 Support 8K MAC entries<br />
3.2.3.3 Support 4K VLAN entries<br />
113
3.2.3.4 Forward<strong>in</strong>g frame: 802.3, 802.1Q, Ethernet II frames<br />
3.2.3.5 PreveMSC forward<strong>in</strong>g of corrupted packet<br />
3.2.3.6 Perate at L2 switch mode<br />
3.2.4 Network Management<br />
3.2.4.1 One RS-232 (DB-9 type) for serial console<br />
3.2.4.2 One 100Mbps Fast Ethernet for out-band management<br />
3.2.4.3 In-band management<br />
3.2.4.4 EMS support<strong>in</strong>g<br />
3.2.5. Features Specification<br />
3.2.5.1 MAC Address Management<br />
3.2.5.2 Class of Service (CoS)<br />
3.2.5.3 802.3x flow control<br />
3.2.5.4 Packet Rate (Storm) Control<br />
3.2.5.5 IEEE802.1D - Spann<strong>in</strong>g Tree Protocol Support<br />
3.2.5.6 IEEE802.1Q Support<br />
3.2.5.7 IP Multicast<strong>in</strong>g<br />
3.2.5.8 Supported by Port Trunk<strong>in</strong>g<br />
3.2.5.9 Packet Filter<strong>in</strong>g<br />
3.2.5.10 Redundancy protection mechanism<br />
3.2.5.11 Configurable upl<strong>in</strong>k and subtend<strong>in</strong>g modes<br />
3.2.6 Hot swappable ADSL2/ ADSL2+ l<strong>in</strong>e card feature<br />
3.2.6.1 Maximum transmission rate up to 25 Mbps/ 1.2 Mbps for ADSL2+ for<br />
Video, Data, and Voice triple-play applications<br />
3.2.6.2 One gigabit backplane<br />
3.2.6.3 Support G.992.3 and G.992.5 Spectral Mask<br />
3.2.6.4 Support EOC and Overhead Channel Access def<strong>in</strong>ed <strong>in</strong> G.992.3 and<br />
Rec.G.997.1<br />
3.2.6.5 Support the latency path function specified <strong>in</strong> G.992.3 and G.992.5<br />
3.2.6.6 Support Annex L and Annex M specified <strong>in</strong> G.992.3 and G.992.5<br />
3.2.6.7 Support loop diagnostic function specified <strong>in</strong> G.992.3 and G.992.5<br />
3.2.6.8 Support the power management capability specified <strong>in</strong> G.992.3 and<br />
G.992.5<br />
3.2.6.9 Support the capability of the Seamless Rate Adaptation (SRA) on-l<strong>in</strong>e<br />
configuration specified <strong>in</strong> G.992.3 and G.992.5<br />
3.2.6.10 Support ATM Qos (UBR/VBR/CBR) is desirable.<br />
3.2.6.11 Manage with web, CLI, SNMP, and EMS<br />
3.2.6.12 Follow<strong>in</strong>g Network Management features required<br />
3.2.6.12.1 Alarm/Status Surveillance<br />
3.2.6.12.2. Automatic alarm and status report<br />
3.2.6.12.3 LED <strong>in</strong>dication for alarm and system status<br />
3.2.6.12.4 Performance monitor<strong>in</strong>g<br />
3.2.6.12.5 Periodical DSL performance counter update<br />
114
3.2.6.12.6 PVC-to-VLAN mapp<strong>in</strong>g<br />
3.2.6.12.7 ADSL l<strong>in</strong>e rate sett<strong>in</strong>g<br />
3.2.6.12.8 Per-channel QoS<br />
3.2.6.12.9 Security and Memory Backup<br />
3.2.6.12.10 Port isolation(port security)<br />
3.2.6.12.11 Provides non-volatile memory to back-up system database<br />
3.2.6.12.12 Keep previous system parameters dur<strong>in</strong>g re-boot<strong>in</strong>g Self diagnostics.<br />
3.2.6.13 Features Specification<br />
3.2.6.13.1 DELT (dual ended loop test) functionality accord<strong>in</strong>g to ITU-T ADSL2+<br />
3.2.6.13.2 Fast Start up<br />
3.2.6.13.3 Power enhancement<br />
3.2.6.13.4 Rate adaptation<br />
3.2.6.13.5 MAC and packet filter<strong>in</strong>g<br />
3.2.6.13.6 DSLAM should support MAC count limit<strong>in</strong>g features. It helps the limit<br />
the number of dynamic learned MAC addresses <strong>in</strong> the MAC table per port<br />
3.2.6.13.7 Broadcast storm filter<strong>in</strong>g<br />
3.2.6.13.8 Hardware-based mutli-cast<strong>in</strong>g<br />
3.2.6.13.9 IGMP snoop<strong>in</strong>g features (With IGMP snoop<strong>in</strong>g, multicast traffic of a<br />
group is only forwarded to the ports that are members of that group)<br />
3.2.6.13.10 DHCP relay option82 required to limit the number of IP addresses or<br />
deliver some specific IP addresses accord<strong>in</strong>g to certa<strong>in</strong> DSL port, VLAN<br />
ID and option 82 str<strong>in</strong>gs.<br />
3.2.6.13.11 IEEE 802.1x port-based authentication is desired to prevent the<br />
