ISO/Anti-Terrorism Equipment - Philippine National Police

cause(s). As soon as practicable after receipt of the Supplier’s notice, and
upon causes provided for under GCC Clause 22, the Procuring Entity shall
evaluate the situation and may extend the Supplier’s time for performance, in
which case the extension shall be ratified by the parties by amendment of
Contract.
18.3. Except as provided under GCC Clause 22, a delay by the Supplier in the
performance of its obligations shall render the Supplier liable to the imposition
of liquidated damages pursuant to GCC Clause 19, unless an extension of
time is agreed upon pursuant to GCC Clause 29 without the application of
liquidated damages.
19. Liquidated Damages
Subject to GCC Clauses 18 and 22, if the Supplier fails to satisfactorily deliver any or
all of the Goods and/or to perform the Services within the period(s) specified in this
Contract inclusive of duly granted time extensions if any, the Procuring Entity shall,
without prejudice to its other remedies under this Contract and under the applicable
law, deduct from the Contract Price, as liquidated damages, the applicable rate of one
tenth (1/10) of one (1) percent of the cost of the unperformed portion for every day of
delay until actual delivery or performance. The maximum deduction shall be ten
percent (10%) of the amount of contract. Once the maximum is reached, the
Procuring Entity shall rescind the Contract pursuant to GCC Clause 23, without
prejudice to other courses of action and remedies open to it.
20. Settlement of Disputes
20.1. If any dispute or difference of any kind whatsoever shall arise between the
Procuring Entity and the Supplier in connection with or arising out of this
Contract, the parties shall make every effort to resolve amicably such dispute
or difference by mutual consultation.
20.2. If after thirty (30) days, the parties have failed to resolve their dispute or
difference by such mutual consultation, then either the Procuring Entity or the
Supplier may give notice to the other party of its intention to commence
arbitration, as hereinafter provided, as to the matter in dispute, and no
arbitration in respect of this matter may be commenced unless such notice is
given.
20.3. Any dispute or difference in respect of which a notice of intention to
commence arbitration has been given in accordance with this Clause shall be
settled by arbitration. Arbitration may be commenced prior to or after
delivery of the Goods under this Contract.
20.4. In the case of a dispute between the Procuring Entity and the Supplier, the
dispute shall be resolved in accordance with Republic Act 9285 (“R.A.
9285”), otherwise known as the “Alternative Dispute Resolution Act of 2004.”
20.5. Notwithstanding any reference to arbitration herein, the parties shall continue
to perform their respective obligations under the Contract unless they
57