C/o Motorable Steel Arch Bridge over river Yamne at Reglat (Bysang)

More documents

Recommendations

Info

47 CONDITIONS OF CONTRACT 1. 1.1. A. GENERAL Definitions Terms which are defined in the Contract Date are not also defined in the Conditions of Contract but keep their defined meanings. Capital initials are used to identify defrned terms. The Adjudicator (synonymous with Dispute Review E\*pert) is the person appointed jointly by the Employer and the Contractor to resolve disputes in the first instance, as provided for in Clauses 24 and 25. The narne of the Adjudicator is de{ined in the Contract Data. Bill of Quantities part of the Bid. means the priced and completed Bill of Quantities forming Compensation Events are those defined in Clause 44 hereunder. The Completion Date is the date of completion of the Works as certified by the Engineer in accordance with Sub Clause 55.1. The Contract is the contract between the Employer and the Contractor to execute, complete and maintain the Works. It consists of the documents listed in Clause 2.3 below. The Contract Data defines the documents and other information which comprise the Contract. The Contractor is a person or corporate body whose Bid to carr5,' out the Works has been accepted by the Employer. The Contractor's Bid is the completed Bidding document submitted by the contractor to the Employer and includes Technical and Financial bids. The Contract price is the price stated in the Letter of Acceptance and thereafter as adjusted in accordance with the provisions of the contract. Da5rs are edendardays; monthsare caiendar morrtlrs. A Defect is any part of the works not completed in accordance with the Contract. The Defects r iahflitJr Period is the period named in the Contract data and calculated from the Complelion Date. The Employer is the party who will employ the contractor to carry out the Works. The Engineer is the person named in the contract Data (or any other competent person appointed and notified to the Contractor to act in replacement of the Engineer) who is responsible for supervising the Contractor, administrating the Contract, certifying pa5rments due to the contractor, issuing and valuing variations to the contract, awarding extensions of time, and valuing the Compensation Events. c =O Otl:O e.'=O I=-O -o-,
48 Equipment is the Contractor's machinery and vehicles brought temporarily to the Site to construct the Works. The Initial Contract Price is the Contract Price listed in the Employer's Letter of Acceptance. The Intended Completion Date is the date on which it is intended that the Contractor shall complete the Works" The Intended Completion Date is specified in the Contract Data- The Intended Completion Date may be revised only by the Engineer by issuing an extension of time. Materials are all supplies, including consumables, used by the contractor for incorporation in the Works. Plant is an integral part of the Works which is to have a mechanica-l, electrical, electronic or chemical or biological function. The Site is the area defined as such in the Contract Data. Site Investigation Reports are those which were included in the Bidding documents and are factual interpretative reports about the surface ad subsurface conditions at the site. Specitication means the Specification of the Works included in the Contract and any modification or addition made or approved by the Engineer. The Start Date is given in the Contract Data. It is the date when the Contractor shall commence execution of the works. It does not necessarily coincide with any of tlle Site Possession Dates. A Subcontractor is a person or corporate body who has a Contract with the Contractor to carry out a part of the work in the Contract which includes work on the site. Temporary Works are works designed, constructed, installed and removed by the Contractor which are needed for construction or installation of the Works. 1\ Variation is an instmctioq glYqn by the Englneg:r-q[ich varies the Wor@ The Works are what the Contract requires the Contractor to construct, install, and turn over to the Employer, as defined in the Contract Data. 2. 