unauthorized ports (clients) from ga<strong>in</strong><strong>in</strong>g access to the network.<br />
3.2.7 Hot swappable SHDSL/SHDSL.bis l<strong>in</strong>e card<br />
3.2.7.1 Symmetric transmission rate of 2.048 Mbps (2-wire), and 4.096 Mbps (4-<br />
wire)<br />
3.2.7.2 Support ETSI TS 101 524 V 1.2.1, ITU-T G.991.2, ITU-T G.991.2.bis<br />
3.2.7.3 One gigabit backplane<br />
3.2.8 Hot swappable 24-port VDSL2 DMT-based l<strong>in</strong>e card<br />
3.2.8.1 Support G.993.2, G.994.1, G.997.1<br />
3.2.8.2 Maximum transmission rate up to 100 Mbps/ 45 Mbps, and average 40/40<br />
Mbps<br />
3.2.8.3 One gigabit backplane<br />
3.2.8.4 Support VDSL2 profiles 8a, 8b, 8c, 8d, 12a<br />
3.2.8.5 Support frequency allocation band plan Annex A, Annex B 998.A, 998.B,<br />
998.M<br />
3.2.8.6 Support U0 band, customer PSD, RFI notch, s<strong>in</strong>gle latency <strong>in</strong> PTM mode<br />
(64/65 encapsulation) and INP<br />
3.2.8.7 Support UPBO, Reed Solomon and Trellis cod<strong>in</strong>g<br />
115
116
Section – III<br />
Chapter – 4<br />
Technical Specifications of<br />
NMS / EMS<br />
117
Specifications for Network / Element Management System<br />
A fully functional NMS/EMS along with all necessary hardware and software and<br />
complete FCAPS (Fault, configuration, account<strong>in</strong>g, performance and security)<br />
functionality should be provided to manage various components of the network - Viz IP<br />
DSLAM etc.<br />
The NMS/EMS should be capable of provid<strong>in</strong>g Fault management, Alarm<br />
management, Configuration Management, performance management and Security<br />
Management of all devices <strong>in</strong> the network. GUI based Configuration, Monitor<strong>in</strong>g and<br />
management should be facilitated by the NMS/EMS.<br />
4.1 Fault Management<br />
This will broadly cover Alarms, Fault localization, Diagnostics and test<strong>in</strong>g and<br />
trouble ticket adm<strong>in</strong>istration.<br />
4.1.1 It should be able to def<strong>in</strong>e whether an alarm is of critical, urgent, non-urgent<br />
nature, and setup a fully fledged Alarm Policy.<br />
4.1.2 A summary of all alarms should be presented <strong>in</strong> real time and on demand or to the<br />
user or to a remote NMS/EMS monitor<strong>in</strong>g po<strong>in</strong>t.<br />
4.1.3 It should give a visual as well as audible <strong>in</strong>dication of an alarm depend<strong>in</strong>g on its<br />
severity level.<br />
4.1.4 All the Alarm related <strong>in</strong>formation, such as start of alarm, end of alarm,<br />
acknowledge time should be able to be logged to a write protected file.<br />
4.1.5 Alarm escalation procedures should be possible to be def<strong>in</strong>ed, depend<strong>in</strong>g on<br />
severity, time elapsed, location, service affected, vendor, customer and<br />
technology. It should have a capability to escalate the alarms to higher authorities<br />
via SMS, emails etc if required <strong>in</strong> future.<br />
4.1.6 It should be able to run diagnostic rout<strong>in</strong>es and to locate the fault up-to a part of<br />
the network. It should have capabilities to identify faults up-to the module / port<br />
level.<br />
4.1.7 It should be possible to run automatic or manual tests based on certa<strong>in</strong> policies<br />
and authorizations. When a test is be<strong>in</strong>g run, the network component should be<br />
locked for any operation from the local craft term<strong>in</strong>al. However it should be<br />
possible to configure whether or not a local craft term<strong>in</strong>al can get precedence over<br />
the NMS/EMS.<br />
118
4.1.8 Alarm monitor<strong>in</strong>g can be customized and saved for future usage.<br />
4.1.9 Alarm localizer should be supplied so that a xxx hav<strong>in</strong>g fault can be localized<br />
easily from a list of current alarms.<br />
4.2.0 Alarm security can be def<strong>in</strong>ed by users / Adm<strong>in</strong>istrator.<br />
4.2.1 System should allow user to build up there knowlage base for alarm trouble<br />
shoot<strong>in</strong>g shar<strong>in</strong>g.<br />
4.2 Configuration Management:<br />
