01.02.2015 Views

PAYMENT BOND - Build-laccd.org

PAYMENT BOND - Build-laccd.org

PAYMENT BOND - Build-laccd.org

SHOW MORE
SHOW LESS

You also want an ePaper? Increase the reach of your titles

YUMPU automatically turns print PDFs into web optimized ePapers that Google loves.

LOS ANGELES COMMUNITY COLLEGE DISTRICT<br />

DEPARTMENT OF FACILITIES PLANNING AND DEVELOPMENT<br />

PROPOSITION A/AA <strong>BOND</strong> PROGRAM<br />

<strong>PAYMENT</strong> <strong>BOND</strong><br />

Project No. ___________<br />

Bond No. ___________<br />

KNOW ALL PERSONS BY THESE PRESENTS:<br />

THAT WHEREAS, the Los Angeles Community College District (hereinafter referred to as "District") by<br />

Board action on _______, 20__, has awarded Construction Contract Number (hereinafter referred to as<br />

the “Contract”) to as Principal {hereinafter referred to as "Principal”) for the work described as follows:<br />

AND WHEREAS, said Principal is required by the Contract and/or by Division 3, Part IV, Title XV,<br />

Chapter 7 (commencing at Section 3247) of the California Civil Code to furnish a payment bond in connection<br />

with the Contract;<br />

NOW THEREFORE, we the Principal and<br />

(“Surety”), an admitted surety insurer pursuant to Code of Civil Procedure, Section 995.120, are held<br />

and firmly bound unto the District in the penal sum of Dollars ($ ) (this amount being not less than<br />

one hundred percent (100%) of the total sum payable by District under the Contract at the time the Contract is<br />

awarded by the District to the Principal) lawful money of the United States of America, for the payment of which<br />

sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors and assigns,<br />

jointly and severally, firmly by these presents.<br />

THE CONDITION OF THIS OBLIGATION IS SUCH that if Principal, its heirs, executors, administrators,<br />

successors, or assigns approved by District, or its subcontractors, of any contracting tier, shall fail to pay any<br />

person or persons named in Civil Code Section 3181, or amounts due under the Unemployment Insurance Code,<br />

with respect to work or labor performed under the Contract, or amounts required to be deducted, withheld, and<br />

paid over to the State of California Employment Development Department from the wages of employees of<br />

Principal and subcontractors pursuant to Section 13020 of the State of California Unemployment Insurance Code<br />

with respect to such work and labor, then Surety will pay for the same, in or to an amount not exceeding the<br />

penal amount hereinabove set forth, and also will pay in case suit is brought upon this bond, such reasonable<br />

attorney's fees as shall be fixed by the court, awarded and taxed as provided in Division 3, Part IV, Title XV,<br />

Chapter 7 (commencing at section 3247) of the California Civil Code.<br />

This bond shall inure to the benefit of any of the persons named in section 3181 of the California Civil<br />

Code, so as to give a right of action to such persons or their assigns in any suit brought upon this bond.<br />

No change, extension of time, alteration or modification of the Contract, or of the work to be performed<br />

thereunder, nor any rescission or attempted rescission of the Contract or this bond, nor any conditions precedent<br />

or subsequent in the bond or Contract attempting to limit the right of recovery of any claimant otherwise entitled to<br />

Form PA-0055 Page 1 of 2 Rev.2_03.27.07


LOS ANGELES COMMUNITY COLLEGE DISTRICT<br />

DEPARTMENT OF FACILITIES PLANNING AND DEVELOPMENT<br />

PROPOSITION A/AA <strong>BOND</strong> PROGRAM<br />

recover under the Contract or this bond, shall in any way affect Surety’s obligations on this bond; and Surety does<br />

hereby waive notice of any change, extension of time, alteration or modification of the Contract or of work to be<br />

performed thereunder.<br />

This bond shall be construed most strongly against the Surety and in favor of all persons for whose<br />

benefit such bond is given, and under no circumstances shall Surety be released from liability to those for whose<br />

benefit this bond has been given, by reason of any breach of the Contract by the District or Principal, but the sole<br />

conditions of recovery shall be that claimant is a person described in Section 3181 of the California Civil Code,<br />

and has not been paid the full amount of his or its claim.<br />

Surety’s obligations hereunder are independent of the obligations of any other surety for the<br />

performance of the Contract, and suit may be brought against Surety and such other sureties, joint and<br />

severally, or against any one or more of them or against less than all of them, without impairing the District<br />

rights against the others.<br />

Correspondence or claims relating to this bond shall be sent to Surety at the address set forth below.<br />

IN WITNESS WHEREOF, two (2) identical counterparts of this instrument, each of which shall for all<br />

purposes be deemed an original thereof, have been duly executed by the Principal and Surety named therein,<br />

on the day of , 200 the name and corporate seal of each corporate party being hereto affixed and<br />

these presents duly signed by its undersigned representative pursuant to authority of its governing body.<br />

(SEAL AND NOTARIAL<br />

ACKNOWLEDGMENT OF Principal (Seal)<br />

SURETY)<br />

BY<br />

(Name and Title)<br />

(Mailing Address of Surety)<br />

Surety<br />

BY<br />

(Name and Title)<br />

Note: Notary acknowledgment for Surety and Surety’s Power of Attorney must be<br />

included or attached.<br />

Form PA-0055 Page 2 of 2 Rev.2_03.27.07

Hooray! Your file is uploaded and ready to be published.

Saved successfully!

Ooh no, something went wrong!