Model agreement - The NHBRC

More documents

Recommendations

Info

Title Date or revision Available SABS 0400: The application of the National Building Regulations 1990 South African Bureau of Standards Home Building Manual Part 3 1999 National Home Builders Registration Council Model Preambles for Trades E: Precast concrete I: Carpentry and joinery J: Ceilings, partitions and access flooring K: Floor coverings, wall lining, etc L: Ironmongery N Metalwork P: Tiling Q: Plumbing and drainage R: Glazing S: Paintwork T: Paperhanging 1999 The Association of South African Quantity Surveyors Architects Project Specification Rev 0 31/07/03 Attached as Annex A Engineers specifications - From competent person appointed by the contractor. 4. Constraints on how the Contractor provides the Works State any constraints on how the sequence and timing of work and on the methods and conduct of work. The following item must, however, be included: 4.1 The Contractor shall not commence construction before the National Home Builders Registration Council has issued a home enrolment certificate for the house and the housing consumer has been issued with a duly completed Standard Home Warranty. Examples of other requirements: 4.2 The Contractor takes all reasonable precautions to protect the trees and plants designated by the Employer 4.3 Where materials are specifically identified by manufacturer’s name, brand or trade name, such references are used to indicate the type and quality of material to be used only, and alternative materials of similar quality and specification may be used in certain circumstances. The Contractor’s proposal to use any such alternative must be submitted to the Employer’s representative for acceptance before the materials are brought onto site or used. 5 Requirements for the programme State whether a programme is required, and if it is, state what form it is to be put in, what information is to be shown on it , when it is to be submitted and when it is to be updated. Example: 5.1 A programme in the form of a bar chart is to be submitted to the architect (employer’s nominee) for acceptance before commencement of work on site. The information to be shown on the programme includes at least the starting date, the Completion Date, the Contractor’s planned Completion, key dates for co-ordination with principal suppliers and subcontractors, and the order and timing of the activities which the Contractor plans to do in order to Provide the Works. 5.2 Revised programmes are submitted for the Architect’s acceptance every second Friday until Completion. Revised programmes show the actual progress achieved and its effect on the timing of the remaining work, and how the Contractor plans to deal with any delays and to correct Defects. 6 Services and other items provided by the Employer Describe what the Employer will provide such as services (including water and electricity) and free issue Plant and Materials and Equipment. Example: 6.1 The Employer provides the following services and “free issue” Plant and Materials 8
Item Date by which it will be supplied Services Water at usual domestic pressure As required Electricity 3 phase 220v After connection is made Plant & Materials Tiles for kitchen and bathroom In accordance with programme 9
Page 1 and 2: National Home Builders Registration
Page 3 and 4: # Title of proforma document Commen
Page 5 and 6: Appendix A: Basic contract where pa
Page 7: 1. Description of the works SCOPE O
Page 11 and 12: CONTRACT FOR THE CONSTRUCTION OF A
Page 13 and 14: Agreement comes into effect. Failur
Page 15 and 16: Description of the works ………
Page 17 and 18: The Adjudicator is Name ………
Page 19 and 20: C1.2 CONTRACT DATA (for use with th
Page 21 and 22: 15.3 Arbitration The Rules are the
Page 23 and 24: 11 Masonry to top of windows R R R
Page 25 and 26: Title Date or revision Available SA
Page 27: PART 4 : SITE INFORMATION Provide i

Model agreement - The NHBRC

Create successful ePaper yourself

Delete template?

Save as template?