This function broadly covers Provision<strong>in</strong>g, Control, Network Database<br />
preparation and ma<strong>in</strong>tenance.<br />
4.2.1 It should be capable of provision<strong>in</strong>g and management of the VoIP<br />
4.2.2 It should be possible to activate, change or de-activate services or features upon<br />
request from user.<br />
4.2.3 It should be able to configure a new network element hardware, and software with<br />
correspond<strong>in</strong>g database entries.<br />
4.2.4 It should be able to add, modify or delete the network elements, such as entities<br />
like l<strong>in</strong>ks, routes, rates, trunk groups, codec and analysis.<br />
4.2.5 Provision<strong>in</strong>g of SS7 l<strong>in</strong>ks, PRI l<strong>in</strong>ks etc should be possible locally as well as<br />
Premotely. Similarly configur<strong>in</strong>g OPC (orig<strong>in</strong>ation Po<strong>in</strong>t Code), DPC (dest<strong>in</strong>ation<br />
Po<strong>in</strong>t Code), Protocols should be possible.<br />
4.2.6 It should be possible to access the status of a NE (Network Element), receive and<br />
process requests for chang<strong>in</strong>g the status of the network and its components.<br />
4.2.7 It should be able for the NE to <strong>in</strong>itiate automatic notification of change of state<br />
such as change from ‘enable’ to ‘disable’ <strong>in</strong> case of failure.<br />
4.2.8 It should be able to download software and patches to the NE, test the workability<br />
and revert to orig<strong>in</strong>al configuration <strong>in</strong> case of problems.<br />
4.2.9 A s<strong>in</strong>gle GUI should be available for configuration management across all the<br />
devices <strong>in</strong> the network<br />
4.2.10 A database of records of modifications carried out <strong>in</strong> the network should be<br />
ma<strong>in</strong>ta<strong>in</strong>ed, and the size of this database should be configurable.<br />
4.2.11 The NMS/EMS should have the ability to auto-discover the network elements and<br />
the l<strong>in</strong>ks to <strong>in</strong>clude them <strong>in</strong> the visual / graphical map on the GUI.<br />
119
4.2.12 The NMS/EMS shall be able to generate reports based on changes made <strong>in</strong> the<br />
network <strong>in</strong>ventory.<br />
4.2.13 It can be grouped together <strong>in</strong> any N- tier based network doma<strong>in</strong>, geographic<br />
location etc.<br />
4.3 Account<strong>in</strong>g Management:<br />
This function broadly covers measurement of usage of network resources and<br />
computation of costs for the same. It also helps determ<strong>in</strong><strong>in</strong>g uptimes, down-times<br />
and SLA service credits etc.<br />
4.4 Performance Management:<br />
This module gives the ability to detect and correct very low rate or <strong>in</strong>termittent<br />
error conditions, which cannot be detected by the Alarm management module.<br />
4.4.1 Under this module it should be able to set values and thresholds above or below<br />
which certa<strong>in</strong> measurements on a long term basis are to be carried out.<br />
4.4.2 The NMS/EMS should provide history based traffic forecast<strong>in</strong>g.<br />
4.4.3 It should be possible to capture <strong>in</strong>formation such as latency, packet loss, jitter,<br />
l<strong>in</strong>k utilization etc. Based on these SLA reports, Service reports and service<br />
quality reports can be generated.<br />
4.4.4 It should be possible to monitor traffic on real time basis.<br />
4.4.5 The system should support automatic PM query on predef<strong>in</strong>ed time <strong>in</strong>tervals.<br />
4.4.6 The system should support both textual & graphical view of PM results.<br />
4.4.7 The system should support manual on demand PM survey and an immediate of<br />
PM results.<br />
4.5 Security Management:<br />
This broadly covers aspects related to <strong>in</strong>trusion detection, conta<strong>in</strong>ment, and<br />
recovery and security adm<strong>in</strong>istration.<br />