2.1 2.2 Interpretation In interpreting these Conditions of Contract, singular also means plural, male also means female or neuter, and the other way afound. Headings have no significance. Words have their normal meaning under the language of the Contract unless specifically defined. The Engineer will provide instructions clarifying queries about the Conditions of Contract. If secti.onal completion is specified in the Contract Data, references in the Conditions of Contract to the Works, the Completion Date, and the Intended Completion Date apply to any Section of the Works (other than references to the Completion Date and Intended Completion date for the whole of the Works). i. c-- o Ot.I:.8 b=c f= g '1 ,",-'
Page 1 and 2: GOVERNMENT OF ARUNACHAL PRADESII PU
Page 3 and 4: lrt t^ffitr l)(w' c--0 O\^J 2 O J=-
Page 5 and 6: .*natr) I v/>) >., .4 ll.4 lv( i l'
Page 7 and 8: -- .- f,=- D:b I >-
Page 9 and 10: o ^M I ,i:-,-_
Page 11 and 12: 10 SECTION 1 INSTRUCTIONS TO BIDDER
Page 13 and 14: 1.2 A. GENERAL L 1. 1. r.2. 1.3 2.
Page 15 and 16: T4 (k) 0) 4.4. 4.5. A. (a) (b) (c)
Page 17 and 18: c-_ a ow=C I=O D=tl IO 4.7. Bidders
Page 19 and 20: c-- o OU.l = D l-- o D: t) l8 9. 9.
Page 21 and 22: 20 13. 13.1 13.2. Bid Prices The co
Page 23 and 24: C:O Or^l: O (D=b t=- ol 2e (c) in t
Page 25 and 26: AA z- 23.3. zJ.+ 23.5. 3.6. 23.7. '
Page 27 and 28: o gN:e Dzb Such adjusteC bid price
Page 29 and 30: z6 36. 36.1. 37. 37 "r" 37.2" Dispu
Page 31 and 32: c -bl >C 5 =-t) 30 9. Price level o
Page 33 and 34: c+b ot^l -o S=-c I--t JZ ' Atntgn R
Page 35 and 36: 34 filoffi I I i.':-',-- C=A c)"^l
Page 37 and 38: 36 #I.3-2. Quantities of work execu
Page 39 and 40: C: O gvJz 0 D: t) I=o 38 1"6" Quali
Page 41 and 42: gr,tzo DzO L=4 40 SAMPLE FORMAT FOR
Page 43 and 44: C'-o oul zb D:b T=o 42 UNDERTAKING
Page 45 and 46: 44 .,tlnffiw v)" I C=A gt^I? O D>O
Page 47: I I r.ioN=o D>c f=o 46 t1 at(ilK )"
Page 51 and 52: OW: O .Dr c T=e 50 8. 8.1. Other Co
Page 53 and 54: C =.O or.I = D Di o Iio 52 19. 19.1
Page 55 and 56: 54 28.2 28.3 28.3A. 29. 30. 30.1 31
Page 57 and 58: 38.2 The Engineer shal1 not adjust
Page 59 and 60: 58 (d)TheEngineerinstructstheContra
Page 61 and 62: DJc JzC 60 49.2. 49.3. If the Inten
Page 63 and 64: g>t^l: O t> =O 58. 58.1 scope gf th
Page 65 and 66: D =C I--o 64 F. SPE|CIAL CONDITIONS
Page 67 and 68: 66 i) k) r) m) n) Payment of Bonus
Page 69 and 70: ig (c) If one of the parties faiis
Page 71 and 72: 70 Commissioner, Government of Arun
Page 73 and 74: 72 SECTION 4 CONTRACT DATA c ao o\^
Page 75 and 76: 74 (Al Road Works Clause Rederemc w
Page 77 and 78: t) Clause Reference @-to section 3
Page 79 and 80: C so c)t^): o D=o .L=o 78 :*"Tr["i:
Page 81 and 82: ii. Equipment 80 9Ao/o fot rler.i.'
Page 83 and 84: 82 SECTION 5 TDCIINICAL SPECIFICATI
Page 85 and 86: 84 lrt f)\uffir'\ I V IV V Cr o eul
Page 87 and 88: c,=.b outzg D=o Do 86 llrr A /l tl
Page 89 and 90: c>b P>0 f=P 88 6. We accept the app
Page 91 and 92: Ca o g t^}"-o D=0 I=a 90 ,j,',
Page 93 and 94: 9'2 (,)lnfrw l0 ))" V I I CtA gr,Ie
Page 95 and 96: 94 (illnffiw l!)' C-?t] ClvJ:O D=o
Page 97 and 98: " '14- / :; :,1. : .- . -,' : '-: :
Page 99 and 100:
98 ^lr( n nfn ll n\ a^ll?,))t)'" |
Page 101 and 102:
100 This Guarantee will remain in f
Page 103 and 104:
o2 I ṭk= Cac ON:O D :-O IrO A
Page 105 and 106:
104 I C, >c gt^i+_b D:c D=P
Page 107 and 108:
(s) forthwith replace the sarne wit
Page 109 and 110:
C=r] OWz O D=O ftC; 108 ^flr( aliaf
Page 111 and 112:
c-r-o $$Je s D=O c fr/\ 1 ( _.
Page 113 and 114:
l LZ franW C=O gw=o D:O )=e ; ''/^
Page 115 and 116:
C zb euf >O D=O Ll4 The Common Seal
Page 117 and 118:
lt6 \loffiW C=O OuI+P D=C ft' l 'L
Page 119 and 120:
i18 ^rw glaffiy, C :O P aO \ '1r* L
Page 121 and 122:
124 ^l1r( 11 r'tffi ll rr) a^llu)u'
Page 123:
t2'2 lln .')alaffiru lT\il&r)>' I L
show all

C/o Motorable Steel Arch Bridge over river Yamne at Reglat (Bysang)

You also want an ePaper? Increase the reach of your titles

Delete template?

Save as template?