4.5.1 It should be able to detect any <strong>in</strong>cidents of security violations, such as alarms for<br />
door open<strong>in</strong>g unauthorized access <strong>in</strong>to network, physical tamper<strong>in</strong>g of equipment<br />
etc.<br />
4.5.2 It should detect significant shift <strong>in</strong> revenue <strong>in</strong>dicat<strong>in</strong>g frauds or thefts.<br />
4.5.3 It should support actions to limit the damage caused by the security <strong>in</strong>trusion,<br />
such as isolation of equipment, removal of user access permissions etc.<br />
120
4.5.4 Solution should provide Encryption (TLS or IP Sec for Signall<strong>in</strong>g and<br />
IPSec/SRTP for media)<br />
4.5.5 The system should provide user functional access control.<br />
4.5.6 The system can control a user’s session time out; control a user’s passwords valid<br />
Period, control no odd session that the user is allowed to have.<br />
4.6 The Network Management System should be capable of manag<strong>in</strong>g all network<br />
elements<br />
4.7 All <strong>in</strong>formation from each Network element should be presented to the user for<br />
tak<strong>in</strong>g appropriate actions to assess overall network performance.<br />
4.8 Expansions and re-configuration of all network elements should be possible from<br />
the NMS/EMS.<br />
4.9 System shall be capable of captur<strong>in</strong>g the <strong>in</strong>formation like Latency, packet loss,<br />
jitter, l<strong>in</strong>k utilization, etc. us<strong>in</strong>g SNMP protocol. Based on these parameters<br />
NMS/EMS system should able to generate customized reports for each customers<br />
and network elements.<br />
4.10 NMS/EMS shall be able to provide SLA report, service report, and carrier wise<br />
service quality report. System should support SNMP for collect<strong>in</strong>g the element<br />
parameters. System should be hav<strong>in</strong>g <strong>in</strong>tegration capability with third party NMS<br />
system.<br />
4.11 Remote real time monitor<strong>in</strong>g capabilities: System should able to generate the real<br />
time monitor<strong>in</strong>g events and alarms. All events should be displayed on s<strong>in</strong>gle<br />
w<strong>in</strong>dow. Details reports should be stored <strong>in</strong> system for troubleshoot<strong>in</strong>g and<br />
analysis.<br />
4.12 The NMS/EMS shall have XML North Bound Interfaces to get <strong>in</strong>tegrated with the<br />
exist<strong>in</strong>g or proposed CNMS system of Railtel.<br />
4.13 All MIBs should be provided for <strong>in</strong>tegration with third party NMS system.<br />
4.14 NMS/EMS system should have 99.999% uptime.<br />
4.15 Solution should provide Integrated Management (Provision<strong>in</strong>g Alarms)<br />
4.16 Solution should provide Integrated debugg<strong>in</strong>g (Call Trace and Tools)<br />
4.17 Solution should provide Integrated Configuration of Policies (Rout<strong>in</strong>g, QoS, SLA<br />
etc)<br />
121
4.18 Solution should provide a s<strong>in</strong>gle end to end Call Detail Record.<br />
4.19 Solution should provide Topology hid<strong>in</strong>g<br />
4.20 Solution should provide DoS Protection<br />
4.21 Solution should provide Bandwidth theft protection<br />
4.22 Solution should provide Reports, Statistics and alarms for IP <strong>in</strong>terfaces and IP<br />
remote po<strong>in</strong>ts.<br />
4.23 System Management:<br />
4.23.1 Solution should provide <strong>in</strong>tegrated test capability that can do related data and<br />
voice test.<br />
4.23.2 The EMS / NMS system should have capability to support several non- current<br />
EMS / NMS users.<br />
4.23.3 The EMS / NMS system should have the capability to support different broadband<br />
technology products like DSLAM, PON etc.<br />
4.23.4 The solution should support its own system monitor<strong>in</strong>g capability.<br />
122
Section – III<br />
Chapter – 5<br />
IP DSLAM Equipment<br />
Characteristics<br />
123
Equipment Characteristics<br />
5.1 EQUIPMENT INTERFACE AND PROTECTION<br />
5.1.1 The proposed IP-DSLAM shall be a self-conta<strong>in</strong>ed unit, with suitable enclosure<br />
for Subscriber premises equipments.<br />
5.1.2 The system shall be flexible to provide any type of services required by<br />
subscribers. The System shall also be able to adapt to the chang<strong>in</strong>g needs of a<br />
subscriber, without affect<strong>in</strong>g other subscribers.<br />
5.1.3 Customers locations might be <strong>in</strong>stalled at variable distances, the Bidder shall,<br />
therefore, determ<strong>in</strong>e the distances supported by the different product types<br />
proposed by the Bidder.<br />
5.1.4 The equipment shall be <strong>in</strong>stalled <strong>in</strong> Outdoor Cab<strong>in</strong>et (Rack) and/or Indoor<br />
Cab<strong>in</strong>et (Rack) without air conditioner. Batteries, rectifier, r<strong>in</strong>ger generator,<br />
arrestor (for outdoor type) and all required ancillaries shall be conta<strong>in</strong>ed <strong>in</strong> the<br />
cab<strong>in</strong>et (rack).<br />
5.1.5 The proposed DSLAM to be used <strong>in</strong> the outdoor cab<strong>in</strong>et as a term<strong>in</strong>al for copper<br />
cable connected to service the customer shall be complied with Railway’s<br />
specification. The number of DSLAM requirement is specified <strong>in</strong> Technical<br />
Requirement.<br />
5.1.6 In case where the electrical power is cut off caus<strong>in</strong>g the IP-DSLAM to shut down,<br />
the IP-DSLAM must have the capability to automatically cont<strong>in</strong>ue function<strong>in</strong>g<br />
without additional set up or reconfiguration.<br />
5.2. EQUIPMENT CHARATERISTICS<br />
5.2.1 Environmental Specifications<br />
5.2.1.1 For Type A IP DSLAM<br />
Operat<strong>in</strong>g Temp 0 deg C to 50 deg C<br />
Storage Temp -40 deg C to 70 deg C<br />
Operat<strong>in</strong>g Humility 10 ~ 90% (non-condens<strong>in</strong>g)<br />
Storage Humility 10 ~ 95% (non-condens<strong>in</strong>g)<br />
Power Supply: -48V DC<br />
5.2.1.2 For Type B IP DSLAM<br />
Operat<strong>in</strong>g temperature: 0°C ~ 50°C<br />
Storage temperature: -40°C ~ 85°C<br />
Humidity: 5 ~ 95% (non-condens<strong>in</strong>g)<br />
Power Supply: -48V DC<br />
5.2.1.3 ADSL <strong>in</strong>terface shall conform to ITU-T standard.<br />
124
5.2.1.4 The IP-DSLAM must have <strong>in</strong>ternal oscillator or free runn<strong>in</strong>g for synchronization<br />
purpose.<br />
5.2.1.5 The proposed IP-DSLAM shall support alarm <strong>in</strong>dicators. Diagnostics function<br />
with the capability to identify failure shall also be supported.<br />
5.2.2 MECHANICAL REQUIREMENT<br />
Indoor type<br />
All equipment units shall be “plug-<strong>in</strong>” types and capable of be<strong>in</strong>g secured <strong>in</strong> order<br />
to prevent accidental removal. No de-solder<strong>in</strong>g is required for removal of a<br />
module or unit.<br />
a) The equipment shall be configured as 19” or ETSI standard rack type with small<br />
compact footpr<strong>in</strong>t.<br />
b) Where a rack, sub-rack, or assembly is only partially equipped, the unequipped<br />
portions shall be fitted with dust covers or dummy panels to present a pleas<strong>in</strong>g<br />
appearance.<br />
c) The Cab<strong>in</strong>et has to be Custom Design to provide Hous<strong>in</strong>g Solution for IP<br />
DSLAM Systems.<br />
d) The Cab<strong>in</strong>et should feature Enhanced cool<strong>in</strong>g system & Superior heat dissipation<br />
so as to accommodate higher l<strong>in</strong>e density & traffic rate application & also to<br />
improve the battery life.<br />
e) The cab<strong>in</strong>et should have rugged construction, Side Splic<strong>in</strong>g.<br />
f) The racks should have sealed Design & to have a life Span of M<strong>in</strong>imum 15<br />
Years.<br />
5.3 OVERVOLTAGE PROTECTION<br />
Over voltage Protection shall comply with Railway’s specification. It shall cover<br />
all protections for damages which may be occurred <strong>in</strong> l<strong>in</strong>e <strong>in</strong>terface circuit and<br />
other equipment due to over voltage and over current which may be caused by<br />
direct lightn<strong>in</strong>g strikes, <strong>in</strong>duction from currents <strong>in</strong> power l<strong>in</strong>es <strong>in</strong>clud<strong>in</strong>g electric<br />
traction systems, contacts with power l<strong>in</strong>es and rise of earth potential.<br />
5.3.1 Protection devices shall be provided for all term<strong>in</strong>als connected to all outside<br />
plant cables <strong>in</strong>clud<strong>in</strong>g subscriber l<strong>in</strong>es <strong>in</strong> order to enable the equipment to<br />
withstand such conditions, without damage or excessive protector ma<strong>in</strong>tenance.<br />
5.3.2 Detailed characteristics and descriptions of all the proposed protection devices<br />
shall be <strong>in</strong>cluded <strong>in</strong> the proposal.<br />
5.4. POWER SUPPLY<br />
The power supply shall be either –48 Volts DC +20% to -10% or 220 ±10% Volts<br />
AC, 50 ± 10% Hz. without voltage adapter.<br />
125
Section – III<br />
Chapter – 6<br />
Technical Specifications of<br />
ADSL Modem<br />
126
Technical Specifications of ADSL Modem<br />
6.1 ADSL Modem should be a 4-Port Ethernet ADSL2/2+ and WiFi Router which<br />
comb<strong>in</strong>es an “Always-On ”high speed Asymmetric Digital Subscriber L<strong>in</strong>e<br />
(ADSL) connection to the Telephone L<strong>in</strong>e, and one 10/100BASE-T Ethernet port<br />
connection to a host PC or other Ethernet device to enable the widest array of host<br />
connectivity.<br />
6.2 It should be fully compliant with ADSL, ADSL2, ADSL 2+ and RE-DSL2<br />
specifications. It should support ADSL downstream and upstream data rates up to<br />
24 Mbps and 1 Mbps.<br />
6.3 It should be Compliant to ANSI T1.413 i2, G.992.1, G.992.2, G.992.3, G.992.5<br />
and READSL2 ADSL standards. It should also comply with follow<strong>in</strong>g<br />
20 Mbps 1 Km<br />
10 Mbps 2 Km<br />
2 Mbps 4 Km<br />
1 Mbps 5 Km<br />
6.4 It should have built-<strong>in</strong> Quick set up wizard.<br />
6.5 It should be fully compliant with Annex A/B/B(U-R2) ADSL2/2+ specifications.<br />
6.6 It should support all digital loop ADSL.<br />
6.7 It should support IP / Bridge Filter<strong>in</strong>g functionality.<br />
6.8 It should support IP QoS features.<br />
6.9 It should support RFC 1483 Bridge / Rout<strong>in</strong>g over ATM over ADSL.<br />
6.10 It should support PPPoE and PPPoA Rout<strong>in</strong>g ATM over ADSL.<br />
6.11 It should support ATM Layer with Traffic Shap<strong>in</strong>g QoS.<br />
6.12 It should support up to 8PVCs.<br />
6.13 It should have Hardware Reset button for fast default sett<strong>in</strong>g recovery.<br />
6.14 It should have HTTP Web-based Management/Configuration.<br />
6.15 It should have LED <strong>in</strong>dicator <strong>in</strong>dicat<strong>in</strong>g connection status..<br />
127
6.16 It should support follow<strong>in</strong>g ADSL features<br />
6.17.1 Hardware ATM AAL0, AAL5 and OAM.<br />
6.17.2 Software ATM AAL1 and AAL3/4..<br />
6.17.3 ATM UBR, CBR, VBR-rt and VBR-nt Traffic Shap<strong>in</strong>g QoS.<br />
6.18 It should support follow<strong>in</strong>g Bridg<strong>in</strong>g / Rout<strong>in</strong>g features<br />
6.18.1 RFC 2684/1483 Routed/Bridged.<br />
6.18.2 RFC 2364 PPPoA.<br />
6.18.3 RFC 2516 PPPoE.<br />
6.18.4 Transparent Bridg<strong>in</strong>g ( IEEE 802.1D ).<br />
6.18.5 Dynamic and Static Rout<strong>in</strong>g.<br />
6.18.6 DHCP Server, Relay and Client.<br />
6.18.7 NAT with extensive ALG support.<br />
6.18.8 DNS Proxy.<br />
6.18.9 DDNS feature.<br />
6.18.10 IGMP Proxy.<br />
6.18.11 RIP v1 & v2.<br />
6.18.12 Port Mapp<strong>in</strong>g and Port Forward<strong>in</strong>g features.<br />
6.18.13 DMZ functionality.<br />
6.18.14 VPN Pass-Through.<br />
6.18.15 PAP and CHAP PPP Authentication<br />
6.19 It should support follow<strong>in</strong>g Security features:-<br />
6.19.1 Embedded Firewall feature.<br />
6.19.2 IP Filter<strong>in</strong>g features.<br />
6.19.3 Bridge/MAC Filter<strong>in</strong>g.<br />
6.20 It should support follow<strong>in</strong>g Management features:-<br />
6.20.1 Web-based Configuration/Management.<br />
128
6.20.2 AutoPVC.<br />
6.20.3 Firmware upgrade via HTTP/TFTP/FTP.<br />
6.20.4 Built-<strong>in</strong> diagnostic function.<br />
6.20.5 System Log.<br />
6.20.6 SNMP Management.<br />
6.20.7 TR-064 feature<br />
6.20.8 TR-069 feature<br />
6.21 Hardware Interfaces<br />
6.21.1 One RJ-11 ADSL connector.<br />
6.21.2 One RJ-45 LAN Connector.<br />
6.21.3 One Reset Button for factory default sett<strong>in</strong>g recovery.<br />
6.21.4 One Power adaptor connector<br />
6.21.5 LED Indicators <strong>in</strong>dicates connection status<br />
6.21.6 UPnP IGD 1.0 support<br />
6.21.7 Software upgradable IPV 6 enable / disable through GUI<br />
6.21.8 Local automotive GUI activation<br />
6.21.9 QOS features<br />
IEEE 802.1 P Bit mark<strong>in</strong>g based upon services<br />
6.21.10 WiFi Specifications<br />
6.21.10.1 64 / 128 bit Wired Equivalent Privacy ( WEP)<br />
6.21.10.2 WiFi Protected Access (WPA) system<br />
6.21.10.3 Wireless standards and features 802.11 b / g<br />
6.21.10.4 MPC association control<br />
6.22.10.5 Additional Security Features<br />
1. POD Parental Control<br />
2. Fillter<strong>in</strong>g on application basis ( easy MSN messenger / Yahoo etc)<br />
129
3. Stateful Packet Inspection<br />
4. DOS Denial of Services<br />
130
Section – III<br />
Chapter – 7<br />
Technical Specifications of<br />
Router<br />
131
Technical Specification of Router<br />
7.1 SPECIFICATION<br />
The router should have 512 k Boot ROM, 8 MB Flash memory and 64 M of<br />
SDRAM or required memory to support follow<strong>in</strong>g features<br />
7.1.1 The router should have 60 Kbps Forward<strong>in</strong>g Rate.<br />
7.1.2 The router should have at least two 10/100 M Ethernet and two channelised E1<br />
ports.<br />
7.1.3 The router should have Maximum Power consumption 50 W.<br />
7.1.4 Should work on either 230 V AC or -48 V DC Power Supply<br />
7.2 PROTOCOLS<br />
The router should support the follow<strong>in</strong>g Protocols: -<br />
7.2.1 Data L<strong>in</strong>k Layer: -<br />
The router should support 802.1Q, FR, LAPB, PPP, Multil<strong>in</strong>k PPP, PPP, HDLC,<br />
, VLAN Data L<strong>in</strong>k Layer protocols.<br />
7.2.2 Network Layer: -<br />
The router should support ARP/Proxy ARP, DNS/DNS Proxy, NAT, ICMP,<br />
IGMP, DHCP, Server/Client/Relay), IP Multicast & PIM-DM/SM Network Layer<br />
protocols.<br />
7.2.3 Rout<strong>in</strong>g: -<br />
The router should provide Static, RIP, OSPF, , BGP-4, rout<strong>in</strong>gs protocols.<br />
7.2.4 Reliability: -<br />
The router should support Port Backup, HSRP, VRRP reliability protocols.<br />
7.3 SECURITY<br />
The router should provide TACACS+/ Radius, AAA, , Firewall, L2TP, PPTP,<br />
GRE, IPSec, IKE and 500 VPN Tunnel security features.<br />
7.4 QoS<br />
The router should support FIFO, PQ, CQ, CBWFQ, WFQ, RED, WRED, DSCP,<br />
IP Precedence, RTS, RSVP & CAR QoS features.<br />
7.5 MANAGEMENT<br />
The router should be managed through Console, AUX, Web, Telnet, TFTP,<br />
SNMP V1/2/3, MIB, NTP, RMON 1.2.3.9<br />
7.6 INTERFACE<br />
132
The router should have at least two 10/100 M Ethernet and two channelised E 1<br />
ports.<br />
7.7 POWER SUPPLY<br />
The router should work on either 230 V AC or -48 V DC power supply.<br />
133
Section – III<br />
Chapter – 8<br />
Technical Specifications of<br />
Layer – 3 Switch<br />
134
Technical Specification of Layer-3 Switch<br />
8.1 General Specification: -<br />
8.1.1 The L3 switch should support 12.8 Gbps switch<strong>in</strong>g fabric.<br />
8.1.2 The L3 switch should have at least 8 MB Flash memory and 64 M of SDRAM.<br />
8.1.3 The L3 switch should have m<strong>in</strong>imum 24 100Base-TX and two 1000Base-TX/FX<br />
ports.<br />
8.1.4 The L3 switch should support 8 K MAC address.<br />
8.1.5 The L3 switch should have Maximum Power consumption 40 W.<br />
8.1.6 The L3 switch work on either 230 V AC or -48 V DC Power Supply.<br />
8.1.7 The L3 switch should have power redundancy.<br />
a. The L3 switch should have stackable.<br />
8.2 Rout<strong>in</strong>g Protocol: -<br />
The L3 switch should support RIP-I & II, OSPF, BGP, IGMP Snoop<strong>in</strong>g, IGMP<br />
v1/v2/v3, PIM-DM/PIM-SM, GMRP, DVMRP, rout<strong>in</strong>gs protocols.<br />
8.3 Availability: -<br />
The L3 switch should support 802.1D STP, 802.1w RSTP, 802.1s MSTP, VRRP,<br />
802.3ad L<strong>in</strong>k (LACP), Aggregation, Load balance, ARP Proxy availability<br />
features.<br />
8.4 VLAN: -<br />
The L3 switch should support Port-based VLAN, 802.1Q VLAN, GVRP, and 8k<br />
No. of VLAN.<br />
8.5 Security: -<br />
The L3 switch should support 802.1x, Web authentication, Syslog, Port Security,<br />
SSH v1/v2, TACACS+ and Radius security features.<br />
8.6 QoS: -<br />
The L3 switch should support 802.1p, Broadcast storm control, Multicast Storm<br />
control, ToS, COS and DiffServ (DSCP) QoS features.<br />
8.7 Management: -<br />
135
The L3 switch should be managed through Console, Web, Telnet CLI, DHCP<br />
Server, DHCP Relay, DHCP Client, TFTP, SNMP, MIB, NTP, RMON 1.2.3.9,<br />
and Port Mirror<strong>in</strong>g.<br />
8.8 Access Control List: -<br />
The L3 switch should have Access Control List based on <strong>in</strong>gress, egress, MAC<br />
address, VLAN, IP address, protocol type, TCP/UDP port, Time and DSCP.<br />
8.9 Interfaces: -<br />
The L3 switch should have m<strong>in</strong>imum 24 100Base-TX and two 1000Base-TX/FX<br />
ports<br />
8.10 Power Supply: -<br />
The L3 Switch should work on either 230 V AC or -48 V DC power supply.<br />
136
Section – III<br />
Chapter – 9<br />
Technical Specifications of<br />
ADSL L<strong>in</strong>e Tester<br />
137
Specifications of ADSL L<strong>in</strong>e Tester<br />
9.1 ADSL l<strong>in</strong>e tester should support the latest ADSL2+, ADSL2 and RE-ADSL<br />
standards, and should be used to support the older ADSL deployments.<br />
9.2 The Tester with ADSL2+ module should give all the <strong>in</strong>formation about the<br />
connection, right on screen and allow<strong>in</strong>g users to store results as a permanent<br />
record of the <strong>in</strong>stallation.<br />
9.3 It should support follow<strong>in</strong>g connectors<br />
9.3.1 RJ-45 for connection to an ADSL2+ l<strong>in</strong>e<br />
9.3.2 RS232C (V.24) DB-9 for upgrad<strong>in</strong>g software and download<strong>in</strong>g results to a PC.<br />
9.3.3 RJ-45 10BaseT Ethernet connection<br />
9.4 It should have at least 100 result storage.<br />
9.5 It should comply with follow<strong>in</strong>g standards:-<br />
9.5.1 ITU-T G.992.5 (ADSL2+)<br />
9.5.2 ITU-T G.992.3 (ADSL2) <strong>in</strong>clud<strong>in</strong>g RE-ADSL (Annex L)<br />
9.5.3 ITU-T G.992.1 (G.DMT)<br />
9.5.4 ANSI T1.413 Issue 2, and<br />
9.5.5 ITU-T G.994.1 (G.hs)<br />
9.6 Modes of Operation should be ATU-R.<br />
9.7 Chipset used should be Conexant.<br />
9.8 It should support follow<strong>in</strong>g general features:-<br />
9.8.1 Battery Module should be Rechargeable and Battery Usage should be more than 5<br />
hours<br />
9.8.2 AC Power (Ma<strong>in</strong>s) Adaptor should have Input 100-240 VAC, 50-60 Hz.<br />
9.8.3 It should have Display of at least 128 x 128 pixel backlit monochromatic LCD<br />
9.8.4 AC Power (Ma<strong>in</strong>s) Adaptor should have Input 100-240 VAC, 50-60 Hz & Output<br />
15 VDC, 2.7 A<br />
9.8.5 Operat<strong>in</strong>g Temperature should be 0°C to 50°C (32°F to 120°F)<br />
9.8.6 Storage Temperature should be –20°C to 70°C (–4°F to 158°F)<br />
9.8.7 It should have Display of 128 x 128 pixel backlit monochromatic LCD<br />
9.9 It should Support the follow<strong>in</strong>g optional Test Suites:<br />
9.9.1 Broadband Internet Application Test Suite (BIATS): features P<strong>in</strong>g, traceroute,<br />
Web Speed test<strong>in</strong>g<br />
138
9.9.2 Video over DSL Test Suite (VDTS): Features MPEG support, STB Emulation,<br />
Analysis of DSL,<br />
ATM, and IP layers<br />
9.9.3 Throughmode (TMOD): Features LOS counters, ADSL Frame counters, ATM<br />
Cell counters and<br />
DSL Parameters<br />
9.9.4 Video over IP Test Suite (VOIP): Features SIP & MGCP support, Call Flow<br />
Analysis, Jitter Analysis, and Interpacket Dispersion Analysis<br